ARCHAEOLOGICAL FINDS Sample Clauses

ARCHAEOLOGICAL FINDS. The Owner AGREES that it, or its agents, builders or contractors shall immediately cease work and notify the Ministry of Tourism, Culture and Sport, of any discovery of any archaeological resources, including but not limited to artifacts or burials, during development and housing construction. The Owner further AGREES that if during construction any archaeological or cultural heritage resources (including human remains) are found, that all work shall cease and the Ministry of Tourism, Culture and Sport be notified and only commenced with the Ministry’s concurrence.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
ARCHAEOLOGICAL FINDS. The Site is located on an archeological sensitive area. If Licensee discovers any artifacts during excavation and/or construction, Licensee shall stop all affected work and notify Trustees. Trustees will employ, at Trustees’ cost and expense, the services of a Native American monitor and archeologist to be present whenever excavation of the Site occurs at any depth. Licensee is responsible to notify Trustees in advance of any digging or excavation so these monitors can be scheduled. If Licensee discovers human remains, Licensee shall notify Trustees who will be responsible for contacting the county coroner and a qualified archaeologist. Licensee shall be entitled to a day-for-day extension pursuant to Section 8.6 for any impact on schedule due to any delays or stoppage of installation work pursuant to this Section 8.16.] Applicable only on certain campuses.‌
Sample 1Sample 2See All (4)
ARCHAEOLOGICAL FINDS. Valuable minerals, fossils, articles or objects of antiquity or of anthropological or archaeological (including indigenous) interest and articles of value found on the Site shall as between the parties be and remain the property of Total. Immediately upon the discovery of these things the Sub-Contractor must: a. take precautions to prevent their loss, removal or damage; b. give Total immediate notice of the discovery; c. comply with any directions of the Superintendent or relevant authority; and d. (to the extent possible), continue to perform its obligations under the Sub-Contract.
Sample 1Sample 2Sample 3
ARCHAEOLOGICAL FINDS. .01 If the Contractor's operations expose any items that may indicate an archaeological find, such as building remains, hardware, accumulations of bones, pottery, or arrowheads, the Contractor shall immediately notify the Contract Administrator and suspend operations within the area identified by the Contract Administrator. Notification may be verbal provided that such notice is confirmed in writing within 2 Days. Work shall remain suspended within that area until otherwise directed by the Contract Administrator in writing, in accordance with clause GC 7.10, Suspension of Work. .02 Any delay in the completion of the Contract that is caused by such a suspension of Work shall be considered to be an event entitling the Contractor to request payment for the cost of such delays in accordance with clause GC 3.07.01. .03 Any Work directed or authorized in connection with an archaeological find shall be considered as Extra Work in accordance with clause GC 3.10.02,
Sample 1
ARCHAEOLOGICAL FINDS. During the life of this Contract the Contractor is herewith required to immediately notify the following organizations in the event that any articles such as "charcoal," "bone," "shell," "cultural objects - fire cracked stones or stone flaking material" or any other such related items of historical significance are discovered: a) City by Title (Mayor, Director of Public Utilities, etc.); b) Local Historical Society by Official name; and c) State Historic Preservation Office Xxxxxxxxx Xxxxxxx, Staff Archaeologist Xxx Xxxxxxxxxxxx Xxxxx, 0xx Xxxxx Xxxxxxxx, Xxxxxxxxxxx 00000 000-000-0000
Sample 1
ARCHAEOLOGICAL FINDS. If the Licensee discovers any artifacts during excavation and/or construction, the Licensee shall stop all affected Work and notify the Trustees, who will call in a qualified archaeologist designated by the California Archaeological Inventory to assess the discovery and suggest further mitigation, as necessary. If the Licensee discovers human remains, the Licensee shall notify the Trustees who will be responsible for contacting the county coroner and a qualified archaeologist. If the remains are determined to be Native American, the Trustees shall contact the appropriate tribal representatives to oversee removal of the remains.
Sample 1
ARCHAEOLOGICAL FINDS. If the Service Provider discovers any artifacts during excavation and/or construction, the Service Provider shall stop all affected work and notify the Corporation, who will call in a qualified archaeologist designated by the California Archaeological Inventory to assess the discovery and suggest further mitigation, as necessary. If the Service Provider discovers human remains, the Service Provider shall notify the Corporation who will be responsible for contacting the county coroner and a qualified archaeologist. If the remains are determined to be Native American, the Corporation shall contact the appropriate tribal representatives to oversee removal of the remains.
Sample 1
AutoNDA by SimpleDocs
ARCHAEOLOGICAL FINDS. If Contractor discovers any artifacts during excavation and/or construction, Contractor shall stop all affected work and notify the CSU, who will call in a qualified archaeologist designated by the California Archaeological Inventory to assess the discovery and suggest further mitigation, as necessary. If Contractor discovers human remains, Contractor shall notify the CSU who will be responsible for contacting the county coroner and a qualified archaeologist. If the remains are determined to be Native American, the CSU shall contact the appropriate tribal representatives to oversee removal of the remains.
Sample 1
ARCHAEOLOGICAL FINDS. If the Licensee discovers any artifacts during excavation and/or construction, the Licensee shall stop all affected Work and notify the Trustees, who will call in a qualified archaeologist designated by the California Archaeological Inventory to assess the discovery and suggest further mitigation, as necessary.
Sample 1

