Change of Contract Time. The Contract Time may only be changed by a Change Order (EADOC Software). Any claim for an extension in the Contract Time shall be in writing and delivered to the AE within fifteen (15) calendar days of the occurrence of the event giving rise to the claim and stating general nature of the claim. Notice of the extent of the claim with supporting data (analysis and documentation) shall be delivered within sixty (60) calendar days after such occurrence (unless the AE allows an additional period of time to ascertain in more accurate data in support of the claim) and shall be accompanied by the CM's written statement that the adjustment claim is the entire adjustment to which the CM has reason to believe it is entitle as a result of the occurrence of said event. If adverse weather conditions are the basis for a claim for additional time, such claim shall be documented by data substantiating that weather conditions were abnormal for the period of time and could not have been reasonably anticipated, and that the weather conditions had an adverse effect on the scheduled construction. No claim by the CM under this provision shall be allowed unless the CM has given the notice and the analysis and documentation required in this paragraph. All claims for adjustment in the Contract Time resulting from any such claim shall be incorporated in a Change Order. The Owner shall not be responsible for any delay in the completion of the PROJECT where the delay is beyond the control or without fault or negligence on behalf of the Owner. The Owner shall not be held accountable for extra compensation or an extension of time due to default by the CM, subcontractors, or suppliers in the furnishing of labor or materials for the PROJECT, or having to replace defective materials. The CM shall be entitled to a claim for an extension of time when a delay or hindrance is caused by an act of God, or any act or omission on the part of the Owner, provided the CM gives notice to the AE within fifteen (15) calendar days of the occurrence of the event giving rise to the claim and having stated the general nature of the claim. The CM's sole remedy shall be an extension of Contract Time. No extension of Contract Time or increases in Guaranteed Maximum Price (GMP) shall be granted for any delay caused either by (1) inadequate crewing, default or bankruptcy of lower tier contract, slow submittals, etc., or (2) by severe though not unusual weather conditions (other than hurricanes and tornadoes) or
Change of Contract Time. 16.1 The "Contract Time" may only be changed by a Change Order. Any claim for an extension of the "Contract Time" shall be based on written notice delivered by the party making the claim to the CITY ENGINEER and the City’s Project Manager within 7 calendar days of the beginning of the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within 15 days after the end of such occurrence (unless the CITY allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the "Contract Time" shall be determined by the CITY ENGINEER in accordance with paragraph 16.2, if CITY and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the "Contract Time" will be valid if not submitted in accordance with the requirements of this paragraph.
16.2 The CITY ENGINEER and/or City’s Project Manager must submit the request of an extension of the “Contract Time” with the written information provided by the CONTRACTOR and with a written explanation as to why the extension shall be allowed to the City Manager for approval. If the City Manager approves the request, the "Contract Time" will be extended in an amount equal to time lost due to delays beyond the control of and through no fault or negligence of the CONTRACTOR. Such delays shall include, but not limited to, acts or neglect by CITY or the CITY ENGINEER, or by any employee of either, or any separate contractor employed by the CITY, fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God.
Change of Contract Time. A. The Contract Time may only be changed by a Change Order.
B. No extension of the Contract Time will be allowed for Extra Work or for claimed delay unless the Extra Work contemplated or claimed delay is shown to be on the critical path of the Project Schedule or Contractor can show by Critical Path Method analysis how the Extra Work or claimed delay adversely affects the critical path.
Change of Contract Time. 11.1 The Contract Time may only be changed by a Change Order. Any claim for an extension in the Contract Time shall be based on written notice delivered to OWNER and PROJECT MANAGER within fifteen days of the occurrence of the event-giving rise to the claim. Notice of the extent of the claim with supporting data shall be delivered within forty-five (45) days of such occurrence unless PROJECT MANAGER allows an additional period to ascertain additional accurate data. PROJECT MANAGER shall determine all claims for adjustment in the Contract Time if OWNER and CONTRACTOR cannot otherwise agree. Any change in the Contract Time resulting from any such claim shall be incorporated in a Change Order.
11.2 The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CONTRACTOR if a claim is made therefore as provided in Article 11.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others performing additional Work as contemplated by Article 6, or to fires, floods, labor disputes, epidemics, abnormal weather conditions, or acts of God. The CONTRACTOR shall be granted time extensions to the Contract for a period longer than the number of days indicated by month in the table below if rainfall on a given day (measured at a rain gauge site as determined by the Project Manager) is in excess of 1.0 inch and/or site conditions will not permit work on day(s) following a rain in excess of 1.0 inch. Inclement weather and flooding shall not be counted for delays unless Work is scheduled in advance as verified by the PROJECT MANAGER and a legitimate effort is made by the CONTRACTOR to perform that Work. January 2 July 3 February 2 August 4 March 2 September 4 April 4 October 4 May 5 November 4 June 4 December 2 The CONTRACTOR shall furnish all data and analysis to the PROJECT MANAGER to substantiate a claim for Contract time extension on a month-to-month basis with the CONTRACTORS monthly progress payment request. The CONTRACTOR shall not be entitled to any additional monetary consideration for granted time extensions or reimbursement for damages or hindrances because of heavy rainfall or flooding.
