Contractors and Supervision Sample Clauses

Contractors and Supervision. If the Redevelopment Plans contemplate the development or redevelopment of the Property (or if, during the Term, any capital projects are required on the Property), Tenant shall enter into contracts with such architects, engineers, contractors and other such professionals (each, a “Development Professional”) as may be required to effect such development, redevelopment or other capital project. Any Development Professionals so engaged by Tenant shall be subject to the approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed (it being agreed that if Landlord does not respond to Tenant’s notice requesting Landlord’s consent to any such Development Professional on or prior to ten (10) Business Days after the date Tenant gives such notice to Landlord, then Landlord shall be deemed to have consented to such Development Professional).
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Contractors and Supervision. (A) All Alterations (other than Decorative Alterations) shall be performed only under the supervision of a licensed architect that Landlord approves, which approval Landlord shall not unreasonably withhold, condition or delay. (B) Subject to the provisions of this Section 7.9(B), Tenant shall perform all Alterations (other than Decorative Alterations) using contractors, subcontractors, engineers and mechanics that in each case Landlord designates from time to time and charge commercially reasonable prices. Landlord shall give Tenant a notice containing a list of such contractors, such subcontractors and such engineers that Landlord designates promptly after Tenant’s request therefor from time to time (it being understood that Landlord shall include in such list the names of at least three (3) subcontractors for each trade and at least three (3) general contractors).
Sample 1Sample 2
Contractors and Supervision. (A) All Alterations that require Landlord's consent shall be performed only under the supervision of a licensed architect that Landlord approves, which approval Landlord shall not unreasonably withhold, condition or delay. Landlord hereby approves the architects listed on Exhibit "7.9-I" attached hereto and made a part hereof as Tenant's architect for purposes of the Initial Alterations. (B) Subject to the provisions of this Section 7.9(B), Tenant shall perform all Alterations (other than Decorative Alterations) using, at Tenant's option, either (i) contractors, subcontractors, and mechanics that in each case Landlord designates from time to time, or (ii) contractors, subcontractors or mechanics that in each case Tenant designates and that Landlord approves, which approval Landlord shall not unreasonably withhold, condition or delay. Landlord shall give Tenant a notice containing a list of such contractors, subcontractors and mechanics that Landlord designates promptly after Tenant's request therefor from time to time (it being understood that Landlord shall include in such list the names of at least three (3) subcontractors for each trade and at least three (3) general contractors), which list of contractors, subcontractors and mechanics as of the date hereof is attached hereto as Exhibit "7.9-II" and made a part hereof. Landlord hereby approves the contractors, subcontractors and mechanics listed on Exhibit "7.9-I" attached hereto and made a part hereof as Tenant's contractors, subcontractors, and mechanics for purposes of the Initial Alterations. If Tenant performs an Alteration consisting of the installation of a fire suppression system in the Premises in accordance with this Article 7, then Tenant shall engage to perform any programming and connection to the base Building fire alarm system the fire alarm vendor that Landlord designates from time to time (provided that the charges imposed by such vendor designated by Landlord are commercially reasonable). (C) Tenant shall pay to Landlord, from time to time, as additional rent, the Out-of-Pocket Costs incurred by Landlord in reviewing plans and specifications in connection with an Alteration with respect to which Landlord's approval or consent is required pursuant to the terms of this Lease within thirty (30) days after Landlord gives Tenant an invoice therefor together with reasonable supporting documentation for the charges set forth therein (it being understood that Landlord shall not have the right ...
Sample 1
Contractors and Supervision. (I) All Alterations (other than Alterations for which no permit is required from any Governmental Authority) shall be performed only under the supervision of a licensed architect that Landlord approves. (II) Subject to the provisions of this Section 7(i)(II), Sublessee shall perform all Alterations which involve connections to any Building Systems using contractors, subcontractors, engineers and mechanics that in each case Landlord approves pursuant to Section 7.9(B) of the Lease.
Sample 1
Contractors and Supervision. All Alterations that require Landlord’s consent shall be performed only under the supervision of a licensed architect that is approved by Landlord, which approval Landlord shall not unreasonably withhold, condition or delay. Subject to the provisions of this Section 7.9, Tenant shall perform all Alterations using, at Tenant’s option, either (i) contractors, subcontractors and mechanics that in each case are designated from time to time by Landlord, or (ii) contractors, subcontractors or mechanics that in each case are designated by Tenant and approved by Landlord, which approval Landlord shall not unreasonably withhold, condition or
Sample 1
Contractors and Supervision. 36 8.10.... Landlord’s Expenses.................................................................... 37
Sample 1
Contractors and Supervision. All Alterations that require Landlord’s consent shall be performed only under the supervision of an independent licensed architect approved by Landlord, which approval Landlord shall not unreasonably withhold, condition or delay. Subject to the provisions of this Section 8.9, Tenant shall perform all Alterations using, at Tenant’s option, either (i) contractors, subcontractors and mechanics that in each case are designated from time to time by Landlord, or (ii) contractors, subcontractors or mechanics that in each case are designated by Tenant and approved by Landlord, which approval Landlord shall not unreasonably withhold, condition or delay. If an Alteration affects a Building System, then (i) Tenant shall engage to perform such Alteration (or the applicable portion thereof that affects such Building System) a contractor from a list of at least three (3) contractors whose charges are commercially reasonable for the applicable trade as designated reasonably by Landlord, and (ii) Tenant shall engage an engineer whose charges are commercially reasonable designated reasonably by Landlord to design such Alteration (or the applicable portion thereof that affects such Building System). Landlord shall give Tenant notice of such contractors and such engineer designated by Landlord promptly after Tenant’s request therefor from time to time. In connection with the performance of the Initial Alterations, Landlord hereby approves the contractors, subcontractors and mechanics listed on Exhibit 8.9 attached hereto and made a part hereof.
Sample 1
AutoNDA by SimpleDocs