Related to ARCHAEOLOGICAL FINDS

  • Geological and archaeological finds It is expressly agreed that mining, geological or archaeological rights do not form part of this Agreement with the Contractor for the Works, and the Contractor hereby acknowledges that it shall not have any mining rights or interest in the underlying minerals, fossils, antiquities, structures or other remnants or things either of particular geological or archaeological interest and that such rights, interest and property on or under the Site shall vest in and belong to the Authority or the concerned Government Instrumentality. The Contractor shall take all reasonable precautions to prevent its workmen or any other person from removing or damaging such interest or property and shall inform the Authority forthwith of the discovery thereof and comply with such instructions as the concerned Government Instrumentality may reasonably give for the removal of such property. For the avoidance of doubt, it is agreed that any reasonable expenses incurred by the Contractor hereunder shall be reimbursed by the Authority. It is also agreed that the Authority shall procure that the instructions hereunder are issued by the concerned Government Instrumentality within a reasonable period.

  • Geographic Scope The "Territory," which defines the geographic scope of the covenants contained in this Section 7, shall extend to and include all of the states (or foreign equivalent) in which the Company does business as M&A advisors or private placement equity advisors.

  • Proprietary Information and Developments 9.1 The Consultant will not at any time, whether during or after the termination of this Agreement for any reason, reveal to any person or entity any of the trade secrets or confidential information concerning the organization, business or finances of the Company or of any third party which the Company is under an obligation to keep confidential, except as may be required in the ordinary course of performing the Consultant Services to the Company, and the Consultant shall keep secret such trade secrets and confidential information and shall not use or attempt to use any such secrets or information in any manner which is designed to injure or cause loss to the Company. Trade secrets or confidential information shall include, but not be limited to, the Company's financial statements and projections, expansion proposals, property acquisition opportunities and business relationships with banks, lenders and other parties not otherwise publicly available.

  • Physical Fitness New Employees. New employees are required to file a medical examination report with the Director of Health Services before reporting for duty in the Des Moines schools. The employee must pay the cost of this examination given by a physician of his/her choice and reported on the form provided by the Employer.

