Construction Administration Procedures Sample Clauses

Construction Administration Procedures. CM will establish and maintain construction administration procedures. All communications between various members of the Project Team and the contractor(s) will be through the County’s Contract Specialist. These procedures will be detailed in the Project Management Plan.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Construction Administration Procedures. Coordinate with NAIPTA and provide weekly updates on progress, quantity calculations, and Federal reporting.
Sample 1
Construction Administration Procedures. The Construction Manager shall establish and implement procedures for expediting and processing requests for information, shop drawings, material and equipment sample submittals, Contract Schedule adjustment, Change Orders, substitutes, payment requests and the maintenance of logs. The Construction Manager shall maintain daily job reports. The Construction Manager shall be the party to whom requests for information, submittals, Subcontractor schedule adjustment, substitutes, Change Order requests and payment requests shall be submitted.
Sample 1
Construction Administration Procedures. The PM shall establish and implement procedures for reviewing and processing requests for clarifications and interpretations of the Contract Documents; shop drawings, samples, samples and other submittals; contract schedule adjustments; change order proposals; written proposals for substitutions; payment applications; and the maintenance of logs. As the County's representative at the construction site, the PM shall be the party to whom all such information shall be submitted.
Sample 1
Construction Administration Procedures. Consultant, with input from the A/E, shall establish and implement procedures for: expediting and processing requests for information (“RFIs”); and review and approval of shop drawings, material and equipment sample submittals, contract schedule adjustments, change orders, material and equipment substitution requests and payment requests. Consultant shall establish and maintain logs for tracking all relevant information related to the above. Consultant shall maintain daily job reports and submit to the Town on a weekly basis. As the Town’s representative at the construction site, Consultant shall be the party to whom RFIs, submittals, schedule adjustments, substitution requests, test results, change order requests and payment applications shall be submitted. Consultant shall process the requests and forward them to the Fountain Hills Development Services Director with a recommendation for approval or denial. After approval or denial, Consultant shall notify the Construction Contractor of the Development Services Director’s decision.
Sample 1
Construction Administration Procedures. Concessionaire shall establish and implement procedures for reviewing and processing requests for clarifications and interpretations of the Design Documents, shop drawings, samples and other submittals; contract schedule adjustments; change order proposals; and written proposals for substitutions. Concessionaire shall maintain on a current basis and make available to BOR, Program Manager and Contractor, at any time at the Premises, logs recording information relevant to such submittals, including, without limitation, the date of such submittal, Concessionaire comments, Design Professional comments and whether the submittal has been approved or disapproved. Such procedures shall be designed to ensure that all such submittals are duly reviewed by BOR and Program Manager and approved by BOR prior to the commencement of related work. All changes and change orders shall be subject to the prior written approval of BOR and Institution. Such approval shall not to be unreasonably withheld, conditioned, or delayed.
Sample 1

Related to Construction Administration Procedures

  • Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.

  • Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.

  • Administrative Procedures Administrative procedures with respect to the sale of Notes shall be agreed upon from time to time by the Agents and the Company (the "Procedures"). The Agents and the Company agree to perform the respective duties and obligations specifically provided to be performed by them in the Procedures.

  • Procurement procedures 11.1 The Recipient must secure the best value for money and shall act in a fair, open and non-discriminatory manner in all purchases of goods and services.

