Acceptance of Milestones Sample Clauses

Acceptance of Milestones. Each Milestone identified in an Implementation Plan shall be subject to the acceptance procedures set forth in this Section. (1) BNY Mellon shall notify Voya upon completion of each Milestone. Voya shall determine whether each Milestone conforms to its Milestone Completion Criteria. If a Milestone meets its Milestone Completion Criteria, then Voya shall provide BNY Mellon with notice that such Milestone has been accepted. (2) If a Milestone fails to conform to its Milestone Completion Criteria or if BNY Mellon has failed to provide sufficient information for Voya to assess whether a Milestone conforms to its Milestone Completion Criteria, Voya shall notify BNY Mellon of such failure. Promptly after receiving such notice, BNY Mellon shall correct the Milestone such that it meets its Milestone Completion Criteria. BNY Mellon’s efforts to make such corrections shall be provided at no additional cost or expense to Voya. Upon completion of such corrections, BNY Mellon shall notify Voya of its completion of such Milestone. The process set forth in clause (1) and this clause (2) shall be repeated as necessary until the Milestone meets its Milestone Completion Criteria. (3) A Milestone shall be accepted upon the receipt by BNY Mellon of notice from Voya that such Milestone has been accepted. Acceptance shall in no way impair Voya’s rights under the representations and warranties set forth in Article 14 or act as a waiver of Voya’s rights or remedies under the Agreement.
Sample 1Sample 2Sample 3See All (15)
AutoNDA by SimpleDocs
Acceptance of Milestones. SmartDisk shall deliver to Sony each milestone associated with a deliverable as set forth in the Development Schedule for review and approval by Sony. Sony will test the delivered milestone to determine whether such delivered milestone is in conformity with the Final Specifications. Sony will inform SmartDisk whether such delivered milestones are in conformity with the Final Specifications within the time periods set forth in the Development Schedule. In the event that a delivered milestone does not conform to the relevant portion of the Final Specification (such nonconformance will be referred to as "DEFICIENCIES"), Sony shall reject the delivered milestone and provide written notice to SmartDisk describing the Deficiencies in sufficient detail to allow SmartDisk to correct the Deficiencies. Within a period of time to be agreed between the parties after receiving each report regarding Deficiencies, SmartDisk will use its best commercial efforts to correct the Deficiencies so that the milestone conforms to the applicable part of the Final Specifications. The procedure in this Section 3.3 will be repeated with respect to a milestone to determine whether it is acceptable to Sony. In the event a delivered milestone fails to conform to the Final Specifications more than two times, the Program Managers shall meet to determine the appropriate course of action.
Sample 1Sample 2
Acceptance of Milestones. Upon completion of each milestone listed in a SOW, the 4SIGHT project manager will send an email with the summary of the activities completed by 4SIGHT and a request for Your approval. You must acknowledge and confirm successful completion of such milestone based on the requirements described in the applicable SOW (“Acceptance”) within seven days of such request, such Acceptance not to be unreasonably withheld. If You do not provide Acceptance within such time period, it will be deemed given. Any dispute of completion by You shall be accompanied by an explanation of the nonconformity with sufficient detail for 4SIGHT to cure such nonconformity and 4SIGHT shall have a reasonable opportunity to correct any such nonconformity. If You fail to provide Acceptance or dispute within the Acceptance period, the milestone will be deemed completed and You waive any right to dispute completion of such milestone.
Sample 1
Acceptance of Milestones. 1 2.3 Critical Milestones.................................................................................................................... 2 3. SERVICES............................................................................................................................................. 3 3.1 Objectives.................................................................................................................................. 3 3.2 Generally................................................................................................................................... 3 3.3 Cooperation with Regulatory Authorities................................................................................. 3 3.4 Complaints, Proceedings and Inquiries......................................…........................................... 4 3.5 Correspondence with Constituents............................................................................................ 4 3.6 Service Provider Laws............................................................................................................... 4
Sample 1
Acceptance of Milestones. Each milestone identified in a Transition Plan shall be subject to the acceptance procedures set forth in this Section 2.2.
Sample 1
Acceptance of Milestones project approach w ill be used by Infor as outlined in the Project Scope section of this SOW. All milestones w ill require acceptance and sign off by the Licensee prior to Infor submitting the invoice to Licensee for payment. Infor w ill provide an acceptance request to Licensee for each milestone w hich details the completed deliverables associated w ith the milestone. The Licensee project manager w ill approve or disapprove each milestone w ithin 5 business days of notification from Infor. If upon review , the Licensee project manager determines the milestone to be completed and acceptable, the Licensee project manager w ill respond in w riting w ithin the 5 business day period that the milestone has been accepted and Infor w ill submit the invoice for that milestone to the Licensee. If Licensee does not accept or reject the milestone in w riting w ithin 5 business days, the milestone w ill be deemed accepted and Infor w ill submit the invoice for that milestone to the Licensee. If the milestone is not completed or acceptable, the Licensee w ill document in w riting any material nonconformity in the deliverable, and submit these details to the Infor project lead w ithin the 5 business day period. If Infor agrees that a material non-conformity exists in such deliverable, Infor w ill promptly correct any such nonconformity and resubmit that deliverable to Licensee for a second 5 business
Sample 1

Related to Acceptance of Milestones

  • Acceptance of Work The completion of the Work shall be subject to acceptance by NYSERDA in writing of all deliverables as defined in Exhibit A, Statement of Work.

