Indemnification for Third Party Claims
(a) Seller shall defend, indemnify and hold harmless Buyer, its shareholders and Affiliates, and their respective directors, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance by any Project Party of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Seller, the Contractor, any Subcontractor, and its respective employees or agents.
(b) Buyer shall defend, indemnify and hold harmless Seller and its managers, officers, employees and agents, from and against all third party Claims and Liabilities for injury, including death, and property damage caused by, arising out of, or in connection with the performance of the Transaction Documents to the extent any of such Claims or Liabilities were caused by the negligence, gross negligence or willful misconduct of Buyer, its employees or agents.
(c) Either Party seeking indemnification under this Agreement (the “Indemnified Party”) shall give notice to the Party required to provide indemnification hereunder (the “Indemnifying Party”) promptly after the Indemnified Party has actual knowledge of any Claim as to which indemnity may be sought hereunder, and the Indemnified Party shall permit the Indemnifying Party (at the expense of the Indemnifying Party) to assume the defense of any Claim or litigation resulting therefrom; provided that:
(i) counsel for the Indemnifying Party who shall conduct the defense of such Claim or litigation shall be reasonably satisfactory to the Indemnified Party;
(ii) the Indemnified Party may participate in such defense at its own expense, except the Indemnifying Party shall reimburse the Indemnified Party for its participation in such defense to the extent that the Indemnifying Party requests the Indemnified Party to participate in its own defense; and
(iii) the omission by the Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligations hereunder except to the extent that such omission results in a failure of actual notice to the Indemnifying Party and Indemnifying Party is damaged as a result of such failure to give notice. Notwithstanding the foregoing, the Indemnifying Party may not settle any Claim related to the indemnity being provided hereunder without the consent of the Indemnified Party, such consent not to be unreasonably withheld.
(d) With regard to any Claim or Liability which is the result of the joint or concurrent fault or negligence of Seller and Buyer, the Parties agree to jointly defend any Claim with respect thereto that is based on such joint or concurrent fault or negligence of Buyer and Seller. Any Claim of contribution or indemnification between Buyer and Seller relating to such Claims shall be resolved on the basis of the percentage of fault or negligence and the Parties agree to reserve the determination of such percentage until after resolution of such Claim. Such pro rata share shall be based upon a final judicial determination of the Parties’ comparative fault or negligence or, in the absence of such determination, by mutual agreement.
(e) Nothing in this Section 26.1 is intended to allow any Indemnified Party to be indemnified from and against any third party Claims and Liabilities caused by, arising out of, or in connection with the performance of this Agreement to the extent any of such Claims or Liabilities were caused by, arose out of, or were in any way incidental to or in connection with its own negligence or intentional misconduct.
Indemnification by Contractor To the fullest extent permitted by law, the CONTRACTOR agrees to indemnify, defend and hold the COUNTY and its departments, elected and appointed officials, employees, agents and volunteers, harmless from and against any and all claims, damages, losses and expenses, including but not limited to court costs, attorney’s fees and alternative dispute resolution costs, for any personal injury, for any bodily injury, sickness, disease or death and for any damage to or destruction of any property (including the loss of use resulting therefrom) which 1) are caused in whole or in part by any action or omission, negligent or otherwise, of the CONTRACTOR, its employees, agents or volunteers or CONTRACTOR’s subcontractors and their employees, agents or volunteers; or 2) are directly or indirectly arising out of, resulting from, or in connection with performance of this Contract; or 3) are based upon the CONTRACTOR’S or its subcontractors’ use of, presence upon or proximity to the property of the COUNTY. This indemnification obligation of the CONTRACTOR shall not apply in the limited circumstance where the claim, damage, loss or expense is caused by the sole negligence of the COUNTY. This indemnification obligation of the CONTRACTOR shall not be limited in any way by the Washington State Industrial Insurance Action RCW Title 51, or by application of any other workmen’s compensation act, disability benefit act or other employee benefit act, and the CONTRACTOR hereby expressly waives any immunity afforded by such acts. The foregoing indemnification obligations of the CONTRACTOR are a material inducement to COUNTY to enter into the Contract, are reflected in the CONTRACTOR’s compensation, and have been mutually negotiated by the parties.
