Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.
Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.
Violence in the Workplace (a) The parties agree that violence shall be defined as any incident in which an employee is abused, threatened or assaulted while performing his or her work. The parties agree it includes the application of force, threats with or without weapons and severe verbal abuse. The parties agree that such incidents will not be condoned. Any employee who believes he/she has been subjected to such incident shall report this to a supervisor who will make every reasonable effort to rectify the situation. For purposes of sub-article (a) only, employees as referred to herein shall mean all employees of the Employer notwithstanding Article 2.12.
(b) The Employer agrees to develop formalized policies and procedures in consultation with the Joint Health and Safety Committee to deal with workplace violence. The policy will address the prevention of violence and the management of violent situations and support to employees who have faced workplace violence. These policies and procedures shall be communicated to all employees. The local parties will consider appropriate measures and procedures in consultation with the Joint Health and Safety Committee to address violence in the workplace, which may include, among other measures and procedures:
i) Alert employees about a person with a known history of aggressive and responsive behaviours and their known triggers by means of:
A) electronic and/or other appropriate flagging systems,
B) direct verbal communication / alerts (i.e. shift reports),
ii) Communicate and provide appropriate training and education,
iii) Reporting all incidents of workplace violence,
iv) Long-term care home wide violence risk assessments.
(c) The Employer will report all incidents of violence as defined herein to the Joint Health and Safety Committee for review.
(d) The Employer agrees to provide training and information on the prevention of violence to all employees who come into contact with potentially aggressive persons. This training will be done during a new employee’s orientation and updated as required.
(e) Subject to appropriate legislation, and with the employee’s consent, the Employer will inform the Union within three (3) days of any employee who has been subjected to violence while performing his/her work. Such information shall be submitted in writing to the Union as soon as practicable.
Execution of the Project (a) The Recipient declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through its MoE with due diligence and efficiency and in conformity with appropriate financial, economic, environmental and administrative practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project.
(b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Recipient and the Association shall otherwise agree, the Recipient shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement.
(a) Except as the Association shall otherwise agree, procurement of the goods, works and consultants’ services required for the Project and to be financed out of the proceeds of the Grant shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan.
(b) The Recipient shall update the Procurement Plan in accordance with terms of reference acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval.
Section 3.03. Without limitation upon any of its obligations under paragraph (a) of Section 3.01 of this Agreement and except as the Recipient and the Association shall otherwise agree, the Recipient shall: (i) not later than by the effectiveness of this Agreement open a separate project account (the Project Account) in a commercial bank acceptable to the Association; (ii) thereafter maintain the Project Account during the entire Project implementation period, and replenish said Account regularly with funds sufficient to ensure the Recipient’s Project co-financing obligations; and (iii) use the amount in the Project Account exclusively for financing the Recipient’s contribution to Project expenditures.
Section 3.04. For the purposes of Section 6.09 of the General Conditions and without limitation thereto, the Recipient shall:
(a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Recipient and the Association, a plan designed to ensure the continued achievement of the Project’s objectives; and
(b) afford the Association a reasonable opportunity to exchange views with the Recipient on said plan.
Completion of the Project The Participating County acknowledges it is obligated to undertake and complete the design and construction of the Project in compliance with all of the applicable terms and conditions of the Project Documents and the Participating County agrees to use its best efforts to cause the completion of design and construction of the Project in compliance with the applicable terms and conditions of such documents. The Participating County agrees to complete the Project in accordance with this Agreement and consistent with the scope, cost and schedule established by the Board and attached hereto in Exhibit A, as such scope, cost and schedule may be modified with the approval of Finance and the recognition of the Board.
Description of the procurement Under this Lot the supplier will provide the below packs (this list is not exhaustive): o Orthopaedic Day Case o Hip Arthroplasty o Knee Arthroplasty o Shoulder Arthroplasty o Arthroscopy- Knee, Hip, Shoulder, Ankle o Hand Surgery o Foot & Ankle Surgery o ACL (Anterior Cruciate Ligament) o Spine- Lumbar, Cervical TERMS AND CONDITIONS / ACTIVITY BASED INCOME (ABI) The terms and conditions of this Agreement and any resulting call-off contract is appended to the ITT. These terms include provisions requiring the payment by the supplier of an ABI management charge in consideration of the award of this Agreement, the management and administration by HTE of the overall contract structure and associated documentation, as well as the requirement to submit regular management information to HTE. SUBMISSION OF EXPRESSIONS OF INTEREST AND PROCUREMENT INFORMATION This exercise will be conducted on the HTE Bravo portal. Candidates wishing to be considered must register expressions of interest as follows: Register on the HTE portal at xxxxx://xxxxxxxxxxxxxxxxx.xxxxxxxxxxxxx.xx.xx. Login to the portal with username/password. Click the SQs/ITTs Open to All Suppliers link. These are the SQs/ITTs open to any registered supplier. Click on the relevant SQ/ ITT to access the content. Click the Express Interest button at the top of the page. This will move the SQ/ITT into your My SQs/My ITTs page. You can access any attachments by clicking Buyer Attachments in the SQ/ITT Details box. Follow the onscreen instructions to complete the SQ/ITT. Submit your reply using the Submit Response button at the top of the page. If you require any further advice, contact the Bravo e- Tendering Help Desk at xxxx@xxxxxxxxxxxxx.xx.xx. Sid4Gov HTE utilises the sid4gov supplier information database. Candidates should register on sid4gov at xxxxx://xxx0xxx.xxxxxxxxxxxxx.xxx.xx/organisation/register and submit their sid4gov company profile for publication on the database. Candidates already registered on sid4gov must ensure information is up to date. Where access to sid4gov is unavailable, please contact the sid4gov helpdesk at xxx0xxx@xxx.xxx.xxx.xx. Please note that sid4gov does not prepopulate any fields of the SQ on HTE's Bravo portal. Candidates must complete the Qualification & Technical Envelopes of the SQ in Bravo in full.
Changes in the Work The Department may order changes in the work, the Contract Amount being adjusted accordingly. Any monetary adjustment or any substantive change in the work shall be in the form of an amendment, signed by both parties and approved by the State Purchases Review Committee. Said amendment must be effective prior to execution of the work.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
