Records and Progress Reports Sample Clauses

Records and Progress Reports. ARIS shall keep full and accurate records of all of its labor hours and reimbursable expenses