  • ODUF Physical File Characteristics 6.2.1 ODUF will be distributed to TWTC via Secure File Transfer Protocol (FTP). The ODUF feed will be a variable block format. The data on the ODUF feed will be in a non-compacted EMI format (175 byte format plus modules). It will be created on a daily basis Monday through Friday except holidays. Details such as dataset name and delivery schedule will be addressed during negotiations of the distribution medium. There will be a maximum of one dataset per workday per OCN. If AT&T determines the Secure FTP Mailbox is nearing capacity levels, AT&T may move the customer to CONNECT: Direct file delivery. 6.2.2 If the customer is moved, CONNECT: Direct data circuits (private line or dial-up) will be required between AT&T and TWTC for the purpose of data transmission. Where a dedicated line is required, TWTC will be responsible for ordering the circuit, overseeing its installation and coordinating the installation with AT&T. TWTC will also be responsible for any charges associated with this line. Equipment required on the AT&T end to attach the line to the mainframe computer and to transmit messages successfully on an ongoing basis will be negotiated on an individual case basis. Any costs incurred for such equipment will be TWTC's responsibility. Where a dial-up facility is required, dial circuits will be installed in the AT&T data center by AT&T and the associated charges assessed to TWTC. Additionally, all message toll charges associated with the use of the dial circuit by TWTC will be the responsibility of TWTC. Associated equipment on the AT&T end, including a modem, will be negotiated on an individual case basis between the Parties. All equipment, including modems and software, that is required on TWTC end for the purpose of data transmission will be the responsibility of TWTC. 6.2.3 If TWTC utilizes FTP for data file transmission, purchase of the FTP software will be the responsibility of TWTC.

  • Research Independence The Company acknowledges that each Underwriter’s research analysts and research departments, if any, are required to be independent from their respective investment banking divisions and are subject to certain regulations and internal policies, and that such Underwriter’s research analysts may hold and make statements or investment recommendations and/or publish research reports with respect to the Company and/or the offering that differ from the views of its investment bankers. The Company hereby waives and releases, to the fullest extent permitted by law, any claims that the Company may have against such Underwriter with respect to any conflict of interest that may arise from the fact that the views expressed by their independent research analysts and research departments may be different from or inconsistent with the views or advice communicated to the Company by such Underwriter’s investment banking divisions. The Company acknowledges that the Representative is a full service securities firm and as such from time to time, subject to applicable securities laws, may effect transactions for its own account or the account of its customers and hold long or short position in debt or equity securities of the Company.

  • Developments I will make full and prompt disclosure to the Company of all inventions, discoveries, designs, developments, methods, modifications, improvements, processes, algorithms, databases, computer programs, formulae, techniques, trade secrets, graphics or images, and audio or visual works and other works of authorship related to the business of the Company (collectively “Developments”), whether or not patentable or copyrightable, that are created, made, conceived or reduced to practice by me (alone or jointly with others) or under my direction during the period of my employment. I acknowledge that all work performed by me for the Company is on a “work for hire” basis, and I hereby do assign and transfer and, to the extent any such assignment cannot be made at present, will assign and transfer, to the Company and its successors and assigns all my right, title and interest in all Developments made, conceived or reduced to practice by me (alone or jointly with others) that (a) relate to the business of the Company or any customer of or supplier to the Company or any of the products or services being researched, developed, manufactured or sold by the Company or which may be used with such products or services; or (b) result from tasks assigned to me by the Company; or (c) result from the use of premises or personal property (whether tangible or intangible) owned, leased or contracted for by the Company (“Company-Related Developments”), and all related patents, patent applications, trademarks and trademark applications, copyrights and copyright applications, and other intellectual property rights in all countries and territories worldwide and under any international conventions (“Intellectual Property Rights”). To preclude any possible uncertainty, I have set forth on Exhibit 1 attached hereto a complete list of Developments that I have, alone or jointly with others, conceived, developed or reduced to practice prior to the commencement of my employment with the Company that I consider to be my property or the property of third parties and that I wish to have excluded from the scope of this Agreement (“Prior Inventions”). If disclosure of any such Prior Invention would cause me to violate any prior confidentiality agreement, I understand that I am not to list such Prior Inventions in Exhibit 1 but am only to disclose a cursory name for each such invention, a listing of the party(ies) to whom it belongs and the fact that full disclosure as to such inventions has not been made for that reason. I have also listed on Exhibit A all patents and patent applications in which I am named as an inventor, other than those which have been assigned to the Company (“Other Patent Rights”). If no such disclosure is attached, I represent that there are no Prior Inventions or Other Patent Rights. If, in the course of my employment with the Company, I incorporate a Prior Invention into a Company product, process or machine or other work done for the Company, I hereby grant to the Company a nonexclusive, royalty-free, paid-up, irrevocable, worldwide license (with the full right to sublicense) to make, have made, modify, use, sell, offer for sale and import such Prior Invention. Notwithstanding the foregoing, I will not incorporate, or permit to be incorporated, Prior Inventions in any Company-Related Development without the Company’s prior written consent. This Agreement does not obligate me to assign to the Company any Development which, in the sole judgment of the Company, reasonably exercised, is developed entirely on my own time and does not relate to the business efforts or research and development efforts in which, during the period of my employment, the Company actually is engaged or reasonably would be engaged, and does not result from the use of premises or equipment owned or leased by the Company. However, I will also promptly disclose to the Company any such Developments for the purpose of determining whether they qualify for such exclusion. I understand that to the extent this Agreement is required to be construed in accordance with the laws of any state which precludes a requirement in an employee agreement to assign certain classes of inventions made by an employee, this paragraph 5 will be interpreted not to apply to any invention which a court rules and/or the Company agrees falls within such classes. I also hereby waive all claims to any moral rights or other special rights which I may have or accrue in any Company-Related Developments.

