USE OF COMPLETED CONSTRUCTION PHASES Sample Clauses

USE OF COMPLETED CONSTRUCTION PHASES. COMPANY reserves the right to ------------------------------------ occupy and use Construction Phases or systems within the Facility as they are completed, including those Construction Phases or systems completed in advance of other portions of the Facility, and such Construction Phases or systems may be occupied or used pending completion of said other portions, provided that -------- ---- such occupancy or use by COMPANY would not unduly interfere with CONTRACTOR'S subsequent work on the Facility. CONTRACTOR shall complete the milestones in the order of precedence designated by Section 14.1 above, prepare the ------------ Construction Phases for occupancy and testing, and turn same over to COMPANY for operation or use in the aforesaid order of precedence. In such case COMPANY shall give CONTRACTOR a separate notice on each occasion when it takes over any such portion of the Facility for occupancy and testing. If any system in the Facility has been substantially completed and all Punch List items affecting such system, other than minor cosmetic matters (as described in Section 15.2.1), -------------- have been completed, then the provisions of Section 18.1 regarding warranties ------------ and guarantees shall apply. It shall be understood, however, that neither COMPANY'S taking over, or occupancy or use of, any portion or system of the Facility, nor any notice given by COMPANY in connection therewith shall in any way be construed to commit COMPANY to the acceptance of any Construction Work not completed or furnished in accordance with the Design Documents pertaining thereto, nor to constitute a Final Acceptance thereof nor to relieve CONTRACTOR from its obligation to complete the Facility (if it is then not already completed) or from any other unfulfilled obligations or responsibilities under the Contract.
Sample 1
AutoNDA by SimpleDocs

Related to USE OF COMPLETED CONSTRUCTION PHASES

  • Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Completion of Construction (a) For the purposes of this Agreement, the terms "

  • Maintaining Records; Access to Properties and Inspections; Maintenance of Ratings (a) Keep proper books of record and account in which full, true and correct entries in conformity with GAAP and all requirements of law are made of all dealings and transactions in relation to its business and activities. Each Loan Party will, and will cause each of its subsidiaries to, permit any representatives designated by the Administrative Agent or any Lender to visit and inspect the financial records and the properties of such Person at reasonable times and as often as reasonably requested and to make extracts from and copies of such financial records, and permit any representatives designated by the Administrative Agent or any Lender to discuss the affairs, finances and condition of such Person with the officers thereof and independent accountants therefor.

  • Definitions and Construction 1 1.1 Definitions.....................................................................................1 1.2

  • Headings and Construction The headings of sections in this Agreement are for convenience of reference only and are not intended to qualify the meaning of any section. Any reference to a section number shall refer to a section of this Agreement, unless otherwise stated.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.

  • Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

Time is Money Join Law Insider Premium to draft better contracts faster.