We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

PLANS AND Sample Clauses

PLANS AND. SPECIFICATIONS
AutoNDA by SimpleDocs
PLANS AND specifications for Alterations shall be prepared at Tenant's expense by Landlord's architect, or by Tenant's architect if Tenant so requests and Landlord consents, which consent shall be at Landlord's sole discretion, and by engineers approved by Landlord, where the nature of the Alterations requires mechanical or electrical engineering services. Any architect retained by Tenant shall be instructed to follow standard construction administration procedures and use standard specifications and details reasonably promulgated by Landlord for the Building. The plans and specifications shall be subject to approval by Landlord and Tenant, and shall not be unreasonably withheld or delayed by either party. Plans and specifications that have neither been approved nor disapproved by Landlord within thirty (30) days after submittal by Tenant shall be deemed to have been approved. Landlord does not warrant the cost of the Alterations, the timeliness of performance, nor the quality of the contractor's work, but Landlord shall use reasonable best efforts to secure performance of the construction contract for Tenant's benefit.
PLANS AND. SPECIFICATIONS (a) We will loan to you: (i) A sample set of standard building plans and specifications and/or standard recommended floor plans prepared by a licensed architect; (ii) Specifications of our requirements for design, decoration, layout, equipment, furniture, fixtures and signs for the Healthy Bites Grill Franchise (collectively, the "Design Specifications"); and (iii) Specifications for Healthy Bites Grill uniforms for your employees to be purchased directly from our approved suppliers. (b) On or before the Opening Date, you must return to us the plans and specifications described in Subsection 2.3(a).
PLANS AND specifications for such work shall be filed with and subject to the approval of the Director and all work shall be done in accordance with local ordinances and state laws. Only plans and specifications marked "Released for Construction" by the AUTHORITY may be used by AIRLINE's contractors.
PLANS AND specifications for all work undertaken as part of the Project during the term of the Loan have been or will be approved by all governmental authorities having jurisdiction, and all necessary building permits and all other governmental and private authorizations and approvals have been or will be obtained, and will remain in full force and effect during the term of the Loan.
PLANS AND. SPECIFICATIONS - Contractor expressly agrees to read and become familiar with all relevant plans and specifications (available for inspection in Builder’s Office) applicable to this Agreement or any Work requested by Builder before starting any Work. Contractor shall be solely responsible for all construction under this Agreement, including techniques, sequences, procedures, and means for the coordination of all Work. Contractor shall supervise and direct his Work to the best of his ability, and give it all attention necessary for such proper supervision and direction. Contractor shall perform all labor in a good and workmanlike manner.
PLANS AND specifications and surveys delivered by Tenant to Landlord shall be for Landlord's information only except to the extent, if any, otherwise expressly provided in this Lease.
AutoNDA by SimpleDocs
PLANS AND. SPECIFICATIONS ------------------------ 1. Tenant's plans and specifications shall be in such form and detail as Landlord may reasonably require in order to determine (a) if the materials to be used meet the quality standard prescribed by the Landlord for all improvements in the Building; and (b) the effect of such proposed improvements on the structural components and service systems and facilities of the Building. Tenant's plans and specifications shall include the following:

Related to PLANS AND

  • Plans and Specifications After Landlord receives and approves Tenant’s Space Plan as provided above, Tenant will cause Tenant’s Architect to prepare the Plans and Specifications for the Tenant Improvements. Landlord will approve or disapprove (specifically describing any reasons for disapproval) the Plans and Specifications in writing within ten (10) Business Days after receiving them. If Landlord disapproves the Plans and Specifications, Tenant will provide appropriately revised Plans and Specifications to Landlord for approval (or disapproval) within five (5) Business Days on the same basis as set forth above. After Landlord’s approval, Tenant will submit the Plans and Specifications for permits and construction bids. No deviation from the Building Standard will be permitted in the Space Plan or the Plans and Specifications, provided reasonable deviations with respect to the ceiling, lighting, painting, flooring and wall covering may be permitted with Landlord’s approval. Landlord will not approve any deviations which Landlord believes (a) do not conform to applicable codes, ordinances and other Laws or are disapproved by any governmental agency, (b) require services beyond the level normally provided to other tenants in the Building, or (c) are of a nature or quality that are inconsistent with Landlord’s overall plan or objectives for the Building. No approval by Landlord of any deviation constitutes an acknowledgment by Landlord that such deviations are in conformance with applicable codes, ordinances and other Laws. In the event that Landlord’s approval shall be required in this Tenant Improvements Agreement, then notwithstanding anything to the contrary set forth in the Lease, Landlord’s approval shall not be unreasonably withheld, conditioned, or delayed.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.

