Claims Analysis Sample Clauses

Claims Analysis. 7.15.1 The A/E, in consultation with the Contracting Authority, shall respond to the Contractor’s written notice of a Claim within a reasonable time of receipt, but not to exceed 10 days. 7.15.2 The A/E shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim. The written analysis shall include: 7.15.2.1 A narrative of the A/E’s examination of the facts giving rise to the Claim; 7.15.2.2 Identification of relevant Contract Documents and language; 7.15.2.3 An analysis of whether the Contractor complied with the requirements of the Contract Documents pertaining to Claim initiation and substantiation including the issues of entitlement to, and calculation of, adjustments of the Contract Sum and Contract Times; 7.15.2.4 An analysis of claimed additional labor, materials, and equipment for the scope of the Work items described; 7.15.2.5 An analysis of any time extension for any interference, disruption, hindrance, impact, or delay claimed (to include the calculation of any concurrent delays affecting entitlement); 7.15.2.6 A concluding opinion regarding the Contractor’s entitlement to, and the appropriateness and reasonableness of all, or any part of, the Claim; and 7.15.2.7 An appendix containing copies of contemporaneous documentation supporting the concluding opinion. 7.15.3 The A/E shall attend dispute resolution meetings convened by the Contracting Authority related to each Claim.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Claims Analysis. 20.1 When commodities are sold subject to a specification requiring analysis, the BUYER shall have the right to claim an allowance to be agreed or to reject the commodities on the basis of an analysis made by him or on his behalf. When the BUYER exercises this right a representative sample shall be drawn, sealed and, if required by the SELLER, shall be submitted to an agreed independent analyst for the justification of any claim or rejection. If required by the SELLER this representative sealed sample shall be jointly or independently drawn (whichever is agreed) so far as practicable. Costs of independent sampling and analysis so incurred shall be for the SELLER's account if the claim or rejection is upheld, otherwise for the BUYER's account. 20.2 All such claims must be notified so as to be received by the SELLER within 60 days from the last day of the contract period. 20.3 Where the contract between the parties denotes that that the quality/ specifications will be final at load/ place of loading, and a specified certificate is to be provided in terms of this contract, denoting the quality/ specifications at place of loading (and as detailed under item 3, or item 24 of this contract), then the specifications on such a certificate will be final and binding. The Buyer will have no recourse, if upon arrival of the commodity at destination, the quality/specifications is/ are different from those stated on the applicable certificate, as provided for in this contract.
Sample 1Sample 2Sample 3See All (4)
Claims Analysis. 8.14.1 The A/E, in consultation with the Contracting Authority, shall respond to the Contractor’s written notice of a Claim within a reasonable time of receipt, but not to exceed ten days. 8.14.2 The A/E shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim. The written analysis shall include: 8.14.2.1 a narrative of the A/E’s examination of the facts giving rise to the Claim;
Sample 1Sample 2
Claims Analysis. 7.15.1 The A/E, in consultation with the Contracting Authority, shall respond to the Contractor’s written notice of a Claim within a reasonable time of receipt, but not to exceed 10 days. 7.15.2 The A/E shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim. The written analysis shall include: 7.15.2.1 A narrative of the A/E’s examination of the facts giving rise to the Claim; 7.15.2.2 Identification of relevant Contract Documents and language; 7.15.2.3 An analysis of whether the Contractor complied with the requirements of the Contract Documents pertaining to Claim initiation and substantiation including, but not limited to, the issues of entitlement to, and calculation of, adjustments of the Contract Sum, and Contract Times, or both; 7.15.2.4 An analysis of claimed additional labor, materials, and equipment for the scope of the Work items described; 7.15.2.5 An analysis of any time extension for any interference, disruption, hindrance, impact, or delay claimed (to include the calculation of any concurrent delays affecting entitlement); 7.15.2.6 A concluding opinion regarding the Contractor’s entitlement to, and the appropriateness and reasonableness of all, or any part of, the Claim; and 7.15.2.7 An appendix containing copies of contemporaneous documentation supporting the concluding opinion. 7.15.3 The A/E shall attend dispute resolution meetings convened by the Contracting Authority related to each Claim.
Sample 1
Claims Analysis. The A/E, in consultation with the Contracting Authority, shall respond to the Contractor’s written notice of a Claim within a reasonable time of receipt, but not to exceed 10 days. The A/E shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim. The written analysis shall include: A narrative of the A/E’s examination of the facts giving rise to the Claim; Identification of relevant Contract Documents and language; An analysis of whether the Contractor complied with the requirements of the Contract Documents pertaining to Claim initiation and substantiation including the issues of entitlement to, and calculation of, adjustments of the Contract Sum and Contract Times; An analysis of claimed additional labor, materials, and equipment for the scope of the Work items described; An analysis of any time extension for any interference, disruption, hindrance, impact, or delay claimed (to include the calculation of any concurrent delays affecting entitlement); A concluding opinion regarding the Contractor’s entitlement to, and the appropriateness and reasonableness of all, or any part of, the Claim; and An appendix containing copies of contemporaneous documentation supporting the concluding opinion. The A/E shall attend dispute resolution meetings convened by the Contracting Authority related to each Claim.
Sample 1
Claims Analysis. 4.7.1 The A/E, in consultation with the Consultant and the Contracting Authority, shall respond to the Contractor’s written notice of a Claim within a reasonable time of receipt, but not to exceed 10 days. 4.7.2 The A/E, in conjunction with the Consultant, shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim. The written analysis shall include: 4.7.2.1 A narrative of the A/E and Consultant’s examination of the facts giving rise to the Claim; 4.7.2.2 Identification of relevant Contract Documents and language; 4.7.2.3 An analysis of whether the Contractor complied with the requirements of the Contract Documents pertaining to Claim initiation and substantiation including, but not limited to, the issues of entitlement to, and calculation of, adjustments of the Contract Sum, Contract Times, or both; 4.7.2.4 An analysis of claimed additional labor, materials, and equipment for the scope of the Work items described; 4.7.2.5 An analysis of any time extension for any interference, disruption, hindrance, impact, or delay claimed (to include the calculation of any concurrent delays affecting entitlement); 4.7.2.6 A concluding opinion regarding the Contractor’s entitlement to, and the appropriateness and reasonableness of all, or any part of, the Claim; and 4.7.2.7 An appendix containing copies of contemporaneous documentation supporting the concluding opinion.
Sample 1

