Minor Change Orders definition

Minor Change Orders means changes in the Improvements, the Plans or the other Construction and Development Documents which do not modify the scope or overall quality of the Project or involve extensions of time of the Required Completion Date under the General Construction Contract and the performance of which costs less than Five Hundred Thousand Dollars ($500,000) each or Three Million Dollars ($3,000,0000) in the aggregate.
Sample 1Sample 2
Minor Change Orders means amendments or change orders to any Construction Contract that do not result in any deviation from the Project Plans and which have an impact on the Eligible Costs of less than a threshold amount which shall be Approved by the Project Committee;
Sample 1

Examples of Minor Change Orders in a sentence

  • Change Orders other than Minor Change Orders shall be subject to Bank’s reasonable review and approval.

  • Minor Change Orders (under $50,000 per change which do not affect the systems or structure of the Building) shall not require Landlord’s approval.

  • Management’s Annual Report on Internal Control Over Financial ReportingManagement of the Company is responsible for establishing and maintaining effective internal control over financial reporting as defined in Rule 13a-15(f) under the Exchange Act.

  • Initiates Major Change Orders and Minor Change Orders for Department Head or designee approval and maintains Change Order Log.

  • Except for Minor Change Orders, no changes in the Plans or the other Construction and Development Documents (including change orders) shall be effective, unless approved in writing in advance by Lender, as hereinafter described.

  • All Change Orders and Minor Change Orders must be formalized with an agreement prior to work performed.

  • Lender’s approval shall be required for changes in the Plans or the other Construction and Development Documents which are not Minor Change Orders.

  • Except for Minor Change Orders, Borrower will not amend or modify any provisions of the Plans, Construction and Development Documents or the Project Covenant Documents without providing prior written notice, along with copies of such amendments or modifications, to Lender and obtaining the prior consent required by Section 4.15.

  • Each of these parties would also review the change order request as follows:▪ A change order and estimate is prepared by the Rehabilitation Specialist, reviewed by the building inspector and Housing Coordinator, and approved by the owner and contractor.▪ If a change order and estimate represents a monetary change of 10% in the award amount, then bids must be obtained as in Section 5:8:1 below under Minor Change Orders.

  • Other than with respect to Minor Change Orders, any amendments or changes to the Renovation Budget shall require the approval of Lender in its reasonable discretion.

Related to Minor Change Orders

  • Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Unilateral Change Order (ULCO means a Change Order issued by Owner without the complete agreement of Contractor, as to cost and/or time.

  • Construction Change Directive means a written order prepared by Owner Parties and signed by Owner directing Contractor to perform a change in the Work prior to agreeing to a change, if any, to the Contract Time, schedule of performance of the Work, Contract Sum, or Contractor’s compensation.

  • Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including:

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Change of Scope Order shall have the meaning set forth in Clause 13.2 (iv); “Completion Certificate” shall have the meaning set forth in Clause 12.2; “Construction” shall have the meaning set forth in Clause 1.2 (f);

  • Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.

  • Major Change means any event or proposed modification that, in the opinion of the Fund, will involve a major change in, or a restructuring of, a Funded Activity’s scope, structure, design or objectives, including a reallocation of GCF Proceeds beyond the threshold set out in the relevant FAA affecting the Funded Activity’s scope or objectives, or any other change that substantially alters the purpose or benefit of the Funded Activity, in each case, as may be described in detail in the relevant FAA;

  • Construction Drawings means those drawings containing the technical details associated with the design, construction and installation of the Infrastructure;

  • Minor modification means a modification that does not significantly alter the nongovernmental function or purpose of the software or is of the type customarily provided in the commercial marketplace.

  • Major modification means any physical change in or change in the method of operation of a major stationary source that would result in a significant emissions increase of a regulated NSR pollutant and a significant net emissions increase of that pollutant from the major stationary source.

  • Design Change is a change in work and/or materials shown in the Schedule of Items and described in Plans or specifications that has been mutually agreed to in writing or ordered by Contracting Officer. Changes of a minor nature (such as adjustment in horizontal and vertical alignment, that do not exceed specified tolerance, necessary to maintain or balance earthwork quantities substantially as designed) and variation in quantities, as described in B5.251, shall not be considered Design Changes.

  • Construction Budget means the fully-budgeted costs for the acquisition and construction of a given parcel of real property (including, without limitation, the cost of acquiring such parcel of real property, reserves for construction interest and operating deficits, tenant improvements, leasing commissions, and infrastructure costs) as reasonably determined by the Parent in good faith.

  • Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Building Plans means the general building plans in respect of the Development or in respect of any part or parts of the Development prepared by the Authorized Person and approved by the Building Authority and includes any amendments thereto from time to time approved by the Building Authority;

  • Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.

  • Service Specifications means the following documents, as applicable to the Services under Your order: (a) the Oracle Cloud Hosting and Delivery Policies, the Program Documentation, the Oracle service descriptions, and the Data Processing Agreement described in this Schedule C; (b) Oracle’s privacy policies; and (c) any other Oracle documents that are referenced in or incorporated into Your order. The following do not apply to any non-Cloud Oracle service offerings acquired in Your order, such as professional services: the Oracle Cloud Hosting and Delivery Policies, Program Documentation, and the Data Processing Agreement. The following do not apply to any Oracle Software: the Oracle Cloud Hosting and Delivery Policies, Oracle service descriptions, and the Data Processing Agreement.

  • Technical Specifications A specification in a document defining the characteristics of a product or a service, such as the quality levels, the environmental and climate performance levels, the design for all needs, including accessibility for people with disabilities, and the evaluation of conformity, of product performance, of the use of the product, safety or dimensions, as well as requirements applicable to the product as regards the name by which it is sold, terminology, symbols, testing and test methods, packaging, marking or labelling, instructions for use, the production processes and methods at every stage in the life cycle of the supply or service, as well as the evaluation and conformity procedures;

  • Product Schedule means the “Product Schedule” that forms part of the Contract.

  • Benchmark Replacement Conforming Changes means, with respect to any Benchmark Replacement, any technical, administrative or operational changes (including changes to the definition of “Base Rate,” the definition of “Business Day,” the definition of “Interest Period,” timing and frequency of determining rates and making payments of interest, timing of borrowing requests or prepayment, conversion or continuation notices, the applicability and length of lookback periods, the applicability of breakage provisions, and other technical, administrative or operational matters) that the Administrative Agent decides may be appropriate to reflect the adoption and implementation of such Benchmark Replacement and to permit the administration thereof by the Administrative Agent in a manner substantially consistent with market practice (or, if the Administrative Agent decides that adoption of any portion of such market practice is not administratively feasible or if the Administrative Agent determines that no market practice for the administration of such Benchmark Replacement exists, in such other manner of administration as the Administrative Agent decides is reasonably necessary in connection with the administration of this Agreement and the other Loan Documents).

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;