Cost of the Work The sum of all allowable costs necessarily incurred and paid by Contractor in the proper performance of the Work.
SCOPE OF THE WORK The Contractor shall furnish all the materials, perform all of the Work, and do all things required by the Contract Documents.
Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.
THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.
Performance of the Work The Contractor shall perform all of the Work required for the complete and prompt execution of everything described or shown in, or reasonably implied from the Contract Documents for the above referenced Project.
Acceptance of the Work 19.1 The Contractor shall correct any Work that fails to conform to the requirements of the Contract Documents where such failure to conform appears during the progress of the Work, and shall remedy any defects due to faulty permitting, design, materials, equipment or workmanship which appear within a period of one year from the Date of Final Settlement of the Contract or within such longer period of time as may be prescribed by law or by the terms of any applicable special guarantee required by the Contract Documents. The provisions of this Article apply to Work done by Subcontractors as well as to Work done by direct employees of the Contractor, and are in addition to any other remedies or warranties provided by law.
19.2 No act of, or failure to act by, the Owner or the Owner's Representative, either in superintending or directing the Work, or any extension of time for the completion of the Work, shall be regarded as an acceptance of such Work or any part thereof, or of materials used therein, either wholly or in part. Acceptance shall be evidenced only by the final certificate of the Owner. Before any final certificate shall issue, Contractor shall execute an affidavit on the certificate that it accepts the same in full payment and settlement of all claims on account of Work done and materials furnished under this Contract, and that all claims for materials provided or labor performed have been paid or set aside in full. No waiver of any breach of this Contract by the Owner or anyone acting on Owner's behalf shall be held as a waiver of any other subsequent breach thereof.
19.3 Contractor agrees to guarantee all work under this Contract for the periods specified in the RFP from the date of Final Settlement by the Owner. If any unsatisfactory condition or damage develops within the time of this guaranty due to permitting, design, materials or workmanship that are defective, inferior, or not in accordance with the Contract, as reasonably determined by the Owner or the Owner’s Representative, then the Contractor shall, when notified by the Owner or OR, immediately place such guaranteed Work in a condition satisfactory to the Owner or OR.
Installation When installation is required, the Contractor shall be responsible for placing and installing the Commodities or parts in the required locations at no additional charge. All materials used in the installation shall be of good quality and shall be free of defects that would diminish the appearance of the Commodity or render it structurally or operationally unsound. Installation includes the furnishing of any equipment, tools, rigging, labor, and materials required to install or replace the Commodities or parts in the proper location. Contractor shall protect the site from damage and shall repair damages or injury caused during installation by Contractor or its employees or agents. If any alteration, dismantling, excavation, etc., is required to achieve installation, the Contractor shall promptly restore the structure or site to its original condition. Contractor shall perform installation work so as to cause the least inconvenience and interference with Customers and with proper consideration of others on site. Upon completion of the installation, the location and surrounding area of work shall be left clean and in a neat and unobstructed condition, with everything in satisfactory repair and order.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Outside Work All work necessary to the assembling, installation, erection, operation, maintenance, repair, control, in- spection and supervision of all electrical apparatus, devices, wires, cables, supports, insulators, conduc- tors, ducts and raceways when part of distributing systems outside of buildings, railroads and outside the directly related railroad property and yards. In- stalling and maintaining the catenary and trolley work on railroad property, and bonding of rails. All underground ducts and cables when they are in- stalled by and are part of the system of a distrib- uting company, except in power stations during new construction, including ducts and cables to adjacent switch racks or substations. All outdoor substations and electrical connections up to and including the setting of transformers and the connecting of the secondary buses thereto. Outside work to include renewable electrical energy sources such as solar photovoltaic, geothermal, wind, biomass, wave, etc., and other distributed en- ergy installations such as fuel cells, microturbines, etc.
Removal of Improvements All items of Landlord’s construction, all heating, ventilating and air conditioning equipment and all permanent improvements installed by Landlord shall be the property of Landlord and shall not be removed from the Leased Premises without the prior written consent of Landlord. All trade fixtures, furniture, furnishings and signs installed in the Leased Premises by Xxxxxx and paid for by Tenant shall remain the property of Tenant, and may be removed upon the expiration of the Term of this Lease, provided that:
i. Tenant shall have fully performed all of the covenants, conditions and provisions to be performed by Tenant under this Lease; and
ii. Tenant repairs any damage to the Leased Premises or the Building caused by such removal and restores the Leased Premises to the condition that existed on the commencement date of this Lease, reasonable wear and tear excepted. If Tenant fails to remove any such items from the Leased Premises within thirty (30) days after the expiration or earlier termination of this Lease, all such trade fixtures, furniture, furnishings and signs shall, at Landlord’s options, become the property of Landlord, unless Landlord elects to require their removal, in which case Tenant shall promptly remove the same and restore the Leased Premises to its prior condition. If Tenant fails to promptly remove the same, Landlord may remove and store such items at the expense of Tenant.