  • Operating Leases Not permit the aggregate amount of all rental payments under Operating Leases made (or scheduled to be made) by the Loan Parties (on a consolidated basis) to exceed $1,000,000 in any Fiscal Year.

  • Tenant Leases Attached hereto as Exhibit D-1 is a list of all leases and any other licenses and occupancy agreements pursuant to which any person occupies, or has the right to occupy, space in the Project (which leases, agreements and other documents, together with the lease documents entered into with respect to the Project after the date hereof pursuant to Section 5 below, are herein referred to collectively as the "Tenant Leases"). Exhibit D-1 also includes a list of all security deposits currently being held by Seller in connection with the Tenant Leases. Seller has made true, correct and complete copies of the Tenant Leases available to Purchaser on the due diligence website created for this transaction. Except for the Tenant Leases, there are no other leases or other occupancy agreements affecting the Project. Seller has not granted any party any option to purchase the Project, rights of first refusal to purchase the Project or, except as set forth in the Tenants Leases, any licenses or other similar agreement with respect to the Project. To Seller's actual knowledge, except as shown on Exhibit D-2 attached hereto, there are no defaults under any of the Tenant Leases and the Tenant Leases are in full force and effect. There are no brokerage commissions or fees due now or payable in the future in connection with the Tenant Leases except for brokerage commissions that may be due Xxxxxxx & Xxxxxxxxx U.S., Inc. (C&W) for lease renewals pursuant to that certain Commission Agreement for Lease, signed by Seller on December 8, 2017, and by C&W on December 27, 2017 (the "C&W Commission Agreement"); and, except for the Outstanding TI Work, all tenant improvement costs and work applicable to the current term and space covered by the Tenant Leases have been paid completed and paid in full.

  • Real Estate Leases (a) Neither BGH Holdings nor BRH Holdings leases any real estate. Seller does not own or lease any real estate used in connection with the businesses of BGH Holdings, BRH Holdings, or the Companies. (b) Schedule 4.16 sets forth a list of all of the leases or rights of occupancy pursuant to which the Companies (or any of them) lease or sublease any real property or interest therein (collectively, the "Leases"), including the identification of each of the Lessors thereof and the street addresses of the real estate demised under any of the Leases (collectively, the "Leased Real Estate"). Except as set forth in Schedule 4.16, one or more of the Companies is the lessee under all Leases, and no party other than one or more of the Companies has any right to possession, occupancy or use of any of the Leased Real Estate. A true and correct copy of each of the Leases has been delivered to Buyer, together with all amendments and modifications thereto, and no changes, amendments or modifications have been made thereto since the date of such delivery, except as permitted by Section 3.02 (k). Each of the Leases is valid and is in full force and effect and is binding and enforceable in accordance with its terms except to the extent such enforcement may be limited by bankruptcy, insolvency, reorganization, moratorium or other laws relating to or affecting the enforcement of creditors' rights or by general equitable principles. Except as set forth in Schedule 4.16, none of the Companies is in default (after expiration of applicable cure or grace periods) under any provision of any of the Leases, the failure of which to perform would permit the lessor thereunder to terminate such Lease, and, to Seller's knowledge, no event has occurred which (with or without notice, lapse of time or both) would render any of the Companies in default under any of such provisions which default would permit the lessor thereunder to terminate such Lease. To the knowledge of Seller, BRH Holdings, BGH Holdings, or the Companies, no other party to any of the Leases is in default under any of the material commitments and obligations thereof, and no event has occurred which (with or without notice, lapse of time or both) would render any such other party in default under any of such provisions. (c) Except as set forth in Schedule 4.16, the Companies are in actual possession of the Leased Real Estate. Except as set forth in Schedule 4.16, the Companies have good and valid title to all the leasehold estates conveyed under the Leases free and clear of all Liens except for (i) (A) those provided under the relevant lease; (B) matters shown on Schedule 4.16; and (C) defects of title, conditions, easements, covenants or restrictions, if any, none of which items referred to clauses (A), (B) or (C) above is substantial in amount, and none of which, individually or in the aggregate, materially impairs or grants or evidences rights which, if exercised, would materially impair the current use of the affected property in the manner such property is currently being used by the Companies, or impairs the operations of any of the Companies; (ii) zoning or land use ordinances, none of which, to Seller's knowledge, individually or in the aggregate, materially impairs the use of the affected property in the manner such property is currently being used, or impairs the current operations of any of the Companies; and (iii) liens for taxes not yet due and payable (iv) any mortgage liens granted by any lessor under any of the Leases of the lessor's interest in the underlying real estate or the Leases. To Seller's knowledge, none of the Companies has received written notice of any violation of or non-conformity with any zoning, subdivision, wetlands or other similar law, code, rule, regulation or ordinance from any governmental authority with respect to any of the Leased Real Estate, or of any condemnation action, eminent domain proceeding or other litigation concerning any of such properties. (d) Except as set forth in Schedule 4.16, the basic rent, all additional rent and all other charges and amounts payable under the Leases have been paid to date and not more than one month in advance. All work required to be performed under the Leases by the landlords thereunder or by any of the Companies have been performed, and, to the extent that any of the Companies is responsible for payment of such work, has been fully paid for, whether directly to the contractor performing such work or to such landlord as reimbursement therefor, except for items which any of the Companies is disputing in good faith (which items are set forth in Schedule 4.16). (e) Except as set forth on Schedule 4.16, there are no brokerage commissions or finder's fees due from Seller or any of the Companies which are unpaid with regard to any of the Leases or the Leased Real Estate or which will become due at any time in the future with regard to the Leases or the Leased Real Estate. (f) Except as set forth in Schedule 4.16, there have been no casualties which are reasonably likely to result in the termination of any of the Leases or the exercise of any buy-out provision contained in any of the Leases relative to damage by casualty. (g) Except as set forth on Schedule 4.16, (i) no consent of any of the lessors under any of the Leases is required by reason of any of the transactions contemplated by this Agreement, and (ii) none of the rights of any of the Companies under any of the Leases will be impaired by the consummation of the transactions contemplated by this Agreement and all of such rights will be enforceable by the Companies after the Closing Date without the consent or agreement of any other party, including all rights to purchase any of the Leased Real Estate or to renew any of the Leases pursuant to options to purchase or renew contained in any of the Leases. Any lessor under any of the Leases whose consent or agreement is required is identified as such on Schedule 4.16.

