FP Task Orders Sample Clauses

FP Task Orders. Under FP Task Orders, based upon Contractor’s reasonable business judgment, Contractor will perform those tasks necessary to efficiently and effectively perform the Required Change. If mutually agreed, the Project Plan, schedule and FP for the Task Order shall be extended and amended to provide an equitable adjustment. If the parties fail to mutually agree as to Scope or equitable adjustment in schedule or FP for the Change Order, the parties shall submit the failure to agree to dispute resolution pursuant to Section 27, and upon resolution of such proceedings, Services performed after the date of the Required Change shall be tailored in accordance with the resulting decision and a Change Order shall be executed by the parties reflecting any equitable adjustment in Scope, schedule and FP for the Task Order. Either party may call an Emergency Meeting during the pendency of the dispute resolution proceeding to discuss the Change Order, the performance of the Services and the adjusted Project Plan, schedule and FP of the Task Order during which Emergency Meeting the parties will continue to work to reach mutual agreement. It is recognized that not all Required Changes will result in an increase in the FP of a Task Order, but both parties acknowledge and agree that if a Required Change causes an increase in the cost of performance of a Task Order and/or requires additional or different time for delivery of Services, the FP of a Task Order will be equitably adjusted and/or the schedule will be equitably extended (as applicable).
Sample 1
FP Task Orders. Under FP Task Orders, the parties shall promptly submit the matter to dispute resolution in accordance with Section 27. During the pendency of such dispute resolution, Contractor will continue performance of the Services as determined by Contractor in its reasonable business judgment, performing those tasks necessary in Contractor’s judgment to mitigate further delay to the Project Plan. The Project Plan and schedule may be adjusted as necessary based upon Contractor’s reasonable business judgment during the pendency of the dispute resolution. Either party may call an Emergency Meeting during the pendency of the dispute resolution proceeding to discuss the Change Order, the performance of the Services, and/or any adjusted Project Plan, FP and schedule during which Emergency Meeting the parties will continue to work to reach mutual agreement. Upon completion of the dispute resolution proceedings, the parties shall enter into a Change Order in accordance with the dispute resolution determination that equitably compensates Contractor for the Services performed as a result of the Client Delay and equitably adjusts the Project schedule. All Services resulting from the Client Delay shall be tailored in accordance with the decision resulting from resolution of the dispute. For clarity’s sake, the amount of Fees paid to Contractor during the pendency of the dispute resolution shall reduce the amount of Fees that Contractor may collect with regard to the Client Delay. It is recognized that not all Client Delays will result in an increase in the FP of a Task Order, but both parties acknowledge and agree that if a Client Delay causes an increase in the cost of performance of a Task Order or requires additional or different time for delivery of Services, the FP of the Task Order will be equitably adjusted and/or the schedule will be equitably extended (as applicable).
Sample 1

Related to FP Task Orders

  • Task Orders A. Some tasks and Services will be assigned to the Consultant through issuance of Task Orders. After the tasks and Services are identified and communicated to the Consultant by Valley Water Project Manager, Consultant will prepare a proposed Task Order (see Standard Consultant Agreement, Appendix Three Task Order Template). The proposed Task must identify the following: 1) Description of the services, including deliverables; 2) The total Not-to-Exceed Fees for Consultant to complete the services, including estimated number of hours per assigned staff to complete the services; 3) Proposed staff that will be assigned to complete the services, including resumes if not previously provided to Valley Water’s Project Manager; 4) Estimated cost of each other direct cost and reimbursable expense, including any applicable fees; 5) Schedule for completing the services; and 6) Copies of applicable state and federal permits required to complete the services, unless previously provided to Valley Water. B. Consultant agrees that the Not-to-Exceed Fees specified in a proposed Task Order will be the product of a good faith effort in exercising its professional judgment. After an agreement has been reached on the negotiable items, the finalized Task Order will be signed by both Valley Water’s authorized representative referenced in the Standard Consultant Agreement, Appendix One Additional Legal Terms (Appendix One), and Consultant’s authorized representative. C. Consultant must not commence performance of work or services on a Task Order until it has been approved by Valley Water’s authorized representative and Notice to Proceed has been issued by Valley Water Project Manager. No payment will be made for any services performed prior to approval or after the period of performance of the Task Order. The period of performance for Task Orders will be in accordance with dates specified in the Task Order. No Task Order will be written which extends beyond the expiration date of this Agreement. The total amount payable by Valley Water for an individual Task Order will not exceed the amount agreed to in the Task Order.

  • Task Order The Contractor submits a Task Order programme to the Service Manager within 2 days of receiving the Task Order

  • Work Orders If the Contract is for indefinite quantities of Services, as specified in the Signature Document, all Work will be performed in accordance with properly executed Work Orders.

