§ 2 - Extension of Time Sample Clauses

§ 2 - Extension of Time. Where mileage is allowed between the point where final terminal delay time begins and the point where finally relieved, each mile so allowed will extend the 60 minute period after which final terminal delay payment begins by the number of minutes equal to 60 divided by the applicable overtime divisor (60/12.5 = 4.8; 60/13 = 4.6; 60/13.25 = 4.5; 60/13.5 = 4.4, etc.). (Arbitration Award 458, Article 5, Section 2) 6. (a) § 3 - Payment Computation All final terminal delay, computed as provided for in this Article, shall be paid for, on the minute basis, at one-eighth (1/8th) of the basic daily rate in effect as of June 30, 1986, according to class of service and engine used, in addition to full mileage of the trip, with the understanding that the actual time consumed in the performance of service in the final terminal for which an arbitrary allowance of any kind is paid shall be deducted from the final terminal time under this Article. The rate of pay for final terminal delay allowance shall not be subject to increases of any kind. After road overtime commences, final terminal delay shall not apply and road overtime shall be paid until finally relieved from duty NOTE: The phrase "relieved from duty" as used in this Article includes time required to make inspection, complete all necessary reports and/or register off duty. NOTE: Employees who have an engineers/train service seniority date prior to October 31, 1985 when over time, initial terminal delay and final terminal
Sample 1
AutoNDA by SimpleDocs

Related to § 2 - Extension of Time

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.

  • Calculation of Time For the purposes of this Agreement, “days” refers to calendar days unless otherwise specified.

  • EXTENSION OF USE The Contract may be extended to additional States or governmental jurisdictions upon mutual written agreement between New York State (the lead contracting State) and the Contractor. Political subdivisions and other authorized entities within each participating State or governmental jurisdiction may also participate in the Contract if such State normally allows participation by such entities. New York State reserves the right to negotiate additional minimum NYS Vehicle Discounts based on any increased volume generated by such extensions.

  • Computation of Time In computing any period of time prescribed or allowed by procedures herein, the date of the act, event, or default for which the designated period of time begins to run shall not be included. The last day of the period so computed shall be counted, unless it is a Saturday, a Sunday, or a legal holiday, in which event the period runs until the end of the next day which is not a Saturday, a Sunday, or a legal holiday.

  • Calculation of Time Periods Unless otherwise specified, in computing any period of time described in this Agreement, the day of the act or event after which the designated period of time begins to run is not to be included and the last day of the period so computed is to be included, unless such last day is a Saturday, Sunday or legal holiday under the laws of the State in which the Property is located, in which event the period shall run until the end of the next day which is neither a Saturday, Sunday or legal holiday. The final day of any such period shall be deemed to end at 5 p.m., local time.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!