  • Acceptance of Purchase Order Contractor’s acceptance of CCI’s Purchase Order shall be accomplished by the earlier of execution of the Purchase Order or commencement of Services or shipment of any Product specified in the Purchase Order.

  • ACCEPTANCE OF NONCONFORMING WORK If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

  • Acceptance of AAU You will have accepted an AAU for an Offering if: (a) we receive your acceptance, prior to the time specified in the Invitation Wire for such Offering, by wire, telex, telecopy or electronic data transmission, or other written communication (any such communication being deemed “In Writing”) or orally (if promptly confirmed In Writing), in the manner specified in the Invitation Wire, of our invitation to participate in the Offering, or (b) notwithstanding that we did not send you an Invitation Wire or you have not otherwise responded In Writing to any such Wire, you: (i) agree (orally or by a Wire) to be named as an Underwriter in the relevant Underwriting Agreement executed by us as Manager, or (ii) receive and retain an economic benefit for participating in the Offering as an Underwriter. Your acceptance of the invitation to participate will cause such AAU to constitute a valid and binding contract between us. Your acceptance of the AAU as provided above or an Invitation Wire will also constitute acceptance by you of the terms of subsequent Wires to you relating to the Offering unless we receive In Writing, within the time and in the manner specified in such subsequent Wire, a notice from you to the effect that you do not accept the terms of such subsequent Wire, in which case you will be deemed to have elected not to participate in the Offering.

  • Acceptance of these Terms Your use of the Services constitutes your acceptance of this Agreement. This Agreement is subject to change from time to time. We will notify you of any material change via secure message through our online banking site or on our website(s) by providing a link to the revised Agreement or other acceptable manner of delivery. Your continued use of the Services will indicate your acceptance of the revised Agreement. Further, SECURITY BANK reserves the right, in its sole discretion, to change, modify, add, or remove portions from the Services. Your continued use of the Services will indicate your acceptance of any such changes to the Services.

  • Acceptance of the Work 19.1 No act of, or failure to act by, the Owner or the OWNER'S REPRESENTATIVE during the course of the Work, nor any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the Final Payment by the Owner to Contractor. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof. 19.2 Contractor agrees to guarantee all work under this Contract for a period of one year from the date of Final Payment by the Owner or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required under terms of Owner’s conditional acceptance of elements of the Work the Owner deems marginally substandard. If any unsatisfactory condition or damage develops within the time of this guarantee period due to materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the OWNER’S REPRESENTATIVE, then the Contractor shall, when notified by the Owner or OWNER’S REPRESENTATIVE, immediately place such guaranteed Work in a condition satisfactory to the Owner or OWNER’S REPRESENTATIVE. Such guarantee shall be in addition to any implied warranty under law or other manufacturer’s or product supplier’s warranty. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.

  • Acceptance of Purchase Orders Notwithstanding any contrary language in Buyer’s purchase order, each purchase order shall be subject to acceptance by an authorized employee of Seller and each transaction shall be governed exclusively by these Terms and Conditions of Sale (“Contract”), except if any specific terms have been expressly and mutually agreed by the parties and confirmed in Seller’s sale order acknowledgement of each purchase order. Such acceptance is expressly limited to these Terms and Conditions of Sale, and any additional or different terms proposed by Buyer are automatically rejected unless expressly agreed to in writing by Seller. No contract shall exist except as hereinabove provided.

  • Acceptance of the Terms of Use These terms of use are entered into by and between you and Tribal Convenience Store Association ("Company", "we" or "us"). The following terms and conditions (these "Terms of Use") govern your access to and use of the Company’s website, xxxx://xxx.xxxxxxxxxxxxx.xxx, including any content, functionality and services offered on or through the website (the "Website"), whether as a guest or a registered user. Please read the Terms of Use carefully before you start to use the Website. By using the Website or by clicking to accept or agree to the Terms of Use when this option is made available to you, you accept and agree to be bound and abide by these Terms of Use. If you do not want to agree to these Terms of Use, you must not access or use the Website. This Website is offered and available only to users who are 18 years of age or older, and reside in the United States or any of its territories or possessions. By using this Website, you represent and warrant that you are of legal age to form a binding contract with the Company and meet the foregoing eligibility requirements. If you do not meet all of these requirements, you must not access or use the Website.

  • Acceptance of Appointment; Standard of Performance Adviser accepts the appointment as discretionary portfolio manager and agrees to use its best professional judgment to make timely investment decisions for the Fund in accordance with the provisions of this Agreement.

  • Acceptance of Services Services furnished under this Contract are subject to acceptance by OSU. If OSU finds services furnished to be incomplete or not in compliance with the Contract, OSU, at its sole discretion, may either reject the services, require Contractor to correct any defects without charge, or negotiate with Contractor to reduce the price, whichever OSU deems appropriate under the circumstances. If Contractor is unable or refuses to cure any defects within a time deemed reasonable by OSU, OSU may reject the services and cancel the Contract in whole or in part.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!