Early Completion definition

Early Completion. At any point prior to the Client’s deadline, Client may end the project, at which point the project will be considered completed and no further work will be done or paid for, but all work done up to that point will be transferred and paid for, per the Completion clause above. If a phase of the Work has not yet been approved by the Client at the time at which the project is ended, Client will pay on pro-rated basis for the part of the work that has been done. Revisions: Client may request up to [amount] revisions to the Work without additional fees, provided that such revisions do not require work exceeding the Scope of Work as defined in this Agreement. Contractor may decline, or charge additionally for, work that Contractor reasonably deems to be beyond the Scope of Work. Client Responsibilities: Client agrees to provide Contractor with text and images (copy, etc.) needed for the Work to be completed on time and to Client’s satisfaction. Rights: Rights, including copyright, ownership, and publishing rights, to this Work belong to the Contractor until the completion of the project and the transfer of payment, at which point they will transfer to the Client. Contractor can showcase sample works from this project as portfolio pieces only with consent and approval from Client.
Sample 1
Early Completion. Bonus is defined in Section 6.5.4. Effective Date is defined in the Preamble. Final Application for Payment is defined in Section 10.3. Final Completion is defined in Section 6.6.2. Final Completion Date is the date that is 90 Days after the Substantial Completion Date. Final Payment is defined in Section 10.3.
Sample 1
Early Completion. Bonus is defined in Section 6.4.4. Effective Date is defined in the Preamble. Expansion Plant is defined in the Recitals. Expansion Project is defined in Section 2.1. Expansion Project Scope is defined in Exhibit X. Xxxxx Engineering is defined in Section 6.1. Final Application for Payment is defined in Section 10.3. Final Completion is defined in Section 6.5.2. Final Completion Date is defined in Section 6.5.1. Final Payment is defined in Section 10.3.
Sample 1

Examples of Early Completion in a sentence

  • Any action under Clause 47 “Liquidated Damages for Delay” or Payment of Bonus for Early Completion of Works (PCC Sub-Clause 47.3).

  • The Owner shall not be obligated to accept any Early Completion Schedule suggested by the Contractor.

  • Incentive for Early Completion When Contract can be DeterminedCLAUSE 2A -DELETEDIn case, the contractor completes the work ahead of stipulated date of completion or justified extended date of completion as determined under clauses 5.3, 12 & 15, a bonus @ 1% (one per cent) of the tendered value per month computed on per day basis, shall be payable to the contractor, subject to a maximum limit of 5% (five per cent) of the tendered value.

  • In the event that an Early Completion Schedule is accepted, the Engineer will initiate a change order amending the Completion Date to the finish date shown on the accepted Early Completion Schedule.

  • An Early Completion Monthly Update Schedule is defined as a monthly update schedule submitted by the Contractor in which the Finish Date precedes the Contract Completion Date.

  • An Early Completion Schedule is defined as a baseline schedule or update schedule which anticipates completion of all work prior to the Completion Date established by the contract documents and the Contractor submits as an Early Completion Schedule.

  • Early Completion Time.—The difference in time between the contract completion date and the current State- accepted scheduled completion date.

  • The Contractor may elect not to execute the change order amending the Completion Date; however, in so doing, the Contractor waives its rights to delay damages in meeting the projected early Completion Date and the time between the Early Completion Date and the Contract Completion Date is used as Project Float.

  • Contractor shall prepare its schedule to include, at a minimum, the following Schedule Milestones: Contractual Start (defined by the Effective Date of the Contract), Substantial Completion, Certificate of Occupancy, Princeton University’s “Move-In” process, Early Completion date (if one is proposed).

  • If after incorporating necessary revisions in accordance with Section F, the Finish Date precedes the Contract Completion Date by at least the number of days shown Table A the Engineer will initiate a change order amending the Contract Completion Date to the Early Completion Date shown on the accepted Early Completion Monthly Update.


More Definitions of Early Completion

Early Completion means that all of the following have occurred with respect to the Facility: (i) Cool Down has been completed for System 1 and System 2; (ii) Contractor has completed all procurement, fabrication, assembly, erection, installation and precommissioning checks of all of the vaporizers for the Facility to ensure that all such vaporizers and each component thereof was sufficiently fabricated, assembled, erected and installed so as to be capable of being operated safely within the requirements contained in this Agreement, and thirteen vaporizers have been operated to their rated capacity; (iii) Contractor has completed all procurement, fabrication, assembly, erection, installation and pre-commissioning checks and tests of System 1 and System 2 to ensure that these Systems and each component thereof was sufficiently fabricated, assembled, erected and installed so as to be capable of being operated safely within the requirements contained in this Agreement; and (iv) System 1 and System 2, collectively, are capable of a Sendout Rate of 2,000 MMSCFD or above at a temperature of no less than 40°F and at a pressure of no less than 1,440 PSIG, as measured at the exit for the main Facility transfer meter. The status of being “capable” shall be determined by such tests or operational records as may be mutually agreed by the Parties prior to Contractor’s achievement of Early Completion.
Sample 1

Related to Early Completion

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Final Completion Date means the date on which Final Completion occurs.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.

  • Quarterly Commencement Date means the 1st day of each of April, July, October and January in each year.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.