Contractor’s Acknowledgment Sample Clauses

Contractor’s Acknowledgment. When a notice to proceed is issued, the con- tractor will acknowledge receipt there- of by signing and dating all copies of the acknowledgment and returning all but one copy to the contracting officer.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Contractor’s Acknowledgment. Contractor hereby expressly acknowledges and agrees that: (a) the restrictions and obligations set forth and imposed by Sections 5 and 6 will not prevent Contractor from obtaining gainful employment in Contractor's field of expertise or cause Contractor undue hardship; and (b) in view and in consideration of the benefits Contractor will receive from Xzeres pursuant to this Agreement, the restrictions and obligations imposed on Contractor under Sections 5 and 6 are reasonable and necessary to protect the legitimate business interests of Xzeres. If any provision or subdivision of this Agreement, including, but not limited to, Sections 5 and 6, is found by a court of competent jurisdiction to be unreasonable or otherwise unenforceable, any such portion shall nevertheless be enforced to the greatest extent such court shall deem reasonable, and, in such event, it is the parties' intention, desire and request that the court reform such portion in order to make it enforceable. In the event of such judicial reformation, the parties agree to be bound by this Agreement as reformed in the same manner and to the same extent as if they had agreed to such reformed agreement in the first instance.
Sample 1Sample 2
Contractor’s Acknowledgment. Contractor expressly agrees that the period of time specified to complete all Work and the timely achievement of the Substantial Completion Guaranteed Dates includes allowance for coordination with Owner, Owner’s Engineer and for all hindrances and delays incident to the Work (other than an Excusable Event or an event of Force Majeure). No claim shall be made by Contractor for hindrances or delays for any cause during the progress of the Work, except as provided under Articles 8 and 16.
Sample 1
Contractor’s Acknowledgment. Under the Program, vehicles may be delivered to Contractor for repairs either by a Claimant Referral or pursuant to a Progressive Coordinated Repair. Contractor acknowledges, however, that under the Program, Progressive has no obligation to refer vehicles to Contractor and Claimants are not required to use Contractor's services.
Sample 1
Contractor’s Acknowledgment. Contractor acknowledges and agrees that the Confi- dential Information described above is the valuable property of TC, which was developed over
Sample 1
Contractor’s Acknowledgment. Any public presentation or publication by the Contractor, including a student writing a thesis, dissertation, or report, based on the Project of the Foundation’s Property, shall include the following, or a similar, statement acknowledging the Foundation and it’s funding partner U.S. Bureau of Reclamation for providing financial and administrative support: The [Contractor] gratefully acknowledges that the WateReuse Foundation’s financial, technical, and administrative assistance in funding and managing the project through which this information was discovered. The [Contractor] acknowledges the financial assistance from the Foundation.
Sample 1
Contractor’s Acknowledgment. Contractor expressly agrees that the period of time specified to complete all Work and the timely achievement of the Project Guaranteed Dates includes allowance for coordination with Owner, the existing operations at Units 1-4 (but with respect to Units 1-2 only until April 25, 2007 and with respect to Unit 3 only until August 25, 2007), Owner’s Engineer and for all hindrances and delays incident to the Work (other than an Excusable Event or an event of Force Majeure). No claim shall be made by Contractor for hindrances or delays for any cause during the progress of the Work, except as provided under Articles 8 and 16.
Sample 1
AutoNDA by SimpleDocs
Contractor’s Acknowledgment. Any public presentation or publication by the Contractor, including a student writing a thesis, dissertation, or report, based on the Project, shall include the following, or a similar, statement acknowledging the Foundation for providing financial and administrative support:
Sample 1
Contractor’s Acknowledgment. <insert name of contractor> is providing this Acknowledgment to NYSDOL as required by Paragraph 8 of the Non-Disclosure Agreement executed by <insert name of contractor> on this day of
Sample 1

Related to Contractor’s Acknowledgment

  • Contractor’s Documents Any licensing and maintenance agreement, or any order-specific agreement or document, including any pre-installation, linked or “click through” agreement that is allowed by, referenced within or incorporated within the Contract whenever the Contract is used for a State procurement, whether directly by the Contractor or through a Contractor’s agent, subcontractor or reseller, is agreed to only to the extent the terms within any such agreement or document do not conflict with the Contract or applicable Minnesota or Federal law, and only to the extent that the terms do not modify, diminish or derogate the terms of the Contract or create an additional financial obligation to the State. Any such agreement or document must not be construed to deprive the State of its sovereign immunity, or of any legal requirements, prohibitions, protections, exclusions or limitations of liability applicable to this Contract or afforded to the State by Minnesota law. A State employee’s decision to choose “accept” or an equivalent option associated with a “click- through” agreement does not constitute the State’s concurrence or acceptance of terms, if such terms are in conflict with this section.

