Preliminary Design Review (PDR) Sample Clauses

Preliminary Design Review (PDR) a. The Preliminary Design Review (PDR) demonstrates that the preliminary design meets all system requirements with acceptable risk and within the cost and schedule constraints and establishes the basis for proceeding with detailed design. It will show that the correct design option has been selected, interfaces have been identified, and verification methods have been described.
Sample 1Sample 2
AutoNDA by SimpleDocs
Preliminary Design Review (PDR). The System PDR shall be conducted to allow the Contractor to satisfy Inmarsat formally of the baseline design concept and the planned implementation. This meeting shall include reviews of the appropriate budgets and specification requirements for system, subsystem and unit level and shall verify compliance with the contract requirements. This PDR shall also establish the compatibility of the design with the external and internal interfaces (Launch Vehicles, GSID, SDID etc). In view of the fact that the Platform is already qualified, the Platform aspects of the System PDR should actually be at CDR level. For new equipment, PDR’s shall also be held at Subsystem and Equipment level to satisfy Inmarsat of the baseline design concept, configuration, specification and design for that item. These PDR’s shall include a Specification Traceability Review to establish the link back to the overall system level requirements. For equipment which has already been qualified on other programmes and which is to be used unchanged on Inmarsat-4, the PDR, CDR and MRR shall be combined into a single review in order to authorise the start of manufacture for new equipment as early as possible in the programme. For off-the-shelf equipment, the PDR and CDR shall be combined with the TRB to verify its acceptability for the programme. The PDR will be deemed to be complete upon the completion and acceptance by Inmarsat of resolution of major action items. Sub-system reviews may be combined with system level design reviews.
Sample 1Sample 2
Preliminary Design Review (PDR). The contractor shall conduct a Preliminary Design Review in accordance with SECTION H-4 (a) of this contract. The government may provide additional guidance prior to this review.
Sample 1
Preliminary Design Review (PDR). The primary purpose of the PDR is for the Contractor to demonstrate that a technical approach has been selected that appears to be capable of meeting government requirements as established in the contract. The review, as a minimum, will include a description of the physical design planned, software programming required, cost projections, and typical management concerns, such as risk, metrics, and schedule issues.
Sample 1
Preliminary Design Review (PDR). The PDR demonstrates that the preliminary design meets system requirements with acceptable risk and within the cost and schedule constraints and establishes the basis for proceeding with detailed design. Amount: $23.5M Date: November 2024
Sample 1
Preliminary Design Review (PDR). The Contractor shall host a Preliminary Design Review (PDR) at the Contractor’s facility using the Defense Acquisition Guidebook, Paragraph 4.2.12 as guidance not later than seventy-five
Sample 1
Preliminary Design Review (PDR). The purpose of the PDR is for the Contractor to demonstrate to the Government that the integrated baseline of the MK 48 MOD 7 APB6/TI-1 program is operationally effective and that it has accomplished adequate design planning without incurring unacceptable risks that could breach schedule, performance, cost or other established criteria. The Contractor will schedule the PDR within 10 days of being notified by the COR to proceed with the review. The Contractor shall coordinate with the Government when/where the review will be held.
Sample 1
AutoNDA by SimpleDocs
Preliminary Design Review (PDR). The purpose of the PDR is to allow INTELSAT and the parties responsible for the item under review to agree on the baseline concept, configuration, specifications, and preliminary design of that item. The design review package shall be submitted in accordance with the CDRL (Appendix 2, Section 2.3.1). INTELSAT shall have the right to approve the review in accordance with 3.2.7 herein. The system PDR shall comprise a comprehensive review of the spacecraft requirements and their flow down to the subsystems and units. A Spacecraft System Preliminary Design Review shall be held to address specific requirements for each additional Spacecraft, when these requirements are modified from the initial Spacecraft’s requirements.
Sample 1
Preliminary Design Review (PDR). 11.2.1.A detailed preliminary design review (PDR) shall be held at MCF,Xxxxxx within two months from Effective date of contract (EDC)/Award of Contract.
Sample 1

Related to Preliminary Design Review (PDR)

  • Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).

  • Auction Schedule; Method of Submission of Orders (a) The Fund and the Auction Agent shall conduct Auctions for Preferred Shares in accordance with the schedule set forth below. Such schedule may be changed at any time by the Auction Agent with the consent of the Fund, which consent shall not be withheld unreasonably. The Auction Agent shall give notice of any such change to BD. Such notice shall be received prior to the first Auction Date on which any such change shall be effective. Time Event ---- -----

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.

  • Preliminary Plans Tenant shall cause Architect to prepare preliminary plans (the "Preliminary Plans") for the Tenant Improvements to be performed at the Premises. Tenant shall cause Architect to deliver the Preliminary Plans to Landlord within thirty (30) days after the date on which the Lease has been signed by Landlord and Tenant. Within five (5) days after Landlord's receipt of the Preliminary Plans, Landlord shall either approve or disapprove the Preliminary Plans, which approval shall not be unreasonably withheld. If Landlord disapproves the Preliminary Plans, then Landlord shall state in reasonable detail the changes which Landlord requires to be made thereto. Tenant shall submit to Landlord revised Preliminary Plans within five (5) days after Tenant's receipt of Landlord's disapproval notice. Following Landlord's receipt of the revised Preliminary Plans from Tenant, Landlord shall have the right to review and approve the revised Preliminary Plans pursuant to this Paragraph 2.2.1. Landlord shall give Tenant written notice of its approval or disapproval of the revised Preliminary Plans within five (5) days after the date of Landlord's receipt thereof. If Landlord reasonably disapproves the revised Preliminary Plans, then the following shall occur: (i) Landlord and Tenant shall continue to follow the procedures set forth in this Paragraph 2.2.1 until Landlord and Tenant reasonably approve the Preliminary Plans in accordance with this Paragraph 2.2.1, and (ii) the period between the date of Landlord's reasonable disapproval and the eventual mutual approval of such Preliminary Plans shall constitute a Tenant Delay.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!