11.3 All time limits stated in the Contract Documents are of the essence of the Agreement.
Change of Contract Time. All time limits stated in this Contract are of the essence. Contract Time will be changed only by a Change Order. Any extension in Contract Time will be based on written notice delivered to the City within 15 days of the occurrence of the event precipitating the request. The Design-Builder shall deliver a work progress schedule analysis or summary justifying the time extension within 30 days of such occurrence. Failure to deliver any documentation to the City within the time limits specified above will completely foreclose consideration of an extension of Contract Time and all rights and remedies arising therefrom.
Change of Contract Time. 10.6.1 The Contract Time may only be changed by a Change Order. Any request for an extension in the Contract Time shall be made in writing and delivered to the Project Manager within ten (10) days of the occurrence first happening and resulting in the claim. Written supporting data will be submitted to the Project Manager within twenty (20) days after such occurrence unless the Project Manager allows additional time. All claims submitted by the DESIGN-BUILDER for adjustments to the Contract Time must set forth in detail the reasons for and causes of the delay; clearly demonstrate that the delay will impact the Critical Path; and indicate why the subject delay was beyond the DESIGN- BUILDER’S control or fault.
10.6.2 If the DESIGN-BUILDER is delayed at any time in the performance, progress, commencement, or completion of the Work by any act or neglect of the CITY or by any of its employees, or by any separate entity employed by the CITY, or by changes ordered in the Work, or by Acts of God, fire, utility conflicts which could not have been identified or foreseen by the DESIGN-BUILDER using reasonable diligence, or other causes beyond the DESIGN-BUILDER’s reasonable control, then the Contract Time shall be extended by Change Order for such reasonable time as the CITY may determine. DESIGN-BUILDER shall be entitled to an extension of time for such causes only for the number of days of delay which the DESIGN-BUILDER demonstrates to be due to such causes and only to the extent such occurrences actually impact the critical path and consequently delay the completion of the Project. Provided, however, notwithstanding anything in the Contract to the contrary, no interruption, interference, inefficiency, suspension or delay in the performance, progress, commencement or completion of the Work for any cause whatsoever, including those for which the CITY may be responsible in whole or in part, shall relieve DESIGN-BUILDER of its duty to perform the Work under the Contract, or give rise to any right to damages from the CITY. DESIGN-BUILDER shall be entitled to an extension of time and/or reasonable additional compensation as agreed upon by the DESIGN-BUILDER and the CITY related to any delay caused by other contractors not under the authority and control of the DESIGN-BUILDER or any delay caused by the CITY. The above paragraph shall expressly apply to claims based on early completion, as well as claims based upon late completion. The DESIGN-BUILDER shall not have the r...
Change of Contract Time. 1 The Contract Time may only be changed by a Change Order. If the Designer/Builder is entitled by the Contract Documents to make a claim for an extension in the Contract Time, its claim shall be in writing delivered to the Owner and ENGINEER within 10 days of the occurrence of the event that gives rise to the claim. The Owner shall determine all claims for adjustment in the Contract Time. Any change in the Contract Time resulting from any such claim shall be incorporated in a Change Order.
Change of Contract Time. 10.6.1 The Contract Time may only be changed by a Change Order. Any request for an extension in the Contract Time shall be made in writing and delivered to the Project Manager within ten
Change of Contract Time. 12.1 The Contract Time may only be changed by a Change Order or a Written Amendment. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to the other party and to Engineer promptly (but in no event later than thirty (30) days after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within sixty days after such occurrence (unless Engineer allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant’s written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by Engineer in accordance with paragraph 9.11 if Town and Contractor cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1.
Change of Contract Time. 12.1. The Contract Time may only be changed by a Change Order or a Written Amendment. Any claim for an extension or shortening of the Contract Time shall be based on written notice in accordance with Article
11.2. All claims for adjustment in the Contract Time shall be determined by Architect/Engineer in accordance with paragraph 9.11, if Owner and Contractor cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid, and will be deemed waived, if not submitted in accordance with the requirements of this paragraph 12.1.
