PUNCH LISTS. 1. Within fourteen (14) days following receipt of the CMR’s written notification of Substantial Completion (including a CMR’s Punch List, as set forth in Paragraph 11.6.A), the Owner’s Representative shall conduct an inspection of the Work and compile a comprehensive list of deficiencies and incomplete Work (i.e. Architect’s Punch List). The Owner’s Representative shall then issue a Consolidated Punch List incorporating the CMR’s and the Architect’s Punch Lists into a single list in a uniform format (“Consolidated Punch List”).
2. Following issuance of the Consolidated Punch List, the CMR shall have thirty (30) days to complete the Work contained thereon and to achieve Final Completion, unless otherwise specified in the Contract Documents. If the Work for which Final Completion is requested is not Finally Complete within the required period, it is understood and agreed by all parties that the CMR shall become liable to the Owner for Liquidated Damages as established by the Contract, which shall continue in effect until the applicable Final Completion has been achieved.
3. If the Owner has taken beneficial occupancy or has commenced use of any aspect of the Work prior to the date required for Substantial Completion of that portion of the Work, the Contractor shall notify the Owner in a timely manner when access to such occupied or in use space or facilities is required, obtain Owner’s approval to, and coordinate access to, the spaces or facilities without disrupting the use thereof by the Owner. Until the date required for Substantial Completion of any portion of the Work occupied or used by Owner, any impact upon the Contract Period or the Contract Sum arising from such occupancy or use shall be governed by the claims submittal procedures and requirements of the Contract Documents. If the Owner takes or continues occupancy or commences or continues use of any aspect of the Work after the date required for Substantial Completion, and the Contractor requires access to the occupied or in use space or facility prior to achieving Substantial Completion, the Contractor shall notify the Owner in a timely manner, obtain Owner’s approval to, and coordinate access to, the spaces or facilities without disrupting the Owner’s use thereof. Should the Contractor access to such spaces or facilities to perform any portion of the Work, including but not limited to Punch List item repairs, require the temporary removal of furniture or other items and furnishings put in place...
PUNCH LISTS. Tenant's taking possession of the Premises will be conclusive evidence that such Premises was in good order and satisfactorily condition, and that all of Landlord's Work in or to the Premises was satisfactorily completed when Tenant took possession, except as to any latent defects or uncompleted items identified on (i) a punch list prepared and signed by Landlord's Representative and Tenant's Representative after an inspection of the Premises by both such parties made within five business days after Landlord tenders possession of the Premises to Tenant, or (ii) a punch list which Landlord will cause its architect to prepare on or before the same date, and except as to any latent defects in Landlord's Work of which Tenant notifies Landlord within one year after the Commencement Date. Landlord will commence the completion or correction of any matters set forth on such punch lists within 10 days after such lists are received by Landlord, will complete all items within 30 days after such lists are prepared, except for any of such items which, due to reasons beyond Landlord's control, cannot be completed within such time and, as to such delayed items, Landlord will thereafter diligently pursue completion. Landlord will not be responsible for any items of damage caused by Tenant, its agents, independent contractors or suppliers. No promises to construct, alter, remodel or improve the Premises, and no representations concerning the condition of the Premises, have been made by Landlord to Tenant other than as may be expressly stated in this Lease. Any dispute between Landlord and Tenant as to which items should be included on such punch lists, or which items on such punch lists have been completed, shall be subject to Arbitration.
PUNCH LISTS. Upon substantial completion of each project, Consultant shall assist Owner with the preparation of the project punch-list. Prior to substantial completion, while mechanical, electrical and plumbing ("MEP") systems and components are still accessible, Consultant or Consultant's Team shall visit the applicable project and prepare MEP punch-lists and advise Owner of any corrective actions required for compliance with the contract documents for construction and other project documents for such applicable project and all applicable Laws.
PUNCH LISTS. The consultant shall create punch lists as necessary in CM for remedial work which needs to be performed the contractor. The consultant shall monitor and report the contractor’s progress in completing punch list items.
PUNCH LISTS. Consultant shall develop and maintain construction punch lists and coordinate the completion and correction of the punch list items with the Contractor.
