OWNER'S RIGHT OF INSPECTION Sample Clauses

OWNER'S RIGHT OF INSPECTION. AND REVIEW Owner and Owner's accountants, attorneys and agents have the right to enter upon any part of the Project at any reasonable time during the Term of this Agreement for the purpose of examining or inspecting the Project or examining or making copies of books and records of the Project. Any inspection shall be done with as little disruption to the business of the Project as possible. Books and records of the Project shall be kept, as of the commencement date, at the Project or at the location where any central accounting and bookkeeping services are performed by Manager but at all times shall be the property of Owner.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
OWNER'S RIGHT OF INSPECTION. OWNER, it’s representatives, heirs, administrators, successors, assigns and agents shall have the right to enter any part of the PROPERTY at reasonable times and with reasonable notice for inspection of any nature. OWNER agrees that inspection(s) will be done in a manner which will not disrupt PROPERTY operation unduly.
Sample 1
OWNER'S RIGHT OF INSPECTION. 9.1 Owner’s Representative and Owner’s other authorized agents shall be entitled to inspect, at Owner’s expense, progress on the Work and the Materials at any reasonable time, upon reasonable notice, terms, and conditions. 9.2 All completed milestones of the Work and the workmanship and Material required under this Agreement shall be inspected promptly by Owner and promptly accepted or rejected in accordance with the Contract Documents. Failure to object will not prevent Owner from later identifying defects or rejecting workmanship, subject to the terms of the Warranty under Article 11. 9.3 Builder shall schedule for and carry out tests, inspections, and approvals of portions of the Work required by the Contract Documents or by applicable laws, ordinances, rules, regulations, or orders of Regulatory Authorities at appropriate times under the Project Schedule. 9.4 Builder shall give advance notice to Owner’s Representative of the time and place of all tests, trials, inspections, and approvals. In the case of tests, inspections, and approvals at the Shipyard, Builder shall endeavor to give at least five (5) Days prior notice. In the case of tests, inspections, and approvals conducted away from the Shipyard, Builder shall endeavor to give at least seven (7) Days prior notice. 9.5 Unless otherwise provided, Builder shall make all necessary arrangements for such tests, inspections, and approvals, and shall bear all related costs, including the costs of fuels, lubricants, and consumable fluids used in the cleaning and testing of the Work. 9.6 Builder shall set out the onboard testing and trial procedures in cooperation with Owner. Builder shall give a list of inspection items to Owner for Owner's reference. 9.7 The necessary tests and inspections of the Vessel, its machinery, equipment, and outfitting as may be required by the Regulatory Authorities, or as otherwise agreed by the Parties, shall be carried out by the Regulatory Authorities as required throughout the period of construction. Owner’s Representative shall have the right to attend such tests and inspections.
Sample 1
OWNER'S RIGHT OF INSPECTION. AND REVIEW Owner, Owner’s lenders, and their respective accountants, attorneys and agents have the right to enter upon any part of the Project at any reasonable time during the Term upon reasonable prior notice to Manager for the purpose of examining or inspecting the Project or examining or making copies of books and records of the Project. Any inspection shall be done with as little disruption to the business of the Project as possible. Books and records of the Project shall be kept, as of the Commencement Date, at the Project or at the location where any central accounting and bookkeeping services are performed by Manager and at all times shall be digitally accessible by Owner (and those to whom Owner desires to provide such access).
Sample 1
OWNER'S RIGHT OF INSPECTION. Owner, or its authorized agents, shall have the right during normal business hours and upon advance reasonable notice to Customer to enter upon the Job Location for the purpose of inspecting the Equipment.
Sample 1
OWNER'S RIGHT OF INSPECTION. The Owner shall have the right to inspect the equipment during Lessee's normal business hours.
Sample 1

Related to OWNER'S RIGHT OF INSPECTION

  • Right of Inspection Buyer shall have the right to inspect the goods at the time and place of delivery, and within 5 business days after delivery, Buyer must give notice to Seller of any claim for damages on account of the condition, quality, or grade of the goods, and Buyer must specify in detail the basis of such claim. The failure of Buyer to comply with these conditions shall constitute irrevocable acceptance of the goods by Buyer.

  • LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.

  • Lessor’s Right to Inspect Lessee shall permit Lessor and its authorized representatives as frequently as reasonably requested by Lessor to inspect the Leased Property and Lessee’s accounts and records pertaining thereto and make copies thereof, during usual business hours upon reasonable advance Notice, subject only to any business confidentiality requirements reasonably requested by Lessee.

  • DXC’s Right to Inspect DXC may, at any time, inspect the software, Services, or Products and associated manufacturing processes. Inspection may occur at Supplier’s facility, plant or subcontractor’s plant. Supplier will inform its vendors and subcontractors of DXC’s right to inspect and shall secure that right for DXC if necessary.

  • Rights of Inspection In order to ensure that the Quality Standards are maintained, Licensor and its authorized agents and representatives shall have the right, but not the obligation, with prior notice to Licensee, to enter upon the premises of any office or facility operated by or for Licensee with respect to Sprint PCS Products and Services and Premium and Promotional Items at all reasonable times, to inspect, monitor and test in a reasonable manner facilities and equipment used to furnish Sprint PCS Products and Services and Premium and Promotional Items and, with prior written notice to Licensee, to inspect the books and records of Licensee in a manner that does not unreasonably interfere with the business and affairs of Licensee, all as they relate to the compliance with the Quality Standards maintained hereunder.

  • Right to Inspect Bank (through any of its officers, employees, or agents) shall have the right, upon reasonable prior notice, from time to time during Borrower’s usual business hours but no more than twice a year (unless an Event of Default has occurred and is continuing), to inspect Borrower’s Books and to make copies thereof and to check, test, and appraise the Collateral in order to verify Borrower’s financial condition or the amount, condition of, or any other matter relating to, the Collateral.

  • Inspection by Lessor Upon reasonable advance notice, Lessee, during reasonable business hours and subject to Lessee's security requirements, will make the Equipment and its related log and maintenance records available to Lessor for inspection.

  • RIGHT OF ENTRY AND INSPECTION OWNER may enter, inspect, and/or repair the premises at any time in case of emergency or suspected abandonment. OWNER shall give 24 hours advance notice and may enter for the purpose of showing the premises during normal business hours to prospective renters, buyers, lenders, for smoke alarm inspections, and/or for normal inspections and repairs. OWNER is permitted to make all alterations, repairs and maintenance that in OWNER'S judgment is necessary to perform.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Right to Inspect Records Engineer agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of Engineer involving transactions relating to this contract. Engineer agrees that City shall have access during normal working hours to all necessary Engineer facilities and shall be provided adequate and appropriate work space in order to conduct audits in compliance with the provisions of this section. City shall give Engineer reasonable advance notice of intended audits. Engineer further agrees to include in subcontract(s), if any, a provision that any subcontractor or consultant agrees that City shall have access to and the right to examine any directly pertinent books, documents, papers and records of such consultant or subcontractor involving transactions to the subcontract, and further, that City shall have access during normal working hours to all consultant or subcontractor facilities, and shall be provided adequate and appropriate work space, in order to conduct audits in compliance with the provisions of this paragraph. City shall give the consultant or subcontractor reasonable advance notice of intended audits.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!