Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:
Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include: Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration. The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback. At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance. Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter:
Third Schedule MINERAL LEASE Lease No Goldfield(s) XXXXXXXXX THE SECOND by the Grace of God of the United Kingdom, Australia and Her other Realms and Territories Queen, Head of the Commonwealth, Defender of the Faith: TO ALL TO WHOM THESE PRESENTS shall come GREETINGS: KNOW YE that WHEREAS by an Agreement made the day of 1968 between the State of Western Australia of the one part and HAMERSLEY IRON PTY. LIMITED (hereinafter called “the Company” which expression will include the successors and assigns of the company including where the context so admits the assignees of the Company under the said Agreement) of the other part the said State agreed to grant to the Company a mineral lease of portion or portions of the lands referred to in the said Agreement as “the mining areas” AND WHEREAS the said Agreement was ratified by the Act 196 which said Act (inter alia) authorized the grant of a mineral lease to the Company NOW WE in consideration of the rents and royalties reserved by and of the provisions of the said Agreement and in pursuance of the said Act DO BY THESE PRESENTS GRANT AND DEMISE unto the Company subject to the said provisions ALL THOSE pieces and parcels of land situated in the Goldfield(s) containing approximately acres and (subject to such corrections as may be necessary to accord with survey when made) being the land shaded pink on the plan in the Schedule hereto and all those mines, veins, seams, lodes and deposits of iron ore in on or under the said land (hereinafter called “the said mine”) together with all rights, liberties, easements, advantages and appurtenances thereto belonging or appertaining to a lessee of a mineral lease under the Mining Xxx 0000 including all amendments thereof for the time being in force and all regulations made thereunder for the time being in force (which Act and regulations are hereinafter referred to as “the Mining Act”) or to which the Company is entitled under the said Agreement TO HOLD the said land and mine and all and singular the premises hereby demised for the full term of twenty-one years from the day of 19 with the right to renew the same from time to time for further periods each of twenty-one years as provided in but subject to the said Agreement for the purposes but upon and subject to the terms covenants and conditions set out in the said Agreement and to the Mining Act (as modified Third Schedule by the said Agreement) YIELDING and paying therefor the rent and royalties as set out in the said Agreement. AND WE do hereby declare that this lease is subject to the observance and performance by the Company of the following covenants and conditions, that is to say: —
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
Amortization Schedule We do not provide an initial amortization schedule at the time of project agreement release but maintain a "Loan Summary Spreadsheet" on our website on the Financial Tab under "Loans". Once your loan is put into billing an amortization schedule will be posted to the same website, with a copy mailed to the Chief Financial Officer the month following project closeout.
Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.
Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.
