Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
Construction Documents Phase Bidding or Negotiation Phase:
Acquisition Documents As of the Closing Date:
(a) Borrower has furnished Bank with true, correct and complete execution copies of all Acquisition Documents. Borrower has taken all necessary corporate action to authorize the execution, delivery and performance of each Acquisition Document to which it is a party.
(b) Borrower has complied with all applicable federal, state, provincial and local laws, ordinances, codes, rules, regulations and guidelines (including consent decrees and administrative orders) relating to the consummation of the Acquisition and all applicable waiting periods with respect to the transactions contemplated by the Acquisition Documents have expired without any action being taken by any competent governmental authority which restrains, prevents or imposes material adverse conditions upon the consummation of such transactions.
(c) All necessary authorization, consent, approval, license, qualification or formal exemption from, and all necessary filing, declaration or registration with, any court, governmental agency or regulatory authority or any securities exchange or any other Person (whether or not governmental, and including without limit any shareholder, partner or member of an applicable party) required to be made prior to the closing of the Acquisition in connection with the execution, delivery and performance by Borrower, and to Borrower’s best knowledge, each other party to the Acquisition Documents to which Borrower or such other Person is a party, have been obtained and will be in full force and effect, and, to the knowledge of Borrower, are not the subject of any attack or threatened attack (in each case in any material respect) by appeal or direct proceeding or otherwise.
(d) The execution, delivery and performance of the Acquisition Documents, and the consummation of the transactions contemplated thereby, are not in contravention of the terms of any indenture, material contract, instrument, any judgment, order or decree, to which Borrower is a party or by which it or its properties are bound, except, in each case, where such contravention could not reasonably be expected to have a Material Adverse Effect.
(e) Borrower has not granted a collateral assignment of, or a security interest over the Acquisition Documents (other than in favor of Bank) and Borrower has not sold, transferred or assigned any Acquisition Document to any Person (other than to or in favor of Bank).
(f) No Acquisition Document to which Borrower is a party has been modified, amended, altered or changed in any manner except in compliance with Section 7.12 of this Agreement, and to Borrower’s best knowledge, there are no unwaived defaults existing under the Acquisition Documents by Borrower that is a party thereto, or, to the best of the knowledge of Borrower, by any other party thereto.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Description of the Transaction Documents The Transaction Documents will conform in all material respects to the respective statements relating thereto contained in the Offering Memorandum.
Entire Agreement; Construction This Agreement, including the Exhibits and Schedules, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments, course of dealings and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule hereto, the Schedule shall prevail. In the event of any conflict between this Agreement and the Tax Matters Agreement, the terms and conditions of the Tax Matters Agreement shall govern.
Formation Documents With respect to the Issuing Entity, the Certificate of Trust and the Trust Agreement, (ii) with respect to the Grantor Trust, the Grantor Trust Certificate of Trust and the Grantor Trust Agreement, and (iii) with respect to the Depositor, the certificate of formation of the Depositor filed in Delaware, dated as of January 4, 2019 and the amended and restated limited liability company agreement of the Depositor, dated as of March 27, 2019, made by the Sponsor, as member.
Compliance with Transaction Documents The Company shall comply with, observe and timely perform each and every one of the covenants, agreements and obligations under the Transaction Documents.
Applicable Law and Construction This Lease may be executed in counterparts, shall be construed as a sealed instrument, and shall be governed exclusively by the provisions hereof and by the laws of the state where the Property is located without regard to principles of choice of law or conflicts of law. A facsimile signature to this Lease shall be sufficient to prove the execution by a party. If any provisions shall to any extent be invalid, the remainder shall not be affected. Other than contemporaneous instruments executed and delivered of even date, if any, this Lease contains all of the agreements between Landlord and Tenant relating in any way to the Premises and supersedes all prior agreements and dealings between them. There are no oral agreements between Landlord and Tenant relating to this Lease or the Premises. This Lease may be amended only by instrument in writing executed and delivered by both Landlord and Tenant. The provisions of this Lease shall bind Landlord and Tenant and their respective successors and assigns, and shall inure to the benefit of Landlord and its successors and assigns and of Tenant and its permitted successors and assigns, subject to Article 13. The titles are for convenience only and shall not be considered a part of this Lease. This Lease shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared primarily by counsel for one of the parties, it being recognized that both Landlord and Tenant have contributed substantially and materially to the preparation of this Lease. If Tenant is granted any extension or other option, to be effective the exercise (and notice thereof) shall be unconditional; and if Tenant purports to condition the exercise of any option or to vary its terms in any manner, then the purported exercise shall be ineffective. The enumeration of specific examples of a general provision shall not be construed as a limitation of the general provision. Unless a party’s approval or consent is required by the express terms of this Lease not to be unreasonably withheld, such approval or consent may be withheld in the party’s sole discretion. The submission of a form of this Lease or any summary of its terms shall not constitute an offer by Landlord to Tenant; but a leasehold shall only be created and the parties bound when this Lease is executed and delivered by both Landlord and Tenant and approved by the holder of any mortgage of the Premises having the right to approve this Lease. Nothing herein shall be construed as creating the relationship between Landlord and Tenant of principal and agent, or of partners or joint venturers or any relationship other than landlord and tenant. This Lease and all consents, notices, approvals and all other related documents may be reproduced by any party by any electronic means or by facsimile, photographic, microfilm, microfiche or other reproduction process and the originals may be destroyed; and each party agrees that any reproductions shall be as admissible in evidence in any judicial or administrative proceeding as the original itself (whether or not the original is in existence and whether or not reproduction was made in the regular course of business), and that any further reproduction of such reproduction shall likewise be admissible. If any payment in the nature of interest provided for in this Lease shall exceed the maximum interest permitted under controlling law, as established by final judgment of a court, then such interest shall instead be at the maximum permitted interest rate as established by such judgment.
