TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.
Dismissal or Suspension Grievances (a) In the case of a dispute arising from an employee’s dismissal, the grievance may be filed directly at Step 3, within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
(b) In the case of a dispute arising from an employee’s suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within (30) days of the employee receiving notice of suspension.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
Notice of Certain Events Affecting Registration; Suspension of Right to Make an Advance The Company will immediately notify the Investor upon its becoming aware of the occurrence of any of the following events in respect of a registration statement or related prospectus relating to an offering of Registrable Securities: (i) receipt of any request for additional information by the SEC or any other Federal or state governmental authority during the period of effectiveness of the Registration Statement for amendments or supplements to the registration statement or related prospectus; (ii) the issuance by the SEC or any other Federal or state governmental authority of any stop order suspending the effectiveness of the Registration Statement or the initiation of any proceedings for that purpose; (iii) receipt of any notification with respect to the suspension of the qualification or exemption from qualification of any of the Registrable Securities for sale in any jurisdiction or the initiation or threatening of any proceeding for such purpose; (iv) the happening of any event that makes any statement made in the Registration Statement or related prospectus of any document incorporated or deemed to be incorporated therein by reference untrue in any material respect or that requires the making of any changes in the Registration Statement, related prospectus or documents so that, in the case of the Registration Statement, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein not misleading, and that in the case of the related prospectus, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading; and (v) the Company's reasonable determination that a post-effective amendment to the Registration Statement would be appropriate; and the Company will promptly make available to the Investor any such supplement or amendment to the related prospectus. The Company shall not deliver to the Investor any Advance Notice during the continuation of any of the foregoing events.
Post Suspension 1. Without prejudice to the procedures in Article 190 (Examination of the Benefit Suspension Level), if the Party complained against considers that it has eliminated the non-conformity that the Panel has found, it may provide written notice to the complaining Party with a description of how non-conformity has been removed. If the complaining Party has disagreement, it may refer the matter to the original Panel within 60 days after receipt of such written notice. Otherwise, the complaining Party shall promptly stop the suspension of benefits.
2. The Panel shall release its report within 60 days after the referral of the matter. If the Panel concludes that the Party complained against has eliminated the non-conformity, the complaining Party shall promptly stop the suspension of benefits.
Dismissal or Suspension Grievance (a) In the case of a dispute arising from an employee's dismissal, the grievance may be filed directly at arbitration within thirty (30) days of the date on which the dismissal occurred, or within thirty (30) days of the employee receiving notice of dismissal.
(b) In the case of a dispute arising from an employee's suspension, the grievance may commence at Step 2 of the grievance procedure within thirty (30) days of the date on which the suspension occurred, or within thirty (30) days of the employee receiving notice of suspension.
Notice of Adjustments and Certain Other Events (a) Whenever the Fixed Settlement Rates are adjusted as herein provided, the Company shall, as soon as practicable following the occurrence of an event that requires an adjustment pursuant to Section 5.05 (or if the Company is not aware of such occurrence, as soon as practicable after becoming so aware):
(i) compute each adjusted Fixed Settlement Rate in accordance with Section 5.05 and prepare and transmit to the Purchase Contract Agent an Officers’ Certificate setting forth each adjusted Fixed Settlement Rate, the method of calculation thereof in reasonable detail, and the facts requiring such adjustment and upon which such adjustment is based; and
(ii) provide a written notice to the Holders of the Units of the occurrence of such event and a statement in reasonable detail setting forth the method by which the adjustment to each Fixed Settlement Rate was determined and setting forth each adjusted Fixed Settlement Rate.
(b) The Purchase Contract Agent shall not at any time be under any duty or responsibility to any Holder to determine whether any facts exist which may require any adjustment of each Fixed Settlement Rate, or with respect to the nature or extent or calculation of any such adjustment when made, or with respect to the method employed in making the same. The Purchase Contract Agent shall be fully authorized and protected in relying on any Officers’ Certificate delivered pursuant to Section 5.06(a)(i) and any adjustment contained therein and the Purchase Contract Agent shall not be deemed to have knowledge of any adjustment unless and until it has received such certificate. The Purchase Contract Agent shall not be accountable with respect to the validity or value (or the kind or amount) of any shares of Common Stock, or of any securities or property, which may at the time be issued or delivered with respect to any Purchase Contract; and the Purchase Contract Agent makes no representation with respect thereto. The Purchase Contract Agent shall not be responsible for any failure of the Company to issue, transfer or deliver any shares of Common Stock pursuant to a Purchase Contract or to comply with any of the duties, responsibilities or covenants of the Company contained in this Article 5.
Termination; Suspension Your right to use the Online Backup Feature will terminate on expiration of the Service Period. Symantec may immediately suspend or terminate use of the Online Backup Feature during the Service Period for Your failure to or Symantec’s reasonable belief that You have failed to comply with these terms and conditions (other than a trivial or inconsequential breach) or any other misuse of the Online Backup Feature. Following the expiration or termination of the Service Period: Symantec may permanently delete any Data stored to the online backup space provided with Your Software and Services ; Symantec will not be obligated to maintain such Data, forward such Data to You or a third party, or migrate such Data to another backup service or account; and You will not be able to store the Data to any additional backup space that You may have purchased separately unless and until the Service Period is renewed.
Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.
Service Suspension 8.1 By giving reasonable notice to you, or if this is not practicable, such notice as is reasonably practicable in the circumstances, we may suspend the Service (or any part of the Service) for reasons to include but not limited to:
8.1.1 for operational reasons in accordance with the service levels, or
8.1.2 if required because of a regulatory or legal change, or
8.1.3 if we are obliged to comply with the order, instruction, or request of a court, government, agency, emergency service organisation, or other competent administrative or regulatory authority, requiring suspension to the Service, or
8.1.4 if your use of the Service may damage or disrupt the proper functioning of the infrastructure and / or equipment used to provide services to our other Customers, or
8.1.5 if we have reasonable grounds to believe that you are in breach of your obligations, and you either fail to remedy that breach or fail to demonstrate to our reasonable satisfaction that no breach took place within two (2) Working Days of written notice of the suspected breach for a serious breach (serious breach to include, but not limited to, a breach likely to cause serious damage to us or our brand, or that of our contractors, or result in legal action by a third party) or within ten (10) Working Days of written notice of the suspected breach for other breach, or
8.1.6 if an undisputed invoice (or an undisputed part of an invoice) is not paid in full by the due date, provided that we have given you at least five (5) Working Days’ notice of such non- payment.
8.2 Suspension of the Service shall cause our service level obligations to be excluded for the period of the suspension. Such suspension of the Service shall continue for as long as any of the circumstances in Clauses 8 continues.
