CHANGES AND CHANGED CONDITIONS Sample Clauses

CHANGES AND CHANGED CONDITIONS. A. If, during the course of the work herein contemplated, the need to change the Scope of Work or the Work Schedule should arise, for whatever reasons, whichever party first identifies such need to change shall notify the other party in writing. The representatives of the parties shall meet within seven (7) working days of the date of such notice to discuss the need for change so identified and to set the proposed action to be taken by the parties. A change in the Scope of Work may also result in a change in the compensation amount. Compensation changes shall be based upon the Consultant Budget and Fee Schedule (Exhibit C) attached hereto. Any changes agreed to shall be documented by duly executed amendments to this Agreement. B. MPWMD reserves the right to specify individual employees, subcontractors or agents of Consultant who shall be assigned to perform the tasks specified in Exhibit A, Scope of Services. If, during the course of the work herein contemplated, there is a change such that the specified individual employees, subcontractors or agents are no longer assigned to the work described in this contract and/or are no longer affiliated with Consultant, Consultant shall immediately notify MPWMD in writing. Consultant shall assign the rights to this contract to another entity, if requested by MPWMD, as part of termination proceedings pursuant to Section IX, Termination.
Sample 1Sample 2Sample 3See All (18)
AutoNDA by SimpleDocs
CHANGES AND CHANGED CONDITIONS. A. If, during the course of the work herein contemplated, the need to change the Scope of Work or the Work Schedule should arise, for whatever reasons, whichever party first identifies such need to change shall notify the other party in writing. The representatives of the parties shall meet within seven (7) working days of the date of such notice to discuss the need for change so identified and to set the proposed action to be taken by the parties. A change in the Scope of Work may also result in a change in the compensation amount. Compensation changes shall be based upon the Consultant Budget and Fee Schedule (Exhibit B) attached hereto. Any changes agreed to shall be documented by duly executed amendments to this Agreement. B. MPWMD reserves the right to specify individual employees, subcontractors or agents of Consultant who shall be assigned to perform the tasks specified in Exhibit A, Scope of
Sample 1Sample 2
CHANGES AND CHANGED CONDITIONS. (a) The Contracting Officer may, in writing, order changes in the drawings and specifications within the general scope of the contract. (b) The Contractor shall promptly notify the Contracting Officer, in writing, of subsurface or latent physical conditions differing materially from those indicated in this contract or unknown unusual physical conditions at the site before proceeding with the work. (c) If changes under paragraph (a) or conditions under paragraph (b) increase or decrease the cost of, or time required for performing the work, the Contracting Officer shall make an equitable adjustment (see paragraph (d)) upon submittal of a "proposal for adjustment" (hereafter referred to as proposal) by the Contractor before final payment under the contract. (d) THE CONTRACTING OFFICER SHALL NOT MAKE AN EQUITABLE ADJUSTMENT UNDER PARAGRAPH (B) UNLESS-- (1) The Contractor has submitted and the Contracting Officer has received the required written notice; or (2) The Contracting Officer waives the requirement for the written notice. (e) Failure to agree to any adjustment shall be a dispute under the Disputes clause.
Sample 1
CHANGES AND CHANGED CONDITIONS. If, during the course of the work herein contemplated, the need to change the Project Work Plan or the time schedule should arise, for whatever reasons, whichever party first identifies such need to change shall notify the other party in writing. The representatives of the parties shall meet within seven (7) working days of the date of such notice, to discuss the need for change so identified and to set the proposed action to be taken by the parties. A change in the Project Work Plan may also result in a change in the compensation amount. Any changes to the Work Plan or Budget for the Project shall be documented by duly executed amendments to this Agreement and to Exhibit A, State Grant Agreement.
Sample 1
CHANGES AND CHANGED CONDITIONS. A change in the Tasks identified in Exhibit A may, subject to CalAm's express written approval, also result in a change in the reimbursement amount. Reimbursement changes shall be based upon the District's fee schedule. Any change agreed to shall be documented by duly executed amendments to this Agreement or other written means acceptable to both parties.
Sample 1
CHANGES AND CHANGED CONDITIONS. (APRIL 1996) (a) The Contracting Officer may, in writing, order changes in the drawings and specifications within the general scope of the contract. (b) The Contractor shall promptly notify the Contracting Officer, in writing, of subsurface or latent physical conditions differing materially from those indicated in this contract or unknown unusual physical conditions at the site before proceeding with the work. (c) If changes under paragraph (a) or conditions under paragraph (b) increase or decrease the cost of, or time required for performing the work, the Contracting Officer shall make an equitable adjustment (see paragraph (d)) upon submittal of a proposal for adjustment (hereafter referred to as proposal) by the Contractor before final payment under the contract. (d) The Contracting Officer shall not make an equitable adjustment under paragraph (b) unless-
Sample 1
CHANGES AND CHANGED CONDITIONS. If, during the course of the work herein contemplated, the need to change the Scope of Work or the Work Schedule should arise, for whatever reasons, whichever party first identifies such need to change shall notify the other party in writing. The representatives of the parties shall meet within seven (7) working days of the date of such notice to discuss the need for change so identified and to set the proposed action to be taken by the parties. A change in the Scope of Work may also result in a change in the compensation amount. Compensation changes shall be based upon the Consultant Budget and Fee Schedule (Exhibit B) attached hereto. Any changes agreed to shall be documented by duly executed amendments to this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to CHANGES AND CHANGED CONDITIONS

