NOTICE OF ACTUAL DELAY Sample Clauses

NOTICE OF ACTUAL DELAY. If Owner gives written notice to any one of the Tenants listed in paragraph 1 on or after Lease commencement date and if such notice states that occupancy has been delayed because of a prior Tenant’s holding over and the Residence will be ready for occupancy on a specific date, Tenant may terminate the Lease within 3 days after any one of such Tenants receives such written notice, but not thereafter.
AutoNDA by SimpleDocs
NOTICE OF ACTUAL DELAY. Subject to Program Manager’s compliance with the foregoing requirements of notice, Program Manager shall only be entitled to receive an equitable adjustment to the Program Master Schedule to allow such additional time as may be required as the result of a delay, including an Excusable Delay, to complete the affected Services if, as a condition precedent thereto, Program Manager has submitted to the Owner’s Project Manager within seven (7) days after Program Manager knew or, in the exercise of reasonable diligence, should have known of the delay, a detailed written notice of the circumstances of the delay together with supporting documentation thereof, the resultant cost and schedule impact thereof, and a description of any and all actions reasonably required of Owner to reasonably and appropriately mitigate the delay. If Program Manager submits all notices required hereunder in accordance with the foregoing provisions, the Owner, in its sole discretion, shall determine, whether the delay constitutes an Excusable Delay, and whether, as a result of any Excusable Delay, an extension of time should be granted to the Program Manager through equitable adjustment of the Program Master Schedule. The Program Manager’s entitlement to an equitable adjustment to the Program Master Schedule is absolutely conditioned upon Program Manager's timely submission of the written notices required herein. Subject to the foregoing, an equitable adjustment to the Program Master Schedule shall be the Program Manager’s sole remedy for Excusable Delays. Owner shall make no adjustment to the Program Master Schedule and Program Manager shall reimburse Owner for any additional costs incurred by Owner as a result of any delays deemed by Owner, in its sole discretion, to have been caused jointly or solely by the Program Manager.

Related to NOTICE OF ACTUAL DELAY

  • Notice of Actions Tenant will notify Landlord of any of the following actions affecting Landlord, Tenant or the Premises or the Project that result from or in any way relate to Tenant’s use of the Premises or the Project immediately after receiving notice of the same: (i) any enforcement, cleanup, removal or other governmental or regulatory action instituted, completed or threatened under any Hazardous Materials Law; (ii) any claim made or threatened by any person relating to damage, contribution, liability, cost recovery, compensation, loss or injury resulting from or claimed to result from any Hazardous Material; and (iii) any reports made by any person, including Tenant, to any environmental agency relating to any Hazardous Material, including any complaints, notices, warnings or asserted violations. Tenant will also deliver to Landlord, as promptly as possible and in any event within five (5) business days after Tenant first receives or sends the same, copies of all claims, reports, complaints, notices, warnings or asserted violations relating in any way to the Premises or the Project or Tenant’s use of the Premises or the Project. Upon Landlord’s written request, Tenant will promptly deliver to Landlord documentation acceptable to Landlord reflecting the legal and proper disposal of all Hazardous Materials removed or to be removed from the Premises. All such documentation will list Tenant or its agent as a responsible party and the generator of such Hazardous Materials and will not attribute responsibility for any such Hazardous Materials to Landlord or Landlord’s property manager.

  • Notice of Action When a supervisor or manager believes it is necessary to impose a minor disciplinary action on an employee, the supervisor shall notify the employee in writing of his/her decision stating the reason for the action, the regulations or rules which have been violated, the specific action to be taken, and the effective date of the action.

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.

  • NOTICE OF ACCIDENTS 20.01 Tenant shall give notice to Landlord, promptly after Tenant learns thereof, of (i) any accident in or about the Demised Premises for which Landlord might be liable, (ii) all fires in the Demised Premises, (iii) all damages to or defects in the Demised Premises, including the fixtures, equipment and appurtenances thereof, for the repair of which Landlord might be responsible, and (iv) all damage to or defects in any parts or appurtenances of the Building’s sanitary, electrical, heating, ventilating, air-conditioning, elevator and other systems located in or passing through the Demised Premises or any part thereof.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Notice of Lay-off 16.01 In the event of a proposed layoff, the Employer shall: (a) provide the Union with no less than 6 months written notice of the proposed layoff or elimination of position; and (b) provide to the affected employee(s), if any, who will be laid off or whose job will be eliminated, with no less than four (4) months written notice of layoff, or pay in lieu thereof. (c) provide the Union Representative with available space and time, if scheduled to work, to meet with the employee on the date the notice of layoff is given.

  • Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.

  • Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must: a. Be received by the Office of Financial Recovery (OFR) at Post Office Box 9501, Olympia, Washington 98507-9501, within twenty-eight (28) calendar days of service of the notice; b. Be sent by certified mail (return receipt) or other manner that proves OFR received the request; c. Include a statement as to why the Contractor thinks the notice is incorrect; and d. Include a copy of the overpayment notice. Timely and complete requests will be scheduled for a formal hearing by the Office of Administrative Hearings. The Contractor may be offered a pre-hearing or alternative dispute resolution conference in an attempt to resolve the overpayment dispute prior to the hearing. Failure to provide OFR with a written request for a hearing within twenty-eight (28) days of service of a vendor overpayment notice or other overpayment letter will result in an overpayment debt against the Contractor. DSHS may charge the Contractor interest and any costs associated with the collection of this overpayment. DSHS may collect an overpayment debt through lien, foreclosure, seizure and sale of the Contractor’s real or personal property; order to withhold and deliver; or any other collection action available to DSHS to satisfy the overpayment debt.

  • Notice of Impositions Lessor shall give prompt Notice to Lessee of all Impositions payable by Lessee hereunder of which Lessor at any time has knowledge, provided that Lessor’s failure to give any such Notice shall in no way diminish Lessee’s obligations hereunder to pay such Impositions, but such failure shall obviate any default hereunder for a reasonable time after Lessee receives Notice of any Imposition which it is obligated to pay during the first taxing period applicable thereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!