  • Geographic Area See Articles 70.1-70.5.

  • TECHNOLOGY/KNOWLEDGE TRANSFER ACTIVITIES The goal of this task is to develop a plan to make the knowledge gained, experimental results, and lessons learned available to the public and key decision makers. • Prepare an Initial Fact Sheet at start of the project that describes the project. Use the format provided by the CAM. • Prepare a Final Project Fact Sheet at the project’s conclusion that discusses results. Use the format provided by the CAM. • Prepare a Technology/Knowledge Transfer Plan that includes: o An explanation of how the knowledge gained from the project will be made available to the public, including the targeted market sector and potential outreach to end users, utilities, regulatory agencies, and others. o A description of the intended use(s) for and users of the project results. o Published documents, including date, title, and periodical name. o Copies of documents, fact sheets, journal articles, press releases, and other documents prepared for public dissemination. These documents must include the Legal Notice required in the terms and conditions. Indicate where and when the documents were disseminated. o A discussion of policy development. State if project has been or will be cited in government policy publications, or used to inform regulatory bodies. o The number of website downloads or public requests for project results. o Additional areas as determined by the CAM. • Conduct technology transfer activities in accordance with the Technology/Knowledge Transfer Plan. These activities will be reported in the Progress Reports. • When directed by the CAM, develop Presentation Materials for an Energy Commission- sponsored conference/workshop(s) on the project. • When directed by the CAM, participate in annual EPIC symposium(s) sponsored by the California Energy Commission. • Provide at least (6) six High Quality Digital Photographs (minimum resolution of 1300x500 pixels in landscape ratio) of pre and post technology installation at the project sites or related project photographs. • Prepare a Technology/Knowledge Transfer Report on technology transfer activities conducted during the project. • Initial Fact Sheet (draft and final) • Final Project Fact Sheet (draft and final) • Presentation Materials (draft and final) • High Quality Digital Photographs • Technology/Knowledge Transfer Plan (draft and final) • Technology/Knowledge Transfer Report (draft and final)

  • Hazardous Wastes In the event that the Mortgaged Property, related to a Mortgage Loan which is being considered for liquidation by foreclosure or the transfer of a deed-in-lieu of foreclosure, contains, and the Servicer has reason to believe that it contains, hazardous or regulated substances which may impose liability, for damages, remediation or otherwise, upon the owner of such Mortgaged Property pursuant to Federal, State or local law, the Servicer shall not, except with the express prior written approval of the Master Servicer, which approval makes specific reference to the presence of such hazardous or regulated substances, undertake or continue the process of foreclosure with respect to such Mortgaged Property.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!