  • Ground Leases For purposes of this Exhibit C, a “Ground Lease” shall mean a lease creating a leasehold estate in real property where the fee owner as the ground lessor conveys for a term or terms of years its entire interest in the land and buildings and other improvements, if any, comprising the premises demised under such lease to the ground lessee (who may, in certain circumstances, own the building and improvements on the land), subject to the reversionary interest of the ground lessor as fee owner. With respect to any Mortgage Loan where the Mortgage Loan is secured by a Ground Leasehold estate in whole or in part, and the related Mortgage does not also encumber the related lessor’s fee interest in such Mortgaged Property, based upon the terms of the Ground Lease and any estoppel or other agreement received from the ground lessor in favor of Mortgage Loan Seller, its successors and assigns (collectively, the “Ground Lease and Related Documents”), Mortgage Loan Seller represents and warrants that:

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Existing Leases With respect to those Leases listed on Exhibit "F" attached hereto and made a part hereof (the "Existing Xxxxxx Leases"), as assigned by Essex Insurance Company (an affiliate of Tenant) to Landlord, (a) Tenant acknowledges and accepts the existence of such Existing Xxxxxx Leases, and acknowledges and agrees that neither the Existing Xxxxxx Leases nor any rights of the tenants thereunder shall alter, diminish, reduce or modify any obligations of Tenant hereunder, including, but not limited to, obligations to pay Rent and Additional Rent hereunder, notwithstanding that parties other than Tenant have occupancy rights under and pursuant to the Existing Xxxxxx Leases and the space demised thereby; (b) Tenant requests that Landlord permit Tenant to receive and retain the rights to receive the rent and other performance by the tenants under the Existing Xxxxxx Leases, as if such Existing Xxxxxx Leases constituted subleases permitted hereby; (c) Landlord agrees that Tenant shall be entitled to receive and retain the rights to receive the rent and other performance by the tenants under the Existing Xxxxxx Leases, as if such Existing Xxxxxx Leases constituted subleases permitted hereby; (d) Landlord agrees that Tenant shall be entitled to negotiate with, take actions with respect to, and otherwise deal with such tenants under the Existing Xxxxxx Leases, as if such Existing Xxxxxx Leases constituted subleases permitted hereby, and, in connection therewith Landlord agrees that Landlord shall enter into any modification or amendment of such Existing Xxxxxx Leases as Tenant may direct Landlord in writing, subject to Landlord's review and approval thereof, which shall not be unreasonably withheld, delayed or conditioned, (e) Tenant shall have no right to modify or amend any covenant set forth in any Existing Xxxxxx Lease which would increase or impose any new (or extended) obligations on Landlord or on the successor in title to any landlord or lessor thereunder, after the expiration of the Term of this Lease, and (f) Landlord hereby relinquishes any rights to which Tenant is entitled under this Paragraph 10.04 during the Term or extended Term of this Lease.

  • Improvement Plans A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!