Loss Leader; Recycled Products Contractor shall not sell or use any article or product as a “loss leader” as defined in Section 17030 of the Business and Professions Code. If Contractor will sell to the Judicial Council, or use in the performance of this Agreement, goods specified in PCC 12207 (for example, certain paper products, office supplies, mulch, glass products, lubricating oils, plastic products, paint, antifreeze, tires and tire-derived products, and metal products), then with respect to those goods: (i) Contractor shall use recycled products in the performance of this Agreement to the maximum extent doing so is economically feasible, and (ii) upon request, Contractor shall certify in writing under penalty of perjury, the minimum, if not exact, percentage of post consumer material as defined in the PCC 12200, in such goods regardless of whether the goods meet the requirements of PCC 12209.
SOURCE CODE ESCROW FOR LICENSED PRODUCT If Source Code or Source Code escrow is offered by either Contractor or Product manufacturer or developer to any other commercial customers, Contractor shall either: (i) provide Licensee with the Source Code for the Product; or (ii) place the Source Code in a third party escrow arrangement with a designated escrow agent who shall be named and identified to the State, and who shall be directed to release the deposited Source Code in accordance with a standard escrow agreement acceptable to the State; or (iii) will certify to the State that the Product manufacturer/developer has named the State, acting by and through the Authorized User, and the Licensee, as a named beneficiary of an established escrow arrangement with its designated escrow agent who shall be named and identified to the State and Licensee, and who shall be directed to release the deposited Source Code in accordance with the terms of escrow. Source Code, as well as any corrections or enhancements to such source code, shall be updated for each new release of the Product in the same manner as provided above and such updating of escrow shall be certified to the State in writing. Contractor shall identify the escrow agent upon commencement of the Contract term and shall certify annually that the escrow remains in effect in compliance with the terms of this clause. The State may release the Source Code to Licensees under this Contract who have licensed Product or obtained services, who may use such copy of the Source Code to maintain the Product.
Recycled Products The Contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. References: 42 U.S.C. 6962, 40 CFR Part 247, Executive Order 12873 (More than $10,000)
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Product Sales Subject to Sections 10.3(c) and 10.3(d), Licensee agrees that it will not sell, offer for sale, or assist third parties (including Affiliates) in selling Product except for the sale and offer for sale of (A) TAF Product, TAF Combination Product, TDF Product and TDF Combination Product for use in the Field and in the countries of the TDF-TAF Territory, (B) COBI Product and COBI Combination Product for use in the Field and in the countries of the COBI Territory, and (C) EVG Product, EVG Combination Product and Quad Product for use in the Field and in the countries of the EVG-Quad Territory.
(i) Licensee agrees that during the period in which the Patents are valid and enforceable (on a Product-by-Product basis) it will prohibit its Distributors from selling Product (A) to any other wholesaler or distributor, (B) outside the Territory for which Licensee is licensed for sale of such Product pursuant to Section 2.2, or (C) for any purpose outside the Field.
(ii) Licensee agrees that it will not administer the TAF Quad to humans, or sell the TAF Quad until Gilead has obtained marketing approval for the TAF Quad from the FDA. Licensee agrees that it will not administer EVG to humans, or sell Products containing EVG until Gilead has obtained marketing approval for an EVG Product from the FDA. Licensee agrees that it will not administer COBI to humans, or sell Products containing COBI until Gilead has obtained marketing approval for a COBI Product from the FDA. Licensee agrees that it will not administer TAF to humans, or sell Products containing TAF until Gilead has obtained marketing approval for a TAF Product from the FDA. If Gilead obtains marketing approval from the FDA for any Quad Product or a Combination Product containing TAF, COBI or EVG (“Approved Combination Product”) prior to obtaining marketing approval for a TAF Product, EVG Product or COBI Product from the FDA, then Licensee will be allowed to administer such Quad Product or such Approved Combination Product to humans, and sell such Quad Product or such Approved Combination Product from and after the date of such marketing approval from the FDA, but will not (A) administer to humans or sell Combination Products containing EVG other than such Quad Product or such Approved Combination Product until Gilead has obtained marketing approval from the FDA for an EVG Product, or (B) administer to humans or sell Combination Products containing COBI other than such Quad Product or such Approved Combination Product until Gilead has obtained marketing approval from the FDA for a COBI Product or (C) administer to humans or sell Combination Products containing TAF other than such Quad Product or such Approved Combination Product until Gilead has obtained marketing approval from the FDA for a TAF Product.
Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Computer Equipment Recycling Program If this Contract is for the purchase or lease of computer equipment, then Contractor certifies that it is in compliance with Subchapter Y, Chapter 361 of the Texas Health and Safety Code related to the Computer Equipment Recycling Program and the Texas Commission on Environmental Quality rules in 30 TAC Chapter 328.
Combination Products If a LICENSED PRODUCT is sold to any third party in combination with other products, devices, components or materials that are capable of being sold separately and are not subject to royalties hereunder (“OTHER PRODUCTS,” with the combination of products being referred to as “COMBINATION PRODUCTS” and the Other Product and Licensed Product in such Combination Product being referred to as the “COMPONENTS”), the NET SALES of such LICENSED PRODUCT included in such COMBINATION PRODUCT shall be calculated by multiplying the NET SALES of the COMBINATION PRODUCT by the fraction A/(A+B), where A is the average NET SALES price of such LICENSED PRODUCT in the relevant country, as sold separately, and B is the total average NET SALES price of all OTHER PRODUCTS in the COMBINATION PRODUCT in the relevant country, as sold separately. If, in any country, any COMPONENT is not sold separately, NET SALES for royalty determination shall be determined by the formula [C / (C+D)], where C is the aggregate average fully absorbed cost of the Licensed Product components during the prior Royalty Period and D is the aggregate average fully absorbed cost of the other essential functional components during the prior Royalty Period, with such costs being determined in accordance with generally accepted accounting principles. To the extent that any SUBLICENSE INCOME relates to a COMBINATION PRODUCT or is otherwise calculated based on the value of one or more licenses or intellectual property rights held by the COMPANY, an AFFILIATE or SUBLICENSEE, COMPANY shall determine in good faith and report to THE PARTIES the share of such payments reasonably attributable to COMPANY’s or such AFFILIATE’s sublicense of the rights granted hereunder, based upon their relative importance and proprietary protection, which portion shall be the SUBLICENSE INCOME. THE PARTIES shall have the right to dispute such sharing determination in accordance with the dispute provisions of the AGREEMENT.