PUNCH LISTS. The goal of our construction project is to have a zero-punch list job; consequently, Xxxxxxxx uses a Rolling Completion List (RCL). The RCL’s start at the beginning of the job and continue throughout the project. Items of incomplete or deficient work appear on the RCL on a weekly basis and are addressed at that time. The items are not removed from the RCL until the corrections have been made. Along with the RCL’s, a site-specific Field Superintendent will work with the Client to develop and implement a QC Plan. He will report to the Project Manager and have the responsibility of dealing with any items on the RCL. He will, in conjunction with the Client, make a determination of the remaining work required for completion, incorporate the work into the RCL and insure completion of the work.
PUNCH LISTS. Supplier Contracts shall require, in connection with applications for any RFS Certificate, that the Supplier deliver to the Owner for its approval a written punch list (the "PUNCH LIST") of items of Supply or Procured Services to be completed or supplied, which shall specify estimated cost to complete or supply each such item. Upon the Owner's approval of any Punch List, the Owner may withhold from the retainage or any other amount paid to the Supplier upon the issuance of the applicable RFS Certificate, an amount (the "PUNCH LIST RESERVE") equal to [REDACTED]of the cost of completing or correcting all items identified on the relevant Punch List.
PUNCH LISTS. “Punch List” means a list of minor items on the Project that remains for Contractor to complete or correct following the Substantial Completion Date, including all items necessary for the Project to be 100% complete.
PUNCH LISTS. 5.11.1 Developer shall include in the Quality Management Plan procedures and schedules for preparing the Functional Area Punch Lists and the Project Punch List, and for completing the applicable Punch List work. Such procedures and schedules shall be in accordance with the requirements of Sections 5.11.2 through 5.11.5.
5.11.2 Developer shall prepare and maintain each Punch List. Developer shall schedule preparation of the Punch List so as to permit the Owner’s review and inspection for Functional Area Readiness under Section 5.9.2 or for Project Substantial Completion under Section 5.10.2, as applicable.
5.11.3 Developer shall deliver to the Owner not less than five (5) days’ prior written notice stating the date when Developer will commence Punch List field inspections and Punch List preparation. Developer shall cause the Lead Contractor, the Architect(s) of Record, the Engineer(s) of Record, and any other Key Contractor or Key Personnel reasonably requested by the Owner, to participate in the development of the Punch List. The Owner may, but is not obligated to, participate in the development of the Punch List. The Owner shall have the right in its reasonable discretion to add items to the Punch List in a timely manner to address incomplete Work or Work that is not in compliance with the Contract Documents prior to the finalization of such Punch List, provided that Developer shall provide the proposed final Punch List and the Owner shall have 7 days within which to add or modify items on the proposed final Punch List. Developer shall deliver to the Owner a true and complete copy of the Punch List, and each modification thereto, as soon as it is prepared.
5.11.4 The Punch List inspection shall be performed on all definable features of the Work, against the Plans, the Contract Documents and applicable Laws, and note any discrepancies in the Work. Developer shall review the Project Records to ensure that all items addressed by Nonconformance Reports have been corrected, or have been included on the Punch List for corrective action.
5.11.5 Developer shall promptly commence work on the Punch List items and diligently prosecute such work to completion, consistent with the Contract Documents, the Issued for Construction Documents and the Construction Documents within the time period to be set forth in the Project Management Plan and, in any case, complete such work within 90 days following the earlier of the applicable Functional Area Readiness Date or the Pro...
PUNCH LISTS. A. If Tenant's Contractor constructs the Initial Leasehold Improvements, then on or within five (5) Business Days after Landlord delivers each floor of the Premises to Tenant with all Base Building items and Base Building Upgrades substantially complete, Landlord and Tenant shall make a preliminary walkthrough inspection of such floor and prepare a punch list of defective and incomplete work requiring correction or completion by Landlord. Any disputes as to the nature or existence of any punch list item shall be resolved by the Arbitrator described in Paragraph 17 hereof. Subject to Force Majeure, Landlord shall correct or complete all items on such punch list within thirty (30) days after delivering such floor to Tenant.
B. If Landlord's Contractor constructs the Initial Leasehold Improvements, then on or within five (5) Business Days after the date the Lease Term commences for each floor of the Premises, Landlord and Tenant shall make a preliminary walk-through inspection of such floor and prepare a punch list of defective and incomplete work requiring correction or completion by Landlord. Any disputes as to the nature or existence of any punch list item shall be resolved by the Arbitrator described in Paragraph 17 hereof. Subject to Force Majeure, Landlord shall correct or complete all items on such punch list within thirty (30) days after the date the Lease Term commences for such floor.
