Approval of Contractors. Tenant’s general contractor and primary subcontractors shall be subject to Landlord’s prior written approval (which approval shall not be unreasonably withheld, delayed or conditioned, including Landlord’s reasonable approval of the contractor’s bonding capability and Landlord’s lender’s review and approval of the contractor’s bonding capability), and Tenant shall submit to Landlord, no later than thirty (30) days after execution of this Lease, by notice given in the manner specified in the Lease, the following information: (i) the name and address of the general contractor and (as of a date 60 days before the commencement of the Tenant’s Work) all subcontractors which Xxxxxx proposes to engage for the performance of Xxxxxx’s Work; (ii) a fully completed Contractor’s Qualification Statement (AIA Document A305) for Xxxxxx’s proposed general contractor and each of Tenant’s proposed primary subcontractors; (iii) the construction cost breakdown and total cost for all portions of Tenant’s Work; (iv) the actual commencement date of construction and the estimated date of completion of Tenant’s Work, including fixturization; (v) evidence of insurance as required by Section 6; and (vi) Tenant’s contractor’s performance and/or labor and materials bonds, if required by Landlord’s lender. Landlord hereby preapproves Plant Construction Company, Xxxxxx Construction and BCCI. All contractors engaged by Xxxxxx shall employ only union labor and shall be bondable, licensed contractors, possessing good labor relations, capable of performing quality workmanship and working in harmony with Landlord’s construction manager and other contractors on the job.
Approval of Contractors. All general contractors or other contractors directly engaged by Tenant shall be subject to Landlord's advance reasonable approval. All contracts entered into directly by Tenant shall name Landlord as a third-party beneficiary. Copies of all such agreements shall be delivered to Landlord promptly upon execution thereof. All construction and consultants' reports delivered to Tenant relating to any construction matters shall also be delivered and addressed to Landlord.
Approval of Contractors. Contractors and subcontractors to be used in performing Tenant’s Work shall be approved by Landlord in writing before Tenant’s Work is commenced.
Approval of Contractors. Final selection by One University of a general contractor (“General Contractor”) and Major Subcontractors for the Scope shall be subject to the prior approval of the FCRHA, which approval shall not be unreasonably withheld, conditioned or delayed. A “Major Subcontractor” shall mean any subcontractor performing work the cost of which is in excess of ten percent (10%) of the total cost of constructing the Scope, as set forth in the Budget (as defined below). The bidding process and criteria are to be discussed.
Approval of Contractors. In doing any work related to the installation of Tenant's furnishings, fixtures, or equipment in the Premises or in making any alterations pursuant to Subparagraph B above, Tenant will use only contractors or workmen approved by Landlord, which approval shall not be unreasonably withheld or delayed. Tenant shall promptly remove any lien for material or labor claimed against the Premises by such contractors or workmen if such claim should arise and hereby indemnifies and holds Landlord harmless from and against any and all costs, expenses or liabilities incurred by Landlord as a result of such liens filed by contractors or workmen hired by Tenant or its agents.
Approval of Contractors. Tenant shall directly contract with all architects, engineers, consultants, contractors and subcontractors (collectively, “Tenant’s Contractors”) with respect to the design, construction and performance of Tenant’s Work. Tenant’s general contractor, mechanical contractor, electrical contractor, plumbing contractor and fire/life safety contractor shall be subject to Landlord’s prior review and written approval, which shall not be unreasonably withheld, conditioned or delayed. Tenant shall submit to Landlord, prior to the commencement of construction, the following information: (i) with respect to each of Tenant’s Contractors, the name of the company and primary contact person, complete with address, email, phone number and fax number (ii) the construction cost breakdown and total cost for all portions of Tenant’s Work; (iii) the commencement date of construction and the estimated date of completion of Tenant’s Work; and (iv) evidence of insurance as required by Section 8 below. Tenant acknowledges and agrees that Tenant must use union labor.
Approval of Contractors. (i) GENERAL STANDARD; PROHIBITED PERSONS. All Construction Work shall be performed and/or managed by one or more reputable and responsible general contractor(s) (or if Tenant, or any Subtenant, as the case may be, hires contractors instead of a general contractor, such contractors) or construction manager(s). No general contractor, construction manager, Major Contractor or other contractor that is engaged to do Construction Work shall be a Prohibited Person. Tenant shall cause such restriction to be inserted in each Sublease.
(ii) GENERAL CONTRACTOR(S) AND CONSTRUCTION MANAGER(S). Each general contractor and/or construction manager engaged in respect of Tenant's Construction Work shall be subject to the approval of Landlord. Landlord approves, on the date hereof, those general contractors and construction managers listed on EXHIBIT M attached hereto (it being understood that such approval of Landlord (A) is valid for a period ending on the earlier of (1) the date that is five (5) years after the date hereof and (2) the occurrence of any material change in the ownership of the applicable general contractor or construction manager, as the case may be and (B) is not an approval of any proposed general contractor construction manager's Prohibited Person status). Tenant shall deliver to Landlord and update as necessary from time to time upon request therefor, a list identifying to Landlord each general contractor and construction manager that is a member of the Development Team. Landlord shall have the right to disapprove any such general contractor or construction manager only: [a] if such general contractor or construction manager is a Prohibited Person; or [b] if such general contractor or construction manager, in Landlord's reasonable judgment, has demonstrated a failure, based on prior job performance, to exercise due care in the performance of the work for which such contractor may be hired in respect of the New Building (it being agreed that no Person listed on EXHIBIT M attached hereto may be disapproved by Landlord on the basis described in this clause (b) of this SECTION 6.1(e)(ii)). If Landlord fails to approve or reject any such general contractor or, construction manager within eleven (11) Business Days after the written submission to Landlord of such Person's name, address, phone number and EIN (as well as those Principals thereof) or Landlord fails to make reasonable requests for additional information related thereto within such time period and ...
Approval of Contractors. Any and all Alterations shall be made ----------------------- only by such contractors, mechanics or suppliers as are approved in writing in advance by Landlord. Approval of contractors, suppliers, or mechanics by Landlord, which approval may not be unreasonably withheld, conditioned or delayed, shall be based upon the contractors, supplier or mechanics being properly licensed, their financial posture, experience and past job performance. Any contractor employed shall be solely the contractor of Tenant and shall have no privity or relationship with Landlord. Tenant shall indemnify Landlord with regard to all activities of any contractor, mechanic or supplier employed by Tenant or through any such party employed by Tenant.
Approval of Contractors. Any contractor chosen by Tenant to perform the Tenant improvement work shall be subject to the prior approval of Landlord. Landlord agrees that it will not unreasonably withhold its approval of Tenant's contractor and will provide Tenant with specific reasons for the basis of any objection to Tenant's contractor. If Landlord does not respond to Tenant's request for approval within seven (7) business days of Landlord's receipt of Tenant's proposed contractor, then Tenant may give to Landlord a written notice stating the failure of Landlord to respond to the prior request and further stating that if Landlord does not respond to such request within three (3) business days from the receipt by Landlord of such second notice, then Tenant's proposed contractor will be deemed approved. If Landlord does not respond to such request within three (3) business days from the receipt by Landlord of such second notice, then Tenant's proposed contractor shall be deemed approved. Tenant shall have the right to submit a list of not more than six (6) proposed contractors to Landlord for Landlord's approval in accordance with the procedures outlined in this paragraph 6.(c).
Approval of Contractors. Any contractor used by the Lessee to perform its work under Exhibit "C" "Lessee's Work Done at Lessee's Expense", must first be approved in writing by Lessor. Lessor approves of American Building Group as the Lessee's contractor.
