ACCEPTANCE AND REJECTION a. Buyer shall accept the Services or give Seller notice of rejection within a reasonable time after the date of delivery. No payment, prior test, inspection, passage of title, any failure or delay in performing any of the foregoing, or failure to discover any defect or other nonconformance shall relieve Seller of any obligations under this Contract or impair any rights or remedies of Buyer.
b. If Seller delivers defective or non-conforming Services, Buyer may at its option and at Seller's expense: (i) require Seller to promptly reperform, correct or replace the Services; (ii) correct the Services; or (iii) obtain replacement Services from another source. Return to Seller of defective or non-conforming Services and redelivery to Buyer of corrected or replaced Services shall be at Seller's expense.
c. Seller shall not redeliver corrected or rejected Services without disclosing the former rejection or requirement for correction. Seller shall disclose any corrective action taken. All repair, replacement and other correction and redelivery shall be completed as Buyer may reasonably direct.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.
REJECTION OF GOODS Notwithstanding any other rights of, or remedies available to UNDP under the Contract, in case any of the Goods are defective or otherwise do not conform to the specifications or other requirements of the Contract, UNDP, at its sole option, may reject or refuse to accept the Goods, and within thirty (30) days following receipt of notice from UNDP of such rejection or refusal to accept the Goods, the Contractor shall, in sole option of UNDP:
11.7.1 provide a full refund upon return of the Goods, or a partial refund upon a return of a portion of the Goods, by UNDP; or,
11.7.2 repair the Goods in a manner that would enable the Goods to conform to the specifications or other requirements of the Contract; or,
11.7.3 replace the Goods with Goods of equal or better quality; and,
11.7.4 pay all costs relating to the repair or return of the defective Goods as well as the costs relating to the storage of any such defective Goods and for the delivery of any replacement Goods to UNDP.
Acceptance Process All deliverables must be received and accepted in writing by Department’s Grant Manager before payment. The Grantee shall work diligently to correct all deficiencies in the deliverable that remain outstanding, within a reasonable time at Grantee’s expense. If Department’s Grant Manager does not accept the deliverables within 30 days of receipt, they will be deemed rejected.
Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.
Rejection State Street reserves the right to decline to process or delay the processing of a payment order which (a) is in excess of the collected balance in the account to be charged at the time of State Street's receipt of such payment order; (b) if initiating such payment order would cause State Street, in State Street's sole judgment, to exceed any volume, aggregate dollar, network, time, credit or similar limits upon wire transfers which are applicable to State Street; or (c) if State Street, in good faith, is unable to satisfy itself that the transaction has been properly authorized.
Acceptance of the Work 19.1 No act of, or failure to act by, the Owner or the OWNER'S REPRESENTATIVE during the course of the Work, nor any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the Final Payment by the Owner to Contractor. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof.
19.2 Contractor agrees to guarantee all work under this Contract for a period of one year from the date of Final Payment by the Owner or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required under terms of Owner’s conditional acceptance of elements of the Work the Owner deems marginally substandard. If any unsatisfactory condition or damage develops within the time of this guarantee period due to materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the OWNER’S REPRESENTATIVE, then the Contractor shall, when notified by the Owner or OWNER’S REPRESENTATIVE, immediately place such guaranteed Work in a condition satisfactory to the Owner or OWNER’S REPRESENTATIVE. Such guarantee shall be in addition to any implied warranty under law or other manufacturer’s or product supplier’s warranty. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.
Initiation of TIPS Sales When a public entity initiates a purchase with Vendor, if the Member inquires verbally or in writing whether Vendor holds a TIPS Contract, it is the duty of the Vendor to verify whether the Member is seeking a TIPS purchase. Once verified, Vendor must include the TIPS Contract Number on all purchase communications and sales documents exchanged with the TIPS Member.