Related to Claims Analysis

  • Risk Analysis The Custodian will provide the Fund with a Risk Analysis with respect to Securities Depositories operating in the countries listed in Appendix B. If the Custodian is unable to provide a Risk Analysis with respect to a particular Securities Depository, it will notify the Fund. If a new Securities Depository commences operation in one of the Appendix B countries, the Custodian will provide the Fund with a Risk Analysis in a reasonably practicable time after such Securities Depository becomes operational. If a new country is added to Appendix B, the Custodian will provide the Fund with a Risk Analysis with respect to each Securities Depository in that country within a reasonably practicable time after the addition of the country to Appendix B.

  • Escrow Analysis If applicable, with respect to each Mortgage Loan, the Seller has within the last twelve months (unless such Mortgage was originated within such twelve month period) analyzed the required Escrow Payments for each Mortgage and adjusted the amount of such payments so that, assuming all required payments are timely made, any deficiency will be eliminated on or before the first anniversary of such analysis, or any overage will be refunded to the Mortgagor, in accordance with RESPA and any other applicable law;

  • Quantitative Analysis Quantitative analysts develop and apply financial models designed to enable equity portfolio managers and fundamental analysts to screen potential and current investments, assess relative risk and enhance performance relative to benchmarks and peers. To the extent that such services are to be provided with respect to any Account which is a registered investment company, Categories 3, 4 and 5 above shall be treated as “investment advisory services” for purposes of Section 5(b) of the Agreement.”