  • Contractor’s Status At all times during the Contract Period the Contractor shall be an independent contractor and nothing in the Contract shall create a contract of employment, a relationship of agency or partnership or a joint venture between the Parties and accordingly neither Party shall be authorised to act in the name of, or on behalf of, or otherwise bind the other Party save as expressly permitted by the terms of the Contract.

  • Contractor’s Staff 1. The Contractor shall maintain adequate staff to meet the Contractor’s obligations under this Agreement. 2. This staff shall be available to the State for training and meetings which the State may find necessary from time to time.

  • Other Contractors District reserves the right to enter into other agreements for work additional or related to the subject matter of this Contract, and Contractor agrees to cooperate fully with these other contractors and with the District. When requested by District, Contractor shall coordinate its performance under this Contract with such additional or related work. Contractor shall not interfere with the work performance of any other contractor or District employees.

  • HHSC and Contractor Agreements HHSC and Contractor hereby agree: A. That in the event any provision of this Contract becomes unenforceable or void all other provisions of this Contract will remain ineffect. B. That the Contractor may not transfer or assign this Contract without the express prior written approval of HHSC. C. That this Contract may be assigned to a state agency or agencies. D. That HHSC may amend this Contract by written notice to the Contractor. HHSC reserves the right to amend this Contract through execution of a unilateral amendment signed by an HHSC person with delegated signature authority and provided to the Contractor under the following circumstances: 1. to correct an obvious clerical error in the Contract; 2. to incorporate new or revised federal or state statutes, rules or policies; 3. to comply with a court order or judgment; and 4. to change the name of the Contractor to reflect the Contractor's name as recorded by the Texas Secretary of State. E. That nothing in this Contract or any conduct by a representative of HHSC relating to this Contract shall be construed as a waiver of the state's sovereign immunity to suit. F. That neither party to this Contract waives its right to enforce a right under this Contract by failing to enforce or delaying the enforcement of any other right under this Contract. G. That the Contractor is an independent contractor and not an employee of HHSC for any purpose. The Contractor and HHSC agreethat: 1. HHSC will not withhold or pay on behalf of the Contractor any sums for income tax, unemployment insurance, Social Security or any other withholding, or make available to the Contractor any of the benefits, including workers' compensation insurance coverage and health and retirement benefits, afforded to HHSC employees; and 2. the Contractor must indemnify HHSC from any liability, including attorneys' fees and legal expenses, incurred by HHSC with respect to claims that HHSC should have been withholding or making payments on behalf of the Contractor or providing benefits to the Contractor's employees. H. That nothing in this Contract is intended to create a joint venture, a partnership or a principal-agent relationship. I. That the Contractor assigns to HHSC all claims for overcharges associated with this Contract arising under the anti-trust laws of the United States, 15 U.S.C. §§ 1-38, or the anti-trust laws of the state of Texas, Tex. Bus. & Com. Code, §§ 15.01-.40. J. That HHSC has authority to monitor and conduct fiscal and program compliance reviews of the Contractor and its subcontractor(s) to the extent of services provided under the terms of this Contract. The Contractor will grant on-site access at reasonable times to all records relating to services provided and payments received under the terms of this Contract to state and federal auditing agencies and personnel and representatives of HHSC and HHS when it is deemed necessary by such agencies for purposes of inspection, monitoring, auditing or evaluating Contractor's performance under this Contract and compliance with applicable state and federal laws, rules and regulations; the applicable HHSC provider handbook or manual; and this Contract. That for Title XX programs, HHSC shall, by Form 2029, Information Worksheet – POS Contract, set the rate or maximum amount of funds or both available to be paid to Contractor by HHSC. Form 2029 is incorporated into and made a part of this Contract and is effective for the time stated on the form. Form 2029 may be amended by HHSC as necessary to comply with state and federal laws and regulations or renewed by HHSC by a new Form 2029 and incorporated into and made part of this Contract. K. That in compliance with §2262.003, Texas Government Code: 1. the state auditor may conduct an audit or investigation of any entity receiving funds from the state directly under the Contract or indirectly through a subcontract under the Contract; 2. acceptance of funds directly under the Contract or indirectly through a subcontract under the Contract acts as acceptance of the authority of the state auditor, under the direction of the legislative audit committee, to conduct an audit or investigation in connection with those funds; and 3. under the direction of the legislative audit committee, an entity that is the subject of an audit or investigation by the state auditor must provide the state auditor with access to any information the state auditor considers relevant to the investigation or audit. L. That this Contract shall continue subject to the availability of appropriated funds or until the federal or state governments or both cease to participate in the program. M. That any breach or violation of any of the provisions of this Contract or state or federal regulations shall make this entire Contract, at HHSC's option, subject to termination. N. That if HHSC does not renew the Contractor's contract due to the Contractor's noncompliance with applicable federal or Texas statutes or rules, the Contractor cannot enter into another contract for a Community Services program until the application denial period established by HHSC expires. O. That the venue for any lawsuit between HHSC and the Contractor shall be Travis County, Texas. P. That this Contract may be terminated by:

