Extension of Time for Delay Sample Clauses

Extension of Time for Delay. 3.13.1 If the work is delayed at any time by reason of a suspension ordered by the CITY or because of any other act of the CITY, or because of neglect by the CITY without contributory fault or neglect on the part of the CONSULTANT, or if the work should be delayed at any time by reason of strikes, acts of God, the public enemy, acts of the CITY, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, violence of the elements, or for any other unforeseen cause beyond the control and without the fault or negligence of the CONSULTANT, or for any other reason which in the opinion of the CONSULTANT is proper justification for such delay, then the CONSULTANT shall be entitled to an extension of time equivalent to the time actually lost by such delay.
Sample 1See All (4)
AutoNDA by SimpleDocs
Extension of Time for Delay. 3.13.1 If Services are delayed at any time because of a City-ordered suspension, any City action or inaction, or neglect by the City without contributory fault or neglect on the Consultant’s part, or if the Services are delayed at any time by reason of strikes, acts of god, the public enemy, fire, floods, epidemics, quarantine restrictions, freight embargoes, abnormal force, or for any other unforeseen cause beyond the Consultant’s control and without the fault or negligence, or for any other reason in the Consultant’s opinion is proper justification, then the Consultant is entitled to an extension of time equivalent to the time actually lost by such delay.
Sample 1
Extension of Time for Delay. (1) The time fixed for the completion of a contract will not be extended except un­ der the express terms thereof. Stand­ ard Forms Nos. 32 and 33 provide that, in the event of delay in the performance of the contract due to unforeseeable causes beyond the control and without the fault of the contractor, if the con- 704 FEDERAL REGISTER, Saturday, February 17, 1940 tractor shall within 10 days from the beginning of such delay (or within such further period of time as may be granted) notify the contracting officer in writing of the causes of delay, the con­ tracting officer will ascertain the facts and extent of the delay, and his findings of fact xxxxxxx will he final and conclu­ sive on the parties to the contract, sub­ ject only to appeal within 30 days by the contract, and under the liquidated dam­ age article of the supply contract, where activities are suspended by Government orders, liquidated damages are not chargeable for the time intervening be­ tween the effective date of the order for suspension and the effective date of the order to recommence work, or for delivery of the supplies. (See 8 Comp. Gen. 80) ited, but these statutes do not apply where such a contract or claim is trans­ ferred by order of a court in receivership and bankruptcy proceedings, such an assignment being by operation of law See 3 Comp. Gen. 623; 5 id. 592. (R s 3737; 41 U.S.C. 15) [Par. 30, A. R ^ 200, Jan. 2, 1940] [s e a l ] x . X. Xxxxx , Major General, contractor to the head of the department concerned, or his duly authorized repre­
Sample 1

Related to Extension of Time for Delay

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Calculation of Time Periods Unless otherwise specified, in computing any period of time described in this Agreement, the day of the act or event after which the designated period of time begins to run is not to be included and the last day of the period so computed is to be included, unless such last day is a Saturday, Sunday or legal holiday under the laws of the State in which the Property is located, in which event the period shall run until the end of the next day which is neither a Saturday, Sunday or legal holiday. The final day of any such period shall be deemed to end at 5 p.m., local time.

  • Computation of Time Periods In this Agreement in the computation of periods of time from a specified date to a later specified date, the word “from” means “from and including” and the words “to” and “until” each mean “to but excluding”.

  • Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.

  • Extension of Defects Liability Period The Defects Liability Period shall be deemed to be extended till the identified Defects under Clause 17.2 have been remedied or rectified.

  • Application of General Conditions These General Conditions set forth the terms and conditions generally applicable to the Development Grant Agreement to the extent and subject to any modifications set forth in such agreement.”

Time is Money Join Law Insider Premium to draft better contracts faster.