  • Changed Conditions When it is agreed that the completion of certain work or other requirements hereunder would no longer serve the purpose intended because of substantial change in the physical conditions of Sale Area or Included Timber since the date of this contract, the requirements shall be waived in writing. The estimated cost of such waived work or other requirement shall be charged to Timber Sale Account.

  • Existing Conditions Tenant accepts the Property in its condition as of the execution of the Lease, subject to all recorded matters, laws, ordinances, and governmental regulations and orders. Except as provided herein, Tenant acknowledges that neither Landlord nor any agent of Landlord has made any representation as to the condition of the Property or the suitability of the Property for Tenant's intended use. Tenant represents and warrants that Tenant has made its own inspection of and inquiry regarding the condition of the Property and is not relying on any representations of Landlord or any Broker with respect thereto. If Landlord or Landlord's Broker has provided a Property Information Sheet or other Disclosure Statement regarding the Property, a copy is attached as an exhibit to the Lease.

  • Additional Conditions As a condition to any such assignment or subletting, whether or not Landlord’s consent is required, Landlord may require: (i) that any assignee or subtenant agree, in writing at the time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by Landlord without any liability except to credit such payment against those due under the Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and (ii) A list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project, prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlord’s sole and absolute discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any such proposed assignee or subtenant is required, however, to provide Landlord with any portion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities.

  • Legal Conditions to the Merger (a) Subject to the terms hereof, the Company and the Fund shall each use its reasonable best efforts to (i) take, or cause to be taken, all actions, and do, or cause to be done, and to assist and cooperate with the other parties in doing, all things necessary, proper or advisable to consummate and make effective the Merger and the other transactions contemplated hereby and by the Company Stockholders’ Agreement as promptly as practicable, (ii) as promptly as practicable, obtain from any Governmental Entity or any other third party any consents, licenses, permits, waivers, approvals, authorizations, or orders required to be obtained or made by the Company, Acquisition LLC or the Fund or any of their Subsidiaries in connection with the authorization, execution and delivery of this Agreement and the Company Stockholders’ Agreement and the consummation of the transactions contemplated hereby and thereby, (iii) as promptly as practicable, make all necessary filings, and thereafter make any other required submissions, with respect to this Agreement and the Company Stockholders’ Agreement, and the Merger required under (A) the Securities Act and the Exchange Act, and any other applicable federal or state securities laws, and (B) any other applicable law and (iv) execute or deliver any additional instruments necessary to consummate the transactions contemplated by, and to fully carry out the purposes of, this Agreement and the Company Stockholders’ Agreement. The Company and the Fund shall cooperate with each other in connection with the making of all such filings. The Company and the Fund shall use their respective reasonable efforts to furnish to each other all information required for any application or other filing to be made pursuant to the rules and regulations of any applicable law (including all information required to be included in the Proxy Statement and the Registration Statement) in connection with the transactions contemplated by this Agreement and the Company Stockholders’ Agreement. (b) Each of the Company and the Fund shall give (or shall cause their respective Subsidiaries to give) any notices to third parties, and use, and cause their respective Subsidiaries to use, their reasonable efforts to obtain any third party consents related to or required in connection with the Merger that are (i) necessary to consummate the transactions contemplated hereby or in the Company Stockholders’ Agreement, (ii) disclosed or required to be disclosed in the Company Disclosure Schedule or the Fund Disclosure Schedule, as the case may be, or (iii) required to prevent a Company Material Adverse Effect or a Fund Material Adverse Effect from occurring prior to or after the Effective Time.

