Emergency Change Process Sample Clauses

Emergency Change Process. In the event that either Party requires a Change in order to respond to an emergency and such Change would, in the reasonable opinion of the requesting Party, if it was not implemented until Change Control Procedures had been followed, have a detrimental effect generally on Client, including without limitation Client’s financial interests, customer welfare or public safety, or specifically impacting
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Emergency Change Process. In the event that either Party requires a Change in order to respond to an emergency and such Change would, in the reasonable opinion of the requesting Party, if it was not implemented until Change Control Management had been followed, have a detrimental effect on the requesting Party's ability to meet its obligations pursuant to this Agreement, the requesting Party shall make all reasonable efforts to contact the other Party's Designated Executive, and if the requesting Party is unable to contact the other Party's Designated Executive after reasonable efforts, the requesting Party shall, where appropriate and practical, make all reasonable efforts to contact the other Party's designated member of the Executive Steering Committee. If the requesting Party is unable to contact either the other Party's Designated Executive or the other Party's designated Executive Steering Committee member, the requesting Party may make temporary Changes to the Services without the prior consent of the other Party. The requesting Party shall notify the other Party as soon as practicable but no later than [***]* after the event of such Change and shall, as soon as reasonably practicable (but no later than [***]* thereafter) document and report in writing on such Changes to the other Party. Any agreed Change as a result shall be agreed in accordance with Change Control Management. Disputes regarding any extra Charges for Changes under this Section 6 are subject to Section 20.01 of the Agreement.
Sample 1Sample 2
Emergency Change Process. In the event that either Party requires a Change in order to respond to an emergency and such Change would, in the reasonable opinion of the requesting Party, if it was not implemented until Change Control Procedures had been followed, have a detrimental effect generally on Customer Group, including without limitation Customer Group’s financial interests, Customer Group’s welfare or public safety, or specifically impacting Provider‘s ability to meet its obligations pursuant to the Agreement, the requesting Party will make all reasonable efforts to contact the other Party’s Authorized Representative, and if the requesting Party is unable to contact the other Party’s Authorized Representative after reasonable efforts, the requesting Party may make temporary Changes to the Services without the prior consent of the other Party. The requesting Party will notify the other Party as soon as practicable but no later than twenty-four (24) hours after the event of such Change and will, as soon as reasonably practicable (but no later than two (2) business days thereafter) document and report in writing on such Changes to the other Party. Any agreed Change as a result will be agreed in accordance with Change Control Procedures. Disputes regarding any additional Fees for Changes under this Section 2.5 are subject to the Dispute resolution process in the Agreement.
Sample 1

Related to Emergency Change Process

  • Change Process Citizens may require changes altering, adding to, or deducting from the Services (each, a “Change”), provided that: (a) such Change is within the general scope of this Agreement; and, (b) Citizens will make an equitable adjustment in Vendor’s compensation or delivery date if a Change materially affects the cost or time of performance of the Services. Such equitable adjustments require the written consent of Vendor, which consent shall not be unreasonably withheld, delayed or conditioned. The Parties will cooperate in good faith to determine the scope and nature of a Change, the availability of Vendor Staff, the expertise and resources to provide such Change, and the time period in which such Change will be implemented.

  • Emergency Conditions “Emergency Condition” shall mean a condition or situation: (1) that in the judgment of the Party making the claim is imminently likely to endanger life or property; or (2) that, in the case of the Transmission Provider, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to the Transmission System, the Transmission Owner’s Interconnection Facilities or the Transmission Systems of others to which the Transmission System is directly connected; or (3) that, in the case of the Interconnection Customer, is imminently likely (as determined in a non-discriminatory manner) to cause a material adverse effect on the security of, or damage to, the Small Generating Facility or the Interconnection Customer’s Interconnection Facilities. Under Emergency Conditions, the Transmission Owner may immediately suspend interconnection service and temporarily disconnect the Small Generating Facility. The Transmission Provider shall notify the Interconnection Customer promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Interconnection Customer’s operation of the Small Generating Facility. The Interconnection Customer shall notify the Transmission Provider promptly when it becomes aware of an Emergency Condition that may reasonably be expected to affect the Transmission Owner’s Transmission System or other Affected Systems. To the extent information is known, the notification shall describe the Emergency Condition, the extent of the damage or deficiency, the expected effect on the operation of both Parties’ facilities and operations, its anticipated duration, and the necessary corrective action.

  • Emergency Contact CONTRACTOR shall have a responsible person available at, or reasonably near, the Project/Service on a twenty-four (24) hour basis, seven (7) days a week, who may be contacted in emergencies and in cases where immediate action must be taken to handle any problem that might arise. CONTRACTOR shall submit to the COUNTY’s Project Manager, the phone numbers and names of personnel designated to be contacted in cases of emergencies. This list shall contain the name of their supervisors responsible for work pertaining to this Agreement.

  • Emergency Contacts Contractor shall provide County with a list of names and telephone numbers at which Contractor’s representative, alternate, superintendent, and other key personnel can be reached during non-working hours in the case of an emergency.

  • Emergency Thresholds The following matrix presents the emergency thresholds that, if reached by any of the services mentioned above for a TLD, would cause the emergency transition of the Registry for the TLD as specified in Section 2.13 of this Agreement. DNS Service (all servers) 4-hour total downtime / week DNSSEC proper resolution 4-hour total downtime / week EPP 24-hour total downtime / week RDDS (WHOIS/Web-based WHOIS) 24-hour total downtime / week Data Escrow Breach of the Registry Agreement as described in Specification 2, Part B, Section 6.

  • Emergency Call-In When an employee is called in to perform unanticipated extra work, and the work is not an extension of his normal workday, he shall be compensated for the hours worked. Such compensation shall be for a minimum of four (4) hours in the event the employee works less than this amount of time. However, actual time worked will be considered for the computation of overtime.

  • Extraordinary Services For any services other than those covered by the aforementioned, a special per hour charge will be made commensurate with the character of the service, time required and responsibility involved. Such services include but are not limited to excessive administrative time, attendance at closings, specialized reports, and record keeping, unusual certifications, etc.

  • Emergency/Declared Disaster Requirements In the event of an emergency or if Orange County is declared a disaster area by the County, state or federal government, this Contract may be subjected to unusual usage. The Contractor shall service the County during such an emergency or declared disaster under the same terms and conditions that apply during non-emergency/disaster conditions. The pricing quoted by the Contractor shall apply to serving the County’s needs regardless of the circumstances. If the Contractor is unable to supply the goods/services under the terms of the Contract, then the Contractor shall provide proof of such disruption and a copy of the invoice for the goods/services from the Contractor’s supplier(s). Additional profit margin as a result of supplying goods/services during an emergency or a declared disaster shall not be permitted. In the event of an emergency or declared disaster, emergency purchase order numbers will be assigned. All applicable invoices from the Contractor shall show both the emergency purchase order number and the Contract number.

  • Emergency Calls IP Phones need an additional power supply to operate. In the event of a power failure it is your responsibility to ensure you have the means to make emergency calls. In accordance with paragraph 13.2, we will not be liable for any loss or damage (financial or otherwise) where you fail to do so.

  • Shift Changes When an employee is assigned to a specific shift and that assignment is changed, the employee shall be given seven (7) calendar days’ notice prior to the change.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!