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Indemnification Process and Appeal (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request to the Secretary of the Company, including therein or therewith such documentation and information as is reasonably available to Indemnitee and is reasonably necessary to determine whether and to what extent Indemnitee is entitled to indemnification. The Secretary of the Company shall, promptly upon receipt of such a request for indemnification, advise the Board in writing that Indemnitee has requested indemnification.
(b) Upon written request by Indemnitee for indemnification pursuant to the first sentence of Section 4(a) hereof, a determination, if required by applicable law, with respect to Indemnitee's entitlement thereto shall be made in the specific case: (i) if a Change in Control shall have occurred, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee; or (ii) if a Change of Control shall not have occurred, (A) by a majority vote of the Disinterested Directors, even though less than a quorum of the Board, or (B) if there are no such Disinterested Directors and, if required by applicable law, or, if such Disinterested Directors so direct, by Independent Counsel in a written opinion to the Board, a copy of which shall be delivered to Indemnitee or (C) if so directed by the Board, by the stockholders of the Company (any such party referenced in (A), (B) or (C) above is referred to herein as the "Reviewing Party"); and, if it is so determined that Indemnitee is entitled to indemnification, payment to Indemnitee shall be made within ten (10) days after such determination. Indemnitee shall cooperate with the person, persons or entity making such determination with respect to Indemnitee's entitlement to indemnification, including providing to such person, persons or entity upon reasonable advance request any documentation or information which is not privileged or otherwise protected from disclosure and which is reasonably available to Indemnitee and reasonably necessary to such determination. Such determination shall be made as promptly as is reasonably practicable, taking into account all facts and circumstances. Any reasonable costs or expenses (including reasonable attorneys' fees and disbursements) actually incurred by Indemnitee in so cooperating with the person, persons or entity making such determination shall be borne by the Company (irrespective of the determination as to Indemnitee's entitlement to indemnification) and the Company hereby indemnifies and agrees to hold Indemnitee harmless therefrom.
(c) In the event the determination of entitlement to indemnification is to be made by Independent Counsel pursuant to Section 4(b) hereof, the Independent Counsel shall be selected as provided in this Section 4(c). If a Change of Control shall not have occurred, the Board shall select the Independent Counsel, and the Company shall give written notice to Indemnitee advising him of the identity of the Independent Counsel so selected. If a Change of Control shall have occurred, the Independent Counsel shall be selected by Indemnitee (unless Indemnitee shall request that such selection be made by the Board, in which event the preceding sentence shall apply), and Indemnitee shall give written notice to the Company advising it of the identity of the Independent Counsel so selected. In either event, Indemnitee or the Company, as the case may be, may, within ten (10) days after such written notice of selection shall have been given, deliver to the Company or to Indemnitee, as the case may be, a written objection to such selection; provided, however, that such objection may be asserted only on the ground that the Independent Counsel so selected does not meet the requirements of "Independent Counsel" as defined in Section 1 of this Agreement, and the objection shall set forth with particularity the factual basis of such assertion. If such written objection is so made and substantiated, the Independent Counsel so selected may not serve as Independent Counsel unless and until such objection is withdrawn or a court has determined that such objection is without merit. If, within 20 days after submission by Indemnitee of a written request for indemnification pursuant to Section 4(a) hereof, no Independent Counsel shall have been selected and not objected to, either the Company or Indemnitee may petition any court of competent jurisdiction for resolution of any objection which shall have been made by the Company or Indemnitee to the other's selection of Independent Counsel and/or for the appointment as Independent Counsel of a person selected by the court or by such other person as the court shall designate, and the person with respect to whom all objections are so resolved or the person so appointed shall act as Independent Counsel under Section 4(b) hereof. The Company shall pay any and all reasonable fees and Expenses of Independent Counsel incurred by such Independent Counsel in connection with acting pursuant to Section 4(b) hereof, and the Company shall pay all reasonable fees and Expenses incident to the procedures of this Section 4(c), regardless of the manner in which such Independent Counsel was selected or appointed. Upon the due commencement of any judicial proceeding or arbitration pursuant to Section 4(d) of this Agreement, Independent Counsel shall be discharged and relieved of any further responsibility in such capacity (subject to the applicable standards of professional conduct then prevailing).
