Legal Fees and Costs In the event a party elects to incur legal expenses to enforce or interpret any provision of this Agreement by judicial proceedings, the prevailing party will be entitled to recover such legal expenses, including, without limitation, reasonable attorneys’ fees, costs, and necessary disbursements at all court levels, in addition to any other relief to which such party shall be entitled.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
REIMBURSEMENT OF FEES AND COSTS The Parties acknowledge that Xxxxxxx and her counsel offered to reach preliminary agreement on the material terms of this dispute before reaching terms on the amount of fees and costs to be reimbursed to them. The Parties thereafter reached an accord on the compensation due to Xxxxxxx and her counsel under general contract principles and the private attorney general doctrine and principles codified at California Code of Civil Procedure § 1021.5, for all work performed through the mutual execution of this agreement. Under these legal principles, ABG shall reimburse Xxxxxxx’s counsel for fees and costs incurred as a result of investigating and bringing this matter to ABG’s attention, and negotiating a settlement in the public interest. Within ten (10) days of the Effective Date, ABG shall issue a check payable to “Xxxxxxx & Xxxxx” in the amount of $4,500.00 for delivery to the address identified in § 3.2(a)(i), above.
Arbitration Fees and Costs If your claim seeks more than $75,000 in the aggregate, the payment of the AAA’s fees and costs will be governed by the AAA rules. If your claims seek less than $75,000 in the aggregate, the payment of the AAA’s fees and costs will be our responsibility. However, if the arbitrator finds that your Dispute was frivolous or brought for an improper purpose (as measured by the standards set forth in Federal Rule of Civil Procedure 11(b)), the payment of the AAA’s fees and costs shall be governed by the AAA Rules and you shall reimburse us for all fees and costs that were your obligation to pay under the AAA Rules. You may hire an attorney to represent you in arbitration. You are responsible for your attorneys’ fees and additional costs and may only recover your attorneys’ fees and costs in the arbitration to the extent that you could in court if the arbitration is decided in your favor. Notwithstanding anything in this Arbitration Provision to the contrary, we will pay all fees and costs that it is required by law to pay.
Fees and Costs As part of the Appeal Panel Award, the Appeal Panel is hereby directed to require the losing party (the party being awarded the least amount of money by the arbitrator, which, for the avoidance of doubt, shall be determined without regard to any statutory fines, penalties, fees, or other charges awarded to any party) to (a) pay the full amount of any unpaid costs and fees of the Arbitration and the Appeal Panel, and (b) reimburse the prevailing party (the party being awarded the most amount of money by the Appeal Panel, which, for the avoidance of doubt, shall be determined without regard to any statutory fines, penalties, fees, or other charges awarded to any part) the reasonable attorneys’ fees, arbitrator and Appeal Panel costs and fees, deposition costs, other discovery costs, and other expenses, costs or fees paid or otherwise incurred by the prevailing party in connection with the Arbitration (including without limitation in connection with the Appeal).
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Subcontract Costs Payments made by the Construction Manager to Subcontractors in accordance with the requirements of the subcontracts and this Agreement.
Professional Fees Borrower promises to pay Lender’s fees and expenses necessary to finalize the loan documentation, including but not limited to reasonable attorneys fees, UCC searches, filing costs, and other miscellaneous expenses. In addition, Borrower promises to pay any and all reasonable attorneys’ and other professionals’ fees and expenses (including fees and expenses of in-house counsel) incurred by Lender after the Closing Date in connection with or related to: (a) the Loan; (b) the administration, collection, or enforcement of the Loan; (c) the amendment or modification of the Loan Documents; (d) any waiver, consent, release, or termination under the Loan Documents; (e) the protection, preservation, sale, lease, liquidation, or disposition of Collateral or the exercise of remedies with respect to the Collateral; (f) any legal, litigation, administrative, arbitration, or out of court proceeding in connection with or related to Borrower or the Collateral, and any appeal or review thereof; and (g) any bankruptcy, restructuring, reorganization, assignment for the benefit of creditors, workout, foreclosure, or other action related to Borrower, the Collateral, the Loan Documents, including representing Lender in any adversary proceeding or contested matter commenced or continued by or on behalf of Borrower’s estate, and any appeal or review thereof.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.
