Plans and Budgets; Payments Sample Clauses

Plans and Budgets; Payments. Within 90 days of a written request by Rainbow, Falkirk will submit to Rainbow for its review and written approval the proposed plans and budgets for Falkirk’s reclamation activities. Rainbow will not unreasonably delay, condition or withhold its approval of such plans and budgets. In order to permit Falkirk to complete mine reclamation as required under ND SMCRA, Rainbow will pay amounts as invoiced by Falkirk, but shall provide written notice in the event that it disputes the validity of all or a portion of any invoice. In the event of such a dispute, the Parties shall attempt in good faith for a period of thirty days to resolve such dispute. In the event the Parties are unable to so resolve the dispute, the Parties shall conduct arbitration pursuant to Section 14.5. In the event Falkirk ultimately repays an amount paid by Rainbow but found not to be owing to Falkirk, Falkirk will refund such amount with interest from the date of payment by Rainbow to the date of reimbursement by Falkirk, accruing at a per annum rate of five percent. The reclamation costs payable under this Section 5.2(b) shall be determined in accordance with the principles for determining the Cost of Production under Section 4.2. After Rainbow’s written approval of such plans and budgets (or portions thereof), Falkirk will seek Rainbow’s prior written approval of any material changes to or from such plans and budgets. Falkirk will submit such reports regarding Falkirk’s activities and reclamation costs incurred as Rainbow may reasonably request from time to time. The Post-Production Costs payable under this Section 5.2(b) will be invoiced by Falkirk to Rainbow in accordance with Section 6.2. Rainbow or Rainbow’s representative has the right at any time on notice in writing to Falkirk to examine the records and books of account of Falkirk and any Affiliate of Falkirk relating to the Post-Production Costs to be borne by Rainbow under this Section 5.2(b).
Sample 1
AutoNDA by SimpleDocs

Related to Plans and Budgets; Payments

  • Annual Work Plans and Budgets The Recipient shall furnish to the Association as soon as available, but in any case not later than September 1 of each year, the annual work plan and budget for the Project for each subsequent year of Project implementation, of such scope and detail as the Association shall have reasonably requested, except for the annual work plan and budget for the Project for the first year of Project implementation, which shall be furnished no later than one (1) month after the Effective Date.

  • Business Plan and Budget As soon as available, but in any event within sixty (60) days after the end of each fiscal year of the Borrower, an annual business plan and budget of the Borrower and its Subsidiaries on a Consolidated basis, including forecasts prepared by management of the Borrower, in form reasonably satisfactory to the Lender, of Consolidated balance sheets and statements of income or operations and cash flows of the Borrower and its Subsidiaries on a fiscal year basis and, in the case of such forecasted statements of income, on a fiscal quarterly basis for the immediately following fiscal year. As to any information contained in materials furnished pursuant to Section 6.02(f), the Borrower shall not be separately required to furnish such information under Section 6.01(a) or (b) above, but the foregoing shall not be in derogation of the obligation of the Borrower to furnish the information and materials described in Sections 6.01(a) and (b) above at the times specified therein.

  • Operating Budgets (i) The Borrowers shall, not later than thirty (30) days before the Commercial Operation Date for any Plant, adopt an Operating Budget with respect to such Plant and an updated aggregate Operating Budget for the Project from such date to the conclusion of the calendar year immediately following the then-current calendar year and provide a copy of such operating plan and budget at such time to the Administrative Agent. (ii) No less than sixty (60) days in advance of the beginning of each calendar year with respect to each Plant that has achieved its Commercial Operation Date, the Borrowers shall similarly adopt an operating plan and a budget setting forth in reasonable detail the projected requirements for Operation and Maintenance Expenses and Maintenance Capital Expenses for the ensuing two (2) calendar years for each Plant that has achieved its Commercial Operation Date and an aggregate operating plan and budget for the Project and provide a copy of each such operating plan and budget at such time to the Administrative Agent. (Each such operating plan and budget is herein called an "Operating Budget"). (iii) Each Operating Budget shall include the same items and detail as provided in the Financial Model and be prepared in accordance with a form similar to the Madera Operating Budget delivered on the Closing Date (or a form otherwise approved by the Administrative Agent) and shall become effective upon approval of the Administrative Agent (acting in consultation with the Consultants if the Administrative Agent reasonably determines that such consultation is necessary or desirable). The Administrative Agent's approval of such updated Operating Budgets shall not be unreasonably withheld or delayed. (iv) If the Borrowers have not adopted an annual Operating Budget covering the applicable two-year period for each Plant that has achieved its Commercial Operation Date and for the Project before the beginning of any calendar year following the Madera Funding or any Operating Budget adopted by the Borrowers has not been accepted by the Administrative Agent before the beginning of any upcoming calendar year, the Operating Budget for each relevant Plant for the preceding calendar year shall, until the adoption of an annual Operating Budget by the Borrowers and acceptance of such Operating Budget by the Administrative Agent, be deemed to be in force and effective as the annual Operating Budget for such Plant for such upcoming calendar year; provided that if the initial Operating Budget for any Plant is not approved by the Administrative Agent, the Borrowers may use a budget for such Plant that is consistent with the Financial Model until an initial Operating Budget is approved, and the Borrowers shall work diligently to prepare an initial Operating Budget for each Plant that is acceptable to the Administrative Agent. (v) If either the actual Operation and Maintenance Expenses or Maintenance Capital Expenses for any Fiscal Quarter is in excess of the applicable Permitted Operating Budget Deviation Levels, the Borrowers may deliver to the Administrative Agent and the Consultants a proposed updated Operating Budget(s), which shall be subject to approval by the Administrative Agent. Such proposed updated Operating Budget(s) shall not become effective until approved by the Administrative Agent. (vi) Each Operating Budget delivered to the Administrative Agent pursuant to this Section 7.01(j) shall be accompanied by a memorandum addressing all material deviations from the Financial Model.

  • Annual Budgets The School shall adopt a budget for each fiscal year, prior to the beginning of the fiscal year. The budget shall be in the Idaho Financial Accounting Reporting Management Systems (IFARMS) format and any other format as may be reasonably requested by the Authorizer.

  • Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.

  • Capital Expenditures The Issuer shall not make any expenditure (by long-term or operating lease or otherwise) for capital assets (either realty or personalty).

  • Capital Projects (a) The selection of all design professionals and contractors for capital projects shall be made by Lessor and Lessor shall provide at its expense all materials and services for capital projects. (b) Lessee shall cooperate with Lessor with respect to capital projects. Notwithstanding anything in the foregoing which may be construed to the contrary, Lessee shall have no obligation to perform any such capital projects unless Lessee agrees to perform and be responsible for same in accordance with a written agreement therefor between Lessor and Lessee.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.

  • Capital Budget Any amendment that is mutually agreed upon shall be set forth in writing and signed by both parties. It is acknowledged by Owner that capital expenditures required as a result of an emergency situation shall not reduce amounts available pursuant to the Capital Budget or otherwise hereunder, other than to the extent a Capital Budget item is subsumed within the capital expenditures required as a result of the occurrence of the emergency;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!