  • Specific Conditions If applicable, specific conditions required after a risk assessment will be included in Exhibit G. Grantee shall adhere to the specific conditions listed therein.

  • Legal Conditions to Merger Each of the Company, Parent and Sub will take all reasonable actions necessary to comply promptly with all legal requirements which may be imposed on itself with respect to the Merger (which actions shall include, without limitation, furnishing all information required in connection with approvals of or filing with any Governmental Entity) and will promptly cooperate with each other and furnish information to each other in connection with any such requirements imposed upon any of them or any of their Subsidiaries in connection with the Merger. Each of the Company, Parent and Sub will, and will cause its Subsidiaries to, take all reasonable actions necessary to (a) obtain (and will cooperate with each other in obtaining) any consent, authorization, order or approval of, or any exemption by, any Governmental Entity or other public or private third party, required to be obtained or made by Parent, the Company or any of their respective Subsidiaries in connection with the Merger or the taking of any action contemplated thereby or by this Agreement and (b) provide such other information and communications to such Governmental Entities or other public or private third parties as the other party or such Governmental or Regulatory Authorities or other public or private third parties may reasonably request in connection therewith. In addition to and not in limitation of the foregoing, each of the parties will (x) take promptly all actions necessary to make the filings required of Parent and the Company or their affiliates under the HSR Act, (y) comply at the earliest practicable date with any request for additional information received by such party or its affiliates from the Federal Trade Commission (the "FTC") or the Antitrust Division of the Department of Justice (the "Antitrust Division") pursuant to the HSR Act, and (z) cooperate with the other party in connection with such party's filings under the HSR Act and in connection with resolving any investigation or other inquiry concerning the Merger or the other matters contemplated by this Agreement commenced by either the FTC or the Antitrust Division or state attorneys general.

  • FORCE MAJEURE; OTHER CHANGES IN CONDITIONS 19.1 In the event of and as soon as possible after the occurrence of any cause constituting force majeure, the affected Party shall give notice and full particulars in writing to the other Party, of such occurrence or cause if the affected Party is thereby rendered unable, wholly or in part, to perform its obligations and meet its responsibilities under the Contract. The affected Party shall also notify the other Party of any other changes in condition or the occurrence of any event which interferes or threatens to interfere with its performance of the Contract. Not more than fifteen (15) days following the provision of such notice of force majeure or other changes in condition or occurrence, the affected Party shall also submit a statement to the other Party of estimated expenditures that will likely be incurred for the duration of the change in condition or the event of force majeure. On receipt of the notice or notices required hereunder, the Party not affected by the occurrence of a cause constituting force majeure shall take such action as it reasonably considers to be appropriate or necessary in the circumstances, including the granting to the affected Party of a reasonable extension of time in which to perform any obligations under the Contract. 19.2 If the Contractor is rendered unable, wholly or in part, by reason of force majeure to perform its obligations and meet its responsibilities under the Contract, UNDP shall have the right to suspend or terminate the Contract on the same terms and conditions as are provided for in Article 20, “Termination,” except that the period of notice shall be seven (7) days instead of thirty (30) days. In any case, UNDP shall be entitled to consider the Contractor permanently unable to perform its obligations under the Contract in case the Contractor is unable to perform its obligations, wholly or in part, by reason of force majeure for any period in excess of ninety (90) days. 19.3 Force majeure as used herein means any unforeseeable and irresistible act of nature, any act of war (whether declared or not), invasion, revolution, insurrection, terrorism, or any other acts of a similar nature or force, provided that such acts arise from causes beyond the control and without the fault or negligence of the Contractor. The Contractor acknowledges and agrees that, with respect to any obligations under the Contract that the Contractor must perform in areas in which UNDP is engaged in, preparing to engage in, or disengaging from any peacekeeping, humanitarian or similar operations, any delays or failure to perform such obligations arising from or relating to harsh conditions within such areas, or to any incidents of civil unrest occurring in such areas, shall not, in and of itself, constitute force majeure under the Contract.