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Indemnification by Lessee Lessee agrees to indemnify, defend, protect, save and keep harmless Lessor and its Affiliates, and their respective officers, directors, shareholders, unitholders, members, partners, managers, agents, employees, representatives, successors and assigns (collectively, the “Lessor Indemnified Parties”) from and against any and all Claims which may be imposed on, incurred by or asserted against the Lessor Indemnified Parties, in any way and to the extent relating to or arising out of (a) any failure to perform any covenant or agreement made or undertaken by Lessee in this Lease, or (b) the exercise of Lessee’s Parties’ rights under Section 2.2(a); provided, however, Lessee shall not have any obligation to indemnify the Lessor Indemnified Parties for any such Claim under clauses (a) or (b) to the extent resulting from or arising out of the willful misconduct or negligence of any of the Lessor Indemnified Parties. To the extent that the Lessor Indemnified Parties in fact receive full indemnification payments from Lessee under the indemnification provisions of this Section 10.2, Lessee shall be subrogated to the Lessor Indemnified Parties’ rights with respect to the transaction or event requiring or giving rise to such indemnity. NOTWITHSTANDING ANYTHING CONTAINED IN THIS LEASE TO THE CONTRARY, IN NO EVENT SHALL LESSEE BE LIABLE FOR INCIDENTAL, INDIRECT, SPECIAL, PUNITIVE, EXEMPLARY OR CONSEQUENTIAL DAMAGES, LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES IN TORT, CONTRACT OR OTHERWISE UNDER OR ON ACCOUNT OF THIS LEASE, EXCEPT THOSE PAYABLE TO THIRD PARTIES FOR WHICH LESSEE WOULD BE LIABLE UNDER THIS SECTION.
Tenant’s Indemnification Tenant shall indemnify Landlord and Landlord’s managing agent from any and all claims, losses, liabilities, costs, expenses and damages, including attorneys’ fees, costs of testing and remediation costs, incurred by Landlord in connection with any breach by Tenant of its obligations under this Article 15. The covenants and obligations under this Article 15 shall survive the expiration or earlier termination of this Lease.
Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.
20.2.2 An Indemnifying Party’s obligations under Section 20.1 shall be conditioned upon the following:
Additional Indemnification Rights Non Exclusivity a. Notwithstanding any other provision of this Agreement, the Company hereby agrees to indemnify the Indemnitee to the fullest extent permitted by law, notwithstanding that such indemnification is not specifically authorized by the other provisions of this Agreement, the Articles, the By-Laws or by statute.
b. The provisions for indemnification and advancement of expenses set forth in the Agreement shall not be deemed exclusive of any other rights which Indemnitee may have under any provision of law, the Articles, the By-laws, the vote of the Company’s shareholders or disinterested directors, insurance policies, other agreements or otherwise; and nothing in this Agreement shall be used to interpret or otherwise affect such other rights. Indemnitee’s rights hereunder shall continue after Indemnitee has ceased acting as a director, officer, employee or agent of the Company and shall inure to the benefit of the heirs, executors and administrators of Indemnitee. However, no amendment or alteration after the Effective Date of the Articles or By-laws or any other agreement shall adversely affect the rights provided to Indemnitee under the Agreement.