  • Contract Task Order A- E shall be assigned work via a task order by COUNTY which shall subsequently be referred to as the “Contract Task Order” (hereinafter “CTO”). A CTO for each project shall be developed by A-E in conjunction with COUNTY Project Management staff. The County Project Manager shall manage all A-E’s work including monitoring the CTO work schedule, quality of deliverables, review of invoiced amounts, adherence to set budget, and internal review of submittal packages. A-E shall follow all requirements as outlined in the CTO; this general Scope of Work, the project specific Scope Statement, and the Architect-Engineer Guide (Rev July 2018). The CTO shall include a detailed Scope Statement, describing tasks to be performed with a specific list of deliverables for each task, schedule of work and cost to complete the work. The schedule of work shall allow enough time for meetings with County Management staff to review the work progress, provide technical and policy direction, resolve problems and ensure adherence to the work completion schedule. The CTO shall include a cover sheet provided by County Project Management staff with the appropriate signature blocks and contract information. Once both Parties agree, and all Parties have signed the CTO, County Management staff shall provide A-E with a Notice to Proceed (NTP) to begin work. A-E shall submit all plans, reports and other documents produced under the CTO to the assigned County Project Manager within the timeframe indicated in the CTO or as directed by County Project Management staff.

  • Stop Work Orders A. The JBE may, at any time, by Notice to Contractor, require Contractor to stop all or any part of the Services for a period up to ninety (90) days after the Notice is delivered to Contractor, and for any further period to which the parties may agree (“Stop Work Order”). The Stop Work Order shall be specifically identified as such and shall indicate it is issued under this provision. Upon receipt of the Stop Work Order, Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the Services covered by the Stop Work Order during the period of stoppage. Within ninety (90) days after a Stop Work Order is delivered to Contractor, or within any extension of that period to which the parties shall have agreed, the JBE shall either (i) cancel the Stop Work Order; or (ii) terminate the Services covered by the Stop Work Order as provided for in this Agreement. B. If a Stop Work Order issued under this provision is canceled or the period of the Stop Work Order or any extension thereof expires, Contractor shall resume the performance of Services. The JBE shall make an equitable adjustment in the delivery schedule, the Contract Amount, or both, and the Agreement shall be modified, in writing, accordingly, if: i. The Stop Work Order results in an increase in the time required for, or in Contractor’s cost properly allocable to the performance of any part of this Agreement; and ii. Contractor requests an equitable adjustment within thirty (30) days after the end of the period of stoppage; however, if the JBE decides the facts justify the action, the JBE may receive and act upon a proposal submitted at any time before final payment under this Agreement. C. The JBE shall not be liable to Contractor for loss of profits because of a Stop Work Order issued under this provision.

  • Work Order (s) means a detailed scope of work for a Service required by Transnet, including timeframes, Deliverable, Fees and costs for the supply of the Service to Transnet, which may be appended to this Agreement from time to time.

  • Service Orders Service Order shall state the Customer’s minimum committed term of the Services arising thereunder from the date that such Services are made available to the Customer (“Initial Term”); if the Initial Term is not expressly stated in the Service Order, the Initial Term of the Services shall be deemed to be for a twelve (12) month term from the date that the Services are made available to the Customer. Unless a Party notifies the other Party of its intention not to renew the Services at least sixty (60) days prior the end of the Initial Term or then current term (“Term”), the Services shall automatically renew for subsequent twelve (12) month terms under the same terms and conditions except that the Fees may be adjusted to reflect Aptum’s then current pricing for such Services. Cancellation of any Service Order or a particular Service thereunder must be made by way of a cancellation request in writing or through a service ticket in accordance with the applicable Product Terms.

  • Stop Work Order (a) NYSERDA may at any time, by written Order to the Contractor, require the Contractor to stop all or any part of the Work called for by this Agreement for a period of up to ninety (90) days after the Stop Work Order is delivered to the Contractor, and for any further period to which the parties may agree. Any such order shall be specifically identified as a Stop Work Order issued pursuant to this Section. Upon receipt of such an Order, the Contractor shall forthwith comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the Work covered by the Order during the period of work stoppage consistent with public health and safety. Within a period of ninety (90) days after a Stop Work Order is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, NYSERDA shall either: (i) by written notice to the Contractor, cancel the Stop Work Order, which shall be effective as provided in such cancellation notice, or if not specified therein, upon receipt by the Contractor, or (ii) terminate the Work covered by such order as provided in the Termination Section of this Agreement. (b) If a Stop Work Order issued under this Section is cancelled or the period of the Order or any extension thereof expires, the Contractor shall resume Work. An equitable adjustment shall be made in the delivery schedule, the estimated cost, the fee, if any, or a combination thereof, and in any other provisions of the Agreement that may be affected, and the Agreement shall be modified in writing accordingly, if: (i) the Stop Work Order results in an increase in the time required for, or in the Contractor’s cost properly allocable to, the performance of any part of this Agreement, and (ii) the Contractor asserts a claim for such adjustments within 30 days after the end of the period of Work stoppage; provided that, if NYSERDA decides the facts justify such action, NYSERDA may receive and act upon any such claim asserted at any time prior to final payment under this Agreement. (c) If a Stop Work Order is not cancelled and the Work covered by such Order is terminated, the reasonable costs resulting from the Stop Work Order shall be allowed by equitable adjustment or otherwise. (d) Notwithstanding the provisions of this Section 12.01, the maximum amount payable by NYSERDA to the Contractor pursuant to this Section 12.01 shall not be increased or deemed to be increased except by specific written amendment hereto.

  • Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.

  • Statements of Work From time to time, the Parties may execute statements of work that describe the specific services to be performed by Modernizing Medicine, including any work product to be delivered by Modernizing Medicine (as executed by the Parties, a “Statement of Work”). Each Statement of Work will expressly refer to this Agreement, will form a part of this Agreement, and will be subject to the terms and conditions contained herein.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!