  • Contractors All LAUSD Contractors and their Representatives are expected to conduct any and all business affiliated with LAUSD in an ethical and responsible manner that fosters integrity and public confidence. A “Contractor” is any individual, organization, corporation, sole proprietorship, partnership, nonprofit, joint venture, association, or any combination thereof that is pursuing or conducting business with and/or on behalf of LAUSD, including, without limitation, consultants, suppliers, manufacturers, and any other vendors, bidders or proposers. A Contractor’s “Representative” is also broadly defined to include any subcontractors, employees, agents, or anyone else who acts on a Contractor’s behalf.

  • Contractor’s Contract Manager The Contractor’s Contract Manager, who is primarily responsible for the Contractor’s oversight of the Contract performance, will be identified in a separate writing to the Department upon Contract signing in the following format: Contractor’s Contract Manager Name Contractor’s Name Contractor’s Physical Address Contractor’s Telephone # Contractor’s Email Address If the Contractor changes its Contract Manager, the Contractor will notify the Department. Such a change does not require an amendment to the Contract.

  • Contractor If COUNTY elects to renegotiate this Agreement due to reduced or terminated 20 funding, CONTRACTOR shall not be obligated to accept the renegotiated terms.

  • Contractor Key Personnel ‌ The Contractor shall assign a Corporate OASIS SB Program Manager (COPM) and Corporate OASIS SB Contract Manager (COCM) as Contractor Key Personnel to represent the Contractor as primary points-of-contact to resolve issues, perform administrative duties, and other functions that may arise relating to OASIS SB and task orders solicited and awarded under OASIS SB. Additional Key Personnel requirements may be designated by the OCO at the task order level. There is no minimum qualification requirements established for Contractor Key Personnel. Additionally, Contractor Key Personnel do not have to be full-time positions; however, the Contractor Key Personnel are expected to be fully proficient in the performance of their duties. The Contractor shall ensure that the OASIS SB CO has current point-of-contact information for both the COPM and COCM. In the event of a change to Contractor Key Personnel, the Contractor shall notify the OASIS SB CO and provide all Point of Contact information for the new Key Personnel within 5 calendar days of the change. All costs associated with Contractor Key Personnel duties shall be handled in accordance with the Contractor’s standard accounting practices; however, no costs for Contractor Key Personnel may be billed to the OASIS Program Office. Failure of Contractor Key Personnel to effectively and efficiently perform their duties will be construed as conduct detrimental to contract performance and may result in activation of Dormant Status and/or Off-Ramping (See Sections H.16. and H.17.).

  • A3 Contractor’s Status At all times during the Contract Period the Contractor shall be an independent contractor and nothing in the Contract shall create a contract of employment, a relationship of agency or partnership or a joint venture between the Parties and accordingly neither Party shall be authorised to act in the name of, or on behalf of, or otherwise bind the other Party save as expressly permitted by the Terms of the Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!