Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
LESSEE'S DEFAULT (i) If Lessee shall default in the payment of the Fixed Annual Rent, any additional rent or any other sums payable by Lessee herein when due, and such default shall continue for a period of five (5) days after written notice, or (ii) if Lessee shall default in the performance of any nonmonetary covenants or agreements of this Lease and said default shall continue for twenty (20) days after written notice thereof, or in the event that the default be of such a nature as cannot with diligent effort be cured within said twenty (20) day period, if Lessee shall not commence to cure within said period and diligently prosecute remedial efforts to completion within a reasonable time thereafter, not to exceed sixty (60) (iii) if Lessee should become bankrupt or insolvent or any debtor proceedings be taken by or against Lessee or (iv) if Lessee shall abandon or vacate the Premises prior to the expiration of the term of this Lease, then and in addition to any and all other legal remedies and rights available to Lessor at law or in equity, Lessor may: A. Declare the entire balance of fixed Annual Rent due hereunder for the remainder of the term of this Lease to be due and payable and may collect the same by distress or otherwise; B. Terminate this Lease and any right of renewal thereof, and retake possession of the Premises; C. Without terminating this Lease, re-enter and re-let the Premises, or any part thereof, with or without legal process, as the agent and for the account of Lessee, upon such terms and conditions as Lessor may deem advisable or satisfactory, in which event the rents received on such re-letting shall be applied first to the expenses of such re-letting and collection including but not limited to, necessary renovation and alterations of the Premises, reasonable attorney’s fees, any real estate commissions paid, and thereafter toward payment of all sums due or to become due Lessor hereunder, and if a sufficient sum shall not be thus realized or secured to pay such sums and other charges, (i) at Lessor’s option, Lessee shall pay Lessor any deficiency immediately upon demand therefor, notwithstanding Lessor may have received periodic rental in excess of the periodic rental stipulated in this Lease in previous or subsequent rental periods, and Lessor may bring an action therefor as such deficiency shall arise, or (ii) at Lessor’s option, the entire deficiency, which is subject to ascertainment for the remaining term of this Lease, shall be immediately due and payable by Lessee. Lessor shall use commercially reasonable efforts to re-let the Premises. Lessor shall not, in any event, be required to pay Lessee any surplus of any sums received by Lessor on a re-letting of said Premises in excess of the rent provided in this Lease. D. If any Event of Default occurs, Lessor, in addition to other rights and remedies it may have, shall have the right to remove all or any part of Lessee’s property from the Premises and any property removed may be stored in any public warehouse or elsewhere at the cost of, and for the account of Lessee and the Lessor shall not be responsible for the care or safekeeping thereof whether in transport, storage or otherwise, and Lessee hereby waives any and all claim against Lessor for loss, destruction and/or damage or injury which may be occasioned by any of the aforesaid acts. Lessee shall, upon execution of this Lease and promptly thereafter from time to time, give Lessor notice of any leased personal property brought onto the Premises. E. No such re-entry or taking possession of the Premises by Lessor shall be construed as an election on Lessor’s part to terminate this Lease unless a written notice of such intention is given to Lessee. Notwithstanding any such re-letting without termination. Lessor may at all times thereafter elect to terminate this Lease for such previous default. Any such re-entry shall be allowed by Lessee without hindrance, and Lessor shall not be liable in damages for any such re-entry, or guilty of trespass or forcible entry except for damages or injury caused by intentional misconduct. F. In the event of a breach or threatened breach of any covenant of this Lease, Lessor shall have the right of injunction. Any and all rights, remedies and options given in this Lease to Lessor shall be cumulative and in addition to and without waiver of, or in derogation of, any right or remedy given to it under any law now or hereafter in effect or in equity. G. If Lessee shall default in the performance of any provision of this Lease on Lessee’s part to be performed, Lessor may perform the same for the account of Lessee and Lessee shall promptly reimburse Lessor for any expense incurred therefor, which expenses shall be deemed to be additional rent.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
THE RENT Rent: £0.00 (zero pounds) per calendar month subject to any further provisions within this Tenancy Agreement Payable: each month in advance
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work. Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
LANDLORD The covenants and obligations contained in this Lease on the part of Landlord are binding on Landlord, its successors, and assigns only during their respective period of ownership of an interest in the Building. In the event of any transfer or transfers of such title to the Building, Landlord (and, in the case of any subsequent transfers or conveyances, the then grantor) shall be concurrently freed and relieved from and after the date of such transfer or conveyance, without any further instrument or agreement, of all liability with respect to the performance of any covenants or obligations on the part of Landlord contained in this Lease thereafter to be performed.
Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises. Notwithstanding anything to the contrary contained in this Lease, as of the Rent Commencement Date, the maintenance and repair obligations for the Premises shall be allocated between Landlord and Tenant as set forth on Exhibit H attached hereto. The maintenance obligations allocated to Tenant pursuant to Exhibit H (the “Tenant Maintenance Obligations”) shall be performed by Tenant at Tenant’s sole cost and expense. The Tenant Maintenance Obligations shall include the procurement and maintenance of contracts, in form and substance reasonably satisfactory to Landlord, with copies to Landlord upon Landlord’s written request, for and with contractors reasonably acceptable to Landlord specializing and experienced in the respective Tenant Maintenance Obligations. Notwithstanding anything to the contrary contained herein, the scope of work of any such contracts entered into by Tenant pursuant to this paragraph shall, at a minimum, comply with manufacturer’s recommended maintenance procedures for the optimal performance of the applicable equipment. Landlord shall, notwithstanding anything to the contrary contained in this Lease, have no obligation to perform any Tenant Maintenance Obligations. The Tenant Maintenance Obligations shall not include the right or obligation on the part of Tenant to make any structural and/or capital repairs or improvements to the Project, and Landlord shall continue, as part of Operating Expenses, to be responsible, as provided in Section 13, for capital repairs and replacements required to be made to the Project. If Tenant fails to maintain any portion of the Premises for which Tenant is responsible as part of the Tenant Maintenance Obligations in a manner reasonably acceptable to Landlord within the requirements of this Lease, Landlord shall have the right, but not the obligation, to provide Tenant with written notice thereof and to assume the Tenant Maintenance Obligations if Tenant does not cure Tenant’s failure within 10 days after receipt of such notice.
Lessee The related Lessee is a Person other than MBFS USA, any Affiliate thereof or a Governmental Authority and, at the time of origination of the 201[__]-[__] Lease, based on information provided by the Lessee, the Lessee is located in and has a billing address within a State.
Tenant Except as otherwise expressly required of Landlord, Tenant shall, at Tenant’s expense, keep and maintain the Premises, including but not limited to all entry doors, damage to entry doors occasioned by theft or vandalism, furnishings, lighting, trade fixtures, above-ground plumbing and conduits beginning at the point of entry into the Premises, windows, glass and plate glass, doors, interior walls and finish work, floor surfaces and floor coverings, sprinkler and fire protection systems (which shall be in good working order as of the Commencement Date and in compliance with all Applicable Laws), and routine maintenance and repairs of the HVAC System (together with replacement of the HVAC System exclusively 23134410.6 servicing the Premises and installed by Tenant), in good and sanitary condition and repair and in compliance with all Applicable Laws. Tenant shall permit no waste, except normal wear and tear. Tenant shall also be responsible for arranging janitorial services for the Premises and the cost thereof. Tenant shall promptly notify Landlord, in writing, of any known defective condition which Landlord is required to repair, and failure to so report such known defects in a commercially reasonable time and manner shall make Tenant responsible to Landlord for any increased liability incurred by Landlord by reason of such failure to report the known defective condition. Any contractor selected by Tenant in connection with the performance of Tenant’s obligations under this Section in or about the Premises or the Building shall require prior written approval of the Landlord which approval shall not be unreasonably withheld, conditioned or delayed, such approval shall require, at a minimum, Lxxxxxxx’s receipt of a Certificate of General Liability Insurance adding the Agent and the Landlord as additionally insured, proof that the contractor is duly licensed and permitted in the municipality where the Premises is located, to the extent such licensing and permitting is required by such municipality, acknowledgment and agreement by the contractor that all work shall be done with good workmanship and in accordance with current building codes and ordinances, and with agreement to adhere to any other reasonable standards imposed by Landlord for the protection and preservation of the Building and Premises.