  • Supplemental Conditions 1. All individuals involved, and all others who might possibly contribute to the acceptable adjustment of a grievance, are authorized and urged to testify with full assurance that no reprisal will follow by reason of such participation. 2. Upon the final determination of the grievance, the documents, communication and records, excepting a record of the grievance and the final adjustment thereof, and excepting records required by law to be kept and maintained, shall be destroyed. 3. At each step of the procedure, the grievant shall be entitled to be accompanied by legal counsel or any other parties the grievant may designate. 4. All grievance hearings shall be confidential. 5. All discussions and hearings shall be conducted at times other than when classes are in session during the school day. 6. It is the responsibility of the grievant to utilize the procedure for adjusting grievances as soon as he is aware of grievance. 7. Excluded from the grievance procedure shall be matters for which law mandates another method of review. 8. The filing of a formal grievance at all levels shall be in writing and shall be reasonably specific as to the nature of the complaint. The grievance should, to the extent possible, describe the alleged event or act giving rise to the grievance including the time, date, and place of the event or act and the names and addresses of any witnesses thereto. The grievant must file Grievance Report Form, Appendix "A". 9. Nothing in this grievance procedure shall be construed as prohibiting a grievant from seeking a judgment or ruling in a court of law. 10. The number of days indicated at each level should be considered as a maximum and every effort should be made to expedite the process. The time limits specified may, however, be extended by mutual agreement. 11. In the event a grievance is filed at such time that it cannot be processed through all the steps in this grievance procedure by the end of the school year and if left unresolved until the beginning of the following school year could result in irreparable harm to the grievant, the time limit set forth herein shall be reduced so that the grievance procedure may be exhausted prior to the end of the school year or within a maximum of thirty (30) days thereafter. 12. If the Board or any of its administrative staff do not present a written decision within the time allotted after the grievance hearing, such failure to act shall be an admission that the grievance was justified and the grievant shall receive the remedy he is seeking.

  • Safe Working Conditions The Employer undertakes to maintain office furniture, equipment, etc., in a practical and safe condition in order to avoid injury to employees or damage to their attire. Employees, for their part and in their own interest, are expected to advise the Employer of any such potentially injurious equipment.

  • Buyer’s Conditions Buyer’s obligations to Close are conditioned upon the following (“Buyer’s Conditions”): (i) All representations and warranties of Seller in this Agreement shall be true, correct and complete in all material respects as of the Closing Date and Seller shall have performed in all material respects all covenants and obligations required to be performed by Seller on or before the Closing Date. (ii) Title Insurance Company is irrevocably committed to issue to Buyer an owner’s title insurance policy covering the Property with standard coverage customary in the state where the Property is located showing liability in the amount of the Purchase Price and showing insurable title to the Property vested in Buyer, subject only to the following: (a) Title Insurance Company’s standard exceptions; (b) liens for all current general and special real property taxes and assessments not yet due and payable; (c) liens of supplemental taxes, if any assessed; (d) any facts an accurate survey and/or a personal inspection of the Property may disclose; (e) the mortgage/deed of trust/deed to secure debt lien in connection with any Buyer financing; (f) any laws, regulations, ordinances (including but not limited to, zoning, building and environmental) as to the use, occupancy, subdivision or improvement of the Property adopted or imposed by any governmental body, or the effect of any non-compliance with or any violation thereof, including but not limited to, any disclosure and/or report required by ordinance; (g) rights of existing tenants and/or occupants of the Property (if any); (h) covenants, restrictions, easements and other matters that do not materially impair the value of the Property or the use thereof; (i) non-monetary encumbrances disclosed to Buyer in writing prior to entering into this Agreement; and (j) any other matter for which Title Insurance Company agrees to provide insurance at no additional cost to Buyer.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!