Construction Documents Phase Bidding or Negotiation Phase:
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Design Documents Prepare and submit the following documents to the DAS - Records Management Office with a copy of the transmittal letter submitted to the respective Project Manager:
1. City/State Approved Drawings (1) Original set
2. Bid Set Drawings (1) Set BOND PAPER (marked as “ORIGINAL”)
(1) Set electronic file (DWG & PDF)
3. Project Manual
(1) Set hard copy & Detail Manual (1) Set electronic file
REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The
Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.
6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement.
6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement.
6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER.
6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing.
6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8.
6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Acquisition Documents As of the Closing Date:
(a) Borrower has furnished Bank with true, correct and complete execution copies of all Acquisition Documents. Borrower has taken all necessary corporate action to authorize the execution, delivery and performance of each Acquisition Document to which it is a party.
(b) Borrower has complied with all applicable federal, state, provincial and local laws, ordinances, codes, rules, regulations and guidelines (including consent decrees and administrative orders) relating to the consummation of the Acquisition and all applicable waiting periods with respect to the transactions contemplated by the Acquisition Documents have expired without any action being taken by any competent governmental authority which restrains, prevents or imposes material adverse conditions upon the consummation of such transactions.
(c) All necessary authorization, consent, approval, license, qualification or formal exemption from, and all necessary filing, declaration or registration with, any court, governmental agency or regulatory authority or any securities exchange or any other Person (whether or not governmental, and including without limit any shareholder, partner or member of an applicable party) required to be made prior to the closing of the Acquisition in connection with the execution, delivery and performance by Borrower, and to Borrower’s best knowledge, each other party to the Acquisition Documents to which Borrower or such other Person is a party, have been obtained and will be in full force and effect, and, to the knowledge of Borrower, are not the subject of any attack or threatened attack (in each case in any material respect) by appeal or direct proceeding or otherwise.
(d) The execution, delivery and performance of the Acquisition Documents, and the consummation of the transactions contemplated thereby, are not in contravention of the terms of any indenture, material contract, instrument, any judgment, order or decree, to which Borrower is a party or by which it or its properties are bound, except, in each case, where such contravention could not reasonably be expected to have a Material Adverse Effect.
(e) Borrower has not granted a collateral assignment of, or a security interest over the Acquisition Documents (other than in favor of Bank) and Borrower has not sold, transferred or assigned any Acquisition Document to any Person (other than to or in favor of Bank).
(f) No Acquisition Document to which Borrower is a party has been modified, amended, altered or changed in any manner except in compliance with Section 7.12 of this Agreement, and to Borrower’s best knowledge, there are no unwaived defaults existing under the Acquisition Documents by Borrower that is a party thereto, or, to the best of the knowledge of Borrower, by any other party thereto.
MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.