Related to Contractors and Supervision

  • Contractors and Subcontractors Drug-Free Workplace Act of 1988 1) Publish and give a policy statement to all covered employees informing them that the unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited in the covered workplace and specifying the actions that will be taken against employees who violate the policy. 2) Establish a drug-free awareness program to make employees aware of a) the dangers of drug abuse in the workplace; b) the policy of maintaining a drug-free workplace; c) any available drug counseling, rehabilitation, and employee assistance programs; and d) the penalties that may be imposed upon employees for drug abuse violations. 3) Notify employees that as a condition of employment on a federal contract or grant, the employee must a) abide by the terms of the policy statement; and b) notify the employer, within five (5) calendar days, if he or she is convicted of a criminal drug violation in the workplace. 4) Notify the contracting or granting agency within ten (10) days after receiving notice that a covered employee has been convicted of a criminal drug violation in the workplace. 5) Impose a penalty on or require satisfactory participation in a drug abuse assistance or rehabilitation program by any employee who is convicted of a reportable workplace drug conviction. 6) Make an ongoing, good faith effort to maintain a drug-free workplace by meeting the requirements of the act.

  • CONTRACTOR SUPERVISION Contractor shall provide competent supervision of personnel employed on the job Site, use of equipment, and quality of workmanship.

  • SUBCONTRACTORS AND SUPPLIERS The Commissioner reserves the right to reject any proposed Subcontractor or supplier for bona fide business reasons, including, but not limited to: the company failed to solicit New York State certified minority- and women-owned business enterprises as required in prior OGS Contracts; the fact that such Subcontractor or supplier is on the New York State Department of Labor’s list of companies with which New York State cannot do business; the Commissioner’s determination that the company is not qualified or is not responsible; or the fact that the company has previously provided unsatisfactory work or services.

  • Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.

  • CONTRACTOR's Agents and Subcontractors To impose the same restrictions and conditions set forth in this Personal Information and Security Contract on any subcontractors or other agents with whom CONTRACTOR subcontracts any activities under the Agreement that involve the disclosure of DHCS PI or PII to such subcontractors or other agents.

  • Payroll Records Contractors and Subcontractors must keep original payrolls or transcripts subscribed and affirmed as true under the penalties of perjury as required by law. For public works contracts over $25,000 where the Contractor maintains no regular place of business in New York State, such records must be kept at the work site. For building services contracts, such records must be kept at the work site while work is being performed.

  • Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.

  • SITE SUPERVISION 1.9.1 Contractor shall provide adequate supervision of his employees to ensure complete and satisfactory performance of all work in accordance with the terms of the contract. Contractor shall have a responsible supervisor on the job at all times when the work of the contract is being carried out. 1.9.2 Contractor's site supervisor shall be responsible for communication with the State's representatives and shall meet with the Project Manager at the site on a weekly basis to discuss project status, including any problems, ideas, or concerns related to the project work. 1.9.3 Contractor and its employees shall be subject to all applicable State and Federal statutes and regulations for the conduct of personnel. 1.9.4 The Contractor shall provide adequate supervision of his/her subcontractors and their employees at all times.

  • Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA. (b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA. (c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein. (d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors. (e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.

  • Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager. 7.2.2 The Contractor’s Project Manager shall be responsible for the Contractor’s day-to-day activities as related to this Contract and shall meet and coordinate with County’s Project Manager and County’s Contract Project Monitor on a regular basis.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!