  • Sampling and Analysis The Seller has sole responsibility for quality control of the coal and shall forward its “as loaded” quality to the Buyer as soon as possible. The sampling and analysis of the coal delivered hereunder shall be performed by Buyer and the results thereof shall be accepted and used for the quality and characteristics of the coal delivered under this Agreement. All analyses shall be made in Buyer’s laboratory at Buyer’s expense in accordance with ASTM standards where applicable, or using standards mutually acceptable to both parties. Samples for analyses shall be taken by any ASTM standards or standards mutually acceptable to both parties, and may be composited and shall be taken with a frequency and regularity sufficient to provide reasonably accurate representative samples of the deliveries made hereunder. Seller represents that it is familiar with Buyer’s sampling and analysis practices, and finds them to be acceptable. Buyer shall notify Seller in writing of any significant changes in Buyer’s sampling and analysis practices. Any such changes in Buyer’s sampling and analysis practices shall, except for ASTM or mutually agreeable changes in practices, provide for no less accuracy than the sampling and analysis practices existing at the time of the execution of this Agreement, unless the Parties otherwise mutually agree. (1) part shall be used for analysis by Buyer; one (l) part shall be used by Buyer as a check sample, if Buyer in its sole judgment determines it is necessary; one (1) part shall be retained by Buyer (LG&E) until the twenty-fifth (25th) of the month following the month of unloading (the “LG&E Disposal Date”) or Buyer (KU) until thirty (30) days after the sample is taken (the “KU Disposal Date”), the LG&E Disposal Date and the KU Disposal Date are collectively the “Disposal Date”), and shall be delivered to Seller for analysis if Seller so requests before the Disposal Date; and one part (“Referee Sample”) shall be retained by Buyer until the Disposal Date. Seller shall be given copies of all analyses made by Buyer by the tenth (10th) business day of the month following the month of unloading. Seller, on reasonable notice to Buyer shall have the right to have a representative present to observe the sampling and analyses performed by Buyer. Unless Seller requests a Referee Sample analysis before the Disposal Date, Buyer’s analysis shall be used to determine the quality of the coal delivered hereunder. The Monthly Weighted Averages shall be determined by utilizing the individual shipment analyses. If any dispute arises before the Disposal Date, the Referee Sample retained by Buyer shall be submitted for analysis to an independent commercial testing laboratory (“Independent Lab”) mutually chosen by Buyer and Seller. For each coal quality specification in question, a dispute shall be deemed not to exist and Buyer’s analysis shall prevail and the analysis of the Independent Lab shall be disregarded if the analysis of the Independent Lab differs from the analysis of Buyer by an amount equal to or less than: (i) 0.50% moisture (ii) 0.50% ash on a dry basis (iii) 100 Btu/lb. on a dry basis (iv) 0.10% sulfur on a dry basis. For each coal quality specification in question, if the analysis of the Independent Lab differs from the analysis of Buyer by an amount more than the amounts listed above, then the analysis of the Independent Lab shall prevail and Buyer’s analysis shall be disregarded. The cost of the analysis made by the Independent Lab shall be borne by Seller to the extent that Buyer’s analysis prevails and by Buyer to the extent that the analysis of the Independent Lab prevails.

  • Claims and Review Procedure In the event that any claim for benefits that must initially be submitted in writing to the Board of Directors, is denied (in whole or in part) hereunder, the claimant shall receive from First Charter a notice of denial in writing within 60 days, written in a manner calculated to be understood by the claimant, setting forth the specific reasons for denial, with specific reference to pertinent provisions of this Supplemental Agreement. Any disagreements about such interpretations and construction shall be submitted to an arbitrator subject to the rules and procedures established by the American Arbitration Association. The arbitrator shall be acceptable to both First Charter and the Executive (or Beneficiary); if the parties cannot agree on a single arbitrator, the disagreement shall be heard by a panel of three arbitrators, with each party to appoint one arbitrator and the third to be chosen by the other two. No member of the Board of Directors shall be liable to any person for any action taken under Article VIII except those actions undertaken with lack of good faith.

  • Claims and Review Procedures 6.1 For all claims other than Disability benefits:

  • SAMPLE (If applicable and the project has specifications, insert the specifications into this section.)

  • Independent Analysis Each Party hereby confirms that its decision to execute this Agreement has been based upon its independent assessment of documents and information available to it, as it has deemed appropriate.

  • Claims Review Population A description of the Population subject to the Claims Review.

  • Claims Submission We will submit your claims and assist you in any way we reasonably can to help get your claims paid. Your insurance company may need you to supply certain information directly. It is your responsibility to comply with their request. Please be aware that the balance of your claim is your responsibility whether or not your insurance company pays your claim. Your insurance benefit is a contract between you and your insurance company; we are not party to that contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!