Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety Agreement attached as Exhibit E-1, the Department of Industrial Relations Reporting Form attached as Exhibit E-2, and the Workers Compensation Acknowledgement attached as Exhibit E-3 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoisting and otherwise handling its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect those engaged or employed in the work, or the materials used in the work, or which in any way affect the conduct of work, and of all such orders and decrees of bodies or tribunals having any jurisdiction or authority over the same. • Observe and comply with, and cause all of its agents and employees to observe and comply with, all such applicable laws; and shall protect and indemnify the City, and all elected officials, officers, em...
Conduct of the Work. A. The work must be completed in a continuous uninterrupted operation. The Contractor must use sufficient workforce and adequate equipment to complete all the necessary work requirements within a minimum period of time.
Conduct of the Work. Contractor shall: • Do all things necessary to faithfully perform and complete the Work in a competent manner. • All work shall be performed by experienced personnel directly employed and supervised by the Contractor. The Contractor shall provide management and technical supervision daily through competent supervisor as required. • The Contractor shall be responsible for the skills, methods and actions of all employees. • The Contractor shall cooperate to enable the Administrator to determine the Contractor’s conformity with these specifications and the adequacy of the work being performed. The Contractor shall give personal daily supervision of the work and be available for consultation with the Administrator or an engineer or inspector designated by Administrator. • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four (24) hours' notice to Contractor, clean up the site and deduct the cost from the Contract Price. • For projects scheduled to require more than three (3) days to complete, prepare and submit a written daily activity report to City for each day on which work is performed, including weekends and holidays when worked, and submit the reports to the City no later than the next day that the City is open for business. The daily reports shall, at a minimum, include the following information: construction activities and locations, start or completion of activities, progress on construction activities (including units or portions of work completed), tests or inspections performed, deliveries of material or equipment, delays or potential delays, visitors to the site, weather conditions, construction equipment used, and personal injuries or damage to property. • Unload, hoist and otherwise handle its own materials, supplies and equipment. • Keep itself fully informed of all applicable laws including existing and future state and federal laws and county and municipal ordinances and regulations which in any manner affect thos...
Conduct of the Work. 11.1 SUBCONTRACTOR agrees to be bound by all rules and regulations of Federal, State and local laws, codes And ordinances applicable to the Work.
Conduct of the Work. Contractor shall: • Prior to the start of Work, submit to the Administrator, the Contractor Safety agreement attached as Exhibit A-2, the Department of Industrial Relations Reporting form attached as Exhibit A-3, and the Workers Compensation Acknowledgement attached as Exhibit A-4 each signed by an authorized representative of Contractor • Submit all required samples, product data, certificates, operations and maintenance instructions, guarantees, and other submittals no later than five (5) days after the date the City issues a Notice to Proceed. • Ensure all necessary permits and approvals for the Work have been obtained. • Protect all materials to be used in the Work in accordance with the specifications. • Protect existing facilities and personal property. • Remove from the project site all debris resulting from performance of the Work no less often than daily. If Contractor fails to do so, City may, after twenty-four
Conduct of the Work. Dendreon shall undertake and conduct the work, including the Clinical Trials, as set forth in the Collaboration Research Plan in accordance with appropriate standards articulated in current good clinical practices (GCP), current good manufacturing practices (GMP) and current good laboratory practices (GLP). Dendreon will use reasonable efforts to carry out the work in accordance with the Collaboration Research Plan.
Conduct of the Work. Except as otherwise provided in this Article XIV, the conditions under which any Work is to be performed and the method of proceeding with and performing the same shall be governed by all of the provisions of Article IX hereof.
Conduct of the Work. Contractor shall give efficient supervision to the work using his best skills and attention. He shall carefully review and compare all drawings, specifications and other instructions and shall at once report to the Owner any error, discrepancy or omission that he may discover. The contractor shall coordinate his work with other trades, and in particular the maintenance operation on existing landscape areas. Contractor shall confine its operations to the area of work and to the areas allotted Contractor by Owner for material and equipment storage. During the work, Owner shall erect proper protective devices to warn and/or prevent the general public and maintenance personnel of and from the danger of construction activities. Contractor shall be responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the work. Contractor shall take all reasonable precautions for the safety of, and shall provide all reasonable protection to prevent damage, injury or loss to (1) all Contractor’s and Subcontractor’s employees on the work, Owner’s employees, members of the general public, and other persons who may be affected thereby, (2) all the work and all materials and equipment to be incorporated therein, and (3) other property at the site or adjacent thereto. The contractor shall be responsible for all risk of loss for all supplies, materials and equipment delivered and stored on site which may or may not be incorporated into the work, until final acceptance of the completed project.
Conduct of the Work. 2.01. All services to be performed by Construction Manager following the Consultancy (hereinafter referred to as the "Services") shall be performed as agent of Owner.
Conduct of the Work. 3.1 CDKX shall carry out the Work with all due and reasonable diligence and despatch.