  • Loan Procedures (a) In order to request a Borrowing, the Borrower --------------- shall hand deliver or telecopy (or notify by telephone and promptly confirm by hand delivery or telecopy) to the Agent the completed Borrowing Request (i) in the case of a Eurodollar Borrowing, not later than 2:00 p.m., Philadelphia time, three Business Days before a proposed Borrowing and (ii) in the case of a Base Rate Borrowing, not later than 11:00 a.m., Philadelphia time, on the day of a proposed Borrowing. Such notice shall be irrevocable and shall in each case specify (x) whether the Borrowing then being requested is to be a Eurodollar Borrowing or a Base Rate Borrowing; (y) the date of such Borrowing (which shall be a Business Day) and the amount thereof; and (z) if such Borrowing is to be a Eurodollar Borrowing, the Interest Period with respect thereto. If no election as to the Type of Borrowing is specified in any such notice, then the requested Revolving Borrowing shall be a Base Rate Borrowing. If no Interest Period with respect to any Eurodollar Borrowing is specified in any such notice, then the Borrower shall be deemed to have selected an Interest Period of one month's duration. The Agent shall promptly advise the Lenders of any notice given pursuant to this Section 2.2 and of each Lender's portion of the requested Borrowing. (b) Subject to Section 2.3(a), each Lender shall make each Loan to be made by it hereunder on the proposed date thereof by wire transfer of immediately available funds to the designated account of the Agent in Philadelphia, Pennsylvania, not later than 2:00 p.m., Philadelphia time, and the Agent shall by 3:00 p.m., Philadelphia time, wire transfer the amounts so received to the designated account of the Borrower or, if a Borrowing shall not occur on such date because any condition precedent herein specified shall not have been met, return the amounts so received to the respective Lenders. Unless the Agent shall have received notice from a Lender prior to the date of any Borrowing that such Lender will not make available to the Agent such Lender's portion of such Borrowing, the Agent may assume that such Lender has made such portion available to the Agent on the date of such Borrowing in accordance with this paragraph (b) and the Agent may, in reliance upon such assumption, make available to the Borrower on such date a corresponding amount. If and to the extent that such Lender shall not have made such portion available to the Agent, such Lender and the Borrower severally agree to repay to the Agent forthwith on demand such corresponding amount together with interest thereon, for each day from the date such amount is made available to the Borrower until the date such amount is repaid to the Agent at the interest rate applicable at the time to the Loans comprising such Borrowing. If such Lender shall repay to the Agent such corresponding amount, such amount shall constitute such Lender's Loan as part of such Borrowing for purposes of this Agreement.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • Collection Procedures (a) On or before the Closing Date, the Seller and the Purchaser shall have established and shall maintain thereafter the system of collecting and processing Collections of Receivables in accordance with Section 2.02 of the Servicing Agreement. (b) The Seller shall cause all in-store payments to be (i) processed as soon as possible after such payments are received by the Seller but in no event later than the Business Day after such receipt, and (ii) delivered to the Servicer or, if a Daily Payment Event has occurred, deposited in the Collection Account no later than the second Business Day following the date of such receipt. (c) The Seller and the Purchaser shall deliver to the Servicer or, if a Daily Payment Event has occurred, deposit into the Collection Account all Recoveries received by it within two Business Days after the Date of Processing for such Recovery. (d) Any funds held by the Seller representing Collections of Receivables shall, until delivered to the Servicer or deposited in the Collection Account, be held in trust by the Seller on behalf of the Trustee as part of the Trust Estate. (e) The Seller hereby irrevocably waives any right to set off against, or otherwise deduct from, any Collections. (f) The Seller acknowledges that Seller shall not have any right, title or interest in and to any Trust Account.

  • Disbursement Procedures The Issuing Bank shall, promptly following its receipt thereof, examine all documents purporting to represent a demand for payment under a Letter of Credit. The Issuing Bank shall promptly notify the Administrative Agent and the Borrower by telephone (confirmed by telecopy) of such demand for payment and whether the Issuing Bank has made or will make an LC Disbursement thereunder; provided that any failure to give or delay in giving such notice shall not relieve the Borrower of its obligation to reimburse the Issuing Bank and the Lenders with respect to any such LC Disbursement.

  • ESCALATION PROCEDURES 48.1 The Standard Practices outlines the escalation process which may be invoked at any point in the Service Ordering, Provisioning, and Maintenance processes to facilitate rapid and timely resolution of disputes.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!