Project Completion Documents Sample Clauses

Project Completion Documents. The CLIENT has received four (4) copies of the following project completion documents a. Final detailed project costs b. All amended exhibits c. All as−built documentation d. Operating manual including vendor cut sheet giving general instructions and installation instructions, name plate data, parts list along with local service representative and pricing sheet, detailed system description with operating instruction, and detailed adjustment instructions including alignments, tolerances, etc. e. Manufacturer warranty documentation and information including contact names and telephone numbers. f. Tax credit documentation
Sample 1Sample 2
Project Completion Documents. The DISTRICT acknowledges receipt of the following project completion documents: a. Final detailed project costs b. All amended exhibits c. One (1) hard copy and one (1) electronic copy (as practicable) of: i. As-built drawings ii. Operation and maintenance manuals iii. Manufacturer Warranty Information iv. Contact names and numbers of all vendors and applicable service representatives
Sample 1
Project Completion Documents. Landlord-with reimbursement from the Tenant Improvement Allowance except the certificate of completion shall be at Landlord's sole cost if costs related to the issuance thereof is from an Overage.
Sample 1
Project Completion Documents. The Client acknowledges receipt of finalized project costs, all amended exhibits, as-built drawings, operations and maintenance manuals, manufacturer warranty information, contact names and numbers of all vendors and applicable service representatives, and training required under this Agreement. 200 HVAC Upgrades 300 Roofing Upgrades 400 Domestic Water Heaters 1. Date of Final Completion Customer accepts Services as fully complete and assumes full possession of the scope of work as of the Date of Final Completion. Upon execution of this certificate, Customer shall pay all applicable retention to H&H. River Valley School District H&H Energy Services, Inc. Signature: Signature: Printed Name: Printed Name: Xxxx Xxxxxxx Title: Title: Vice President Date: Date: The Client hereby agrees to assume the following responsibilities as part of this Agreement: 1. Maintain and/or Replace Faulty Equipment a. The Client shall properly maintain all equipment that is being repaired, replaced or modified as a result of the Work, or that will have an impact on the Contractor’s ability to meet the Performance Guarantee. When it is necessary to replace the equipment that affects the Contractor’s ability to meet the Performance Guarantee, the Client shall replace it with an equipment of at least equal energy and operational efficiencies. b. Upon receiving a written notice from the Contractor describing any operational or maintenance deficiency, the Client shall immediately make arrangements to remedy the deficiency. Once the deficiency is corrected, the Client shall notify the Contractor to perform inspection on the remedial improvements.
Sample 1
Project Completion Documents. Landlord.
Sample 1

Related to Project Completion Documents

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall allow the Construction Manager to utilize the information uploaded into Owner’s PMIS to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Model coordination shall occur at all reviews during the Construction Documents Phase as identified in the BIM Execution Plan. Architect/Engineer shall utilize Owner’s PMIS to accomplish model coordination and collaborate with Construction Manager in the resolution of critical clashes identified by the Construction Manager. Architect/Engineer shall demonstrate and provide written assurance to Owner that conflicts/collisions between models have been resolved. 1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract. 1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project. 1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development. 1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments. 1.4.8 The Architect/Engineer shall provide a list of all manufacturer warranties and submittals that are required by their specification. 1.4.9 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.

  • Construction Documents Phase Services 3.4.1 Based on the Owner’s approval of the Design Development Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Construction Documents for the Owner’s approval. The Construction Documents shall illustrate and describe the further development of the approved Design Development Documents and shall consist of Drawings and Specifications setting forth in detail the quality levels and performance criteria of materials and systems and other requirements for the construction of the Work. The Owner and Architect acknowledge that, in order to perform the Work, the Contractor will provide additional information, including Shop Drawings, Product Data, Samples and other similar submittals, which the Architect shall review in accordance with Section 3.6.4.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project: A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 or 2024, as applicable and as amended

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.

  • Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof. 6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement. 6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement. 6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER. 6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing. 6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8. 6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.

  • Acquisition Documents Borrower shall fully perform in all material respects all of its obligations under all Acquisition Documents, and shall enforce all of its rights and remedies thereunder as it deems appropriate in its reasonable business judgment; provided, however, that Borrower shall not take any action or fail to take any action which would result in a waiver or other loss of any material right or remedy of Borrower thereunder. Without limiting the generality of the foregoing, Borrower shall take all action necessary or appropriate to permit, and shall not take any action which would have a Material Adverse Effect upon, the full enforcement of all indemnification rights under all the Acquisition Documents. Borrower shall not, without Administrative Agent's prior written consent, modify, amend, supplement, compromise, satisfy, release or discharge any material provision of the Acquisition Documents, any material collateral securing the same, any Person liable directly or indirectly with respect thereto, or any material agreement relating to the Acquisition Documents or the collateral therefor. Borrower shall notify Administrative Agent in writing promptly after Borrower becomes aware thereof, of any event or fact which could give rise to a claim by it for indemnification under any of the Acquisition Documents to the extent such claims in the aggregate exceed $100,000.00, and shall diligently pursue such right and report to Administrative Agent on all further developments with respect thereto. If an Event of Default then exists, Borrower shall remit directly to Administrative Agent, for application to the Loan Obligations in such order as Administrative Agent determines, all amounts received by Borrower as indemnification or otherwise pursuant to the Acquisition Documents. If Borrower fails after Administrative Agent's demand to pursue diligently any right under any of the Acquisition Documents, or if an Event of Default then exists, then Administrative Agent may directly enforce such right in its own or Borrower's name and may enter into such settlements or other agreements with respect thereto as Administrative Agent determines. Notwithstanding the foregoing, Borrower shall at all times remain liable to observe and perform all of its duties and obligations under all the Acquisition Documents, and Administrative Agent's exercise of any of its rights with respect to the Collateral shall not release Borrower from any of such duties or obligations. Administrative Agent shall not be obligated to perform or fulfill any of Borrower's duties or obligations under any of the Acquisition Documents or to make any payment thereunder, or to make any inquiry as to the sufficiency of any payment or property received by it thereunder or the sufficiency of performance by any party thereunder, or to present or file any claim, or to take any action to collect or enforce any performance or payment of any amounts, or any delivery of any property.