Site Acquisition Substantial Completion definition

Site Acquisition Substantial Completion means, with respect to any PCS System or PCS Sub-System, the point at which the Owner will have acquired, by purchase, lease or otherwise, rights to a sufficient number of System Element Locations within the specified System Area or System Sub-Area to be covered by such PCS System or PCS Sub-System such that the performance criteria specified in Exhibit F applicable to such PCS System or PCS Sub-System would be substantially satisfied in the reasonable opinion of the Owner subject to the reasonable acceptance of the Vendor. If the Vendor upon receiving notice from the Owner that Site Acquisition Substantial Completion has been achieved in any PCS System or PCS Sub-System disagrees with the Owner's claim, then the Vendor will have ten (10) Business Days to detail its disagreement in writing to the Owner and a Third Party Engineer chosen by the Owner and such Third Party Engineer will have ten (10) Business Days from the receipt of such writing to make a determination whether or not the Owner's claim of Site Acquisition Substantial Completion is reasonable. The Third Party Engineer will have no discretion or authority to provide the Parties with any answer other than whether in its judgment the Owner's claim is reasonable. Such determination by the Third Party Engineer will be final and binding upon the Parties.
Sample 1Sample 2Sample 3
Site Acquisition Substantial Completion means, with respect to any System, the point at which the Owner shall have: (i) acquired, by purchase, lease or otherwise, rights to a sufficient number of Sites in the judgment of the Owner; and (ii) that, with respect to all Sites within such System, all land use and/or lease requirements necessary to be satisfied prior to the start of construction activities in accordance with Applicable Laws have been satisfied.
Sample 1Sample 2
Site Acquisition Substantial Completion means, with respect to any Functional Unit, the point at which Impsat will have acquired, by purchase, lease or otherwise through Site Acquisition, rights to a sufficient number of Sites within the geographic area to be covered by such Functional Unit such that the Performance Criteria specified in the Specifications and Standards applicable to such Functional Unit would be substantially satisfied in the reasonable opinion of Impsat, subject to the reasonable concurrence of the Vendor.
Sample 1

Examples of Site Acquisition Substantial Completion in a sentence

  • Upon Site Acquisition Substantial Completion, Owner shall notify Vendor of the Site Acquisition Substantial Completion Date.

  • The Build Notice for each PCS System or PCS Sub-System will also include the Owner's best forecast based upon information available at such time (the "M5 Forecast") of when it expects to be able to declare Site Acquisition Substantial Completion within such PCS System or PCS Sub-System.

  • In the event that the Owner determines that it is unlikely to achieve Site Acquisition Substantial Completion for any PCS System and/or PCS Sub-System in a timely and cost-effective manner, the Vendor will modify certain performance criteria set forth in Exhibit F with respect to such PCS System and/or PCS Sub-System in the manner and to the degree that the Owner reasonably specifies in writing to the Vendor in accordance with the terms of Exhibit B3.

  • You agree your use of the service and all information and content, including that of third parties, is at your risk and is provided on an “as is” and “as available” basis.

  • The Build Notice for each PCS System will also include the Owner's best forecast based upon information available at such time (the "M5 Forecast") of when it expects to be able to declare Site Acquisition Substantial Completion within such PCS System.


More Definitions of Site Acquisition Substantial Completion

Site Acquisition Substantial Completion means, with respect to any --------------------------------------- PCS System, the point at which the Owner will have acquired, by purchase, lease or otherwise, rights to a sufficient number of System Element Locations within the specified System Area to be covered by such PCS System such that the performance criteria specified in Exhibit F applicable to such PCS System would be substantially satisfied in the reasonable opinion of the Owner subject to the reasonable acceptance of the Vendor. If the Vendor upon receiving notice from the Owner that Site Acquisition Substantial Completion has been achieved in any given PCS System disagrees with the Owner's claim, then the Vendor will have ten (10) days to detail its disagreement in writing to the Owner and an Independent Auditor chosen by the Owner and such Independent Auditor will have ten (10) business days from the receipt of such writing to make a determination whether or not the Owner's claim of Site Acquisition Substantial Completion is reasonable. The Independent Auditor will have no discretion or authority to provide the Parties with any answer other than whether in its judgment the Owner's claim is reasonable. If the Parties still disagree in good faith with the determination by the Independent Auditor such dispute will be referred to arbitration pursuant to the terms of subsection 23.1 for final resolution.
Sample 1

Related to Site Acquisition Substantial Completion

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Completion Certificate means a certificate of the I-Bank to the effect that the construction of the Project is complete.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Construction and Demolition Debris means and includes:

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Final Completion Date means the date on which Final Completion occurs.

  • construction site means a workplace where construction work is being performed;

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • public open space means the securing of an area of a site at grade or street level which is acceptable to the City and is appropriately landscaped for the use and enjoyment of the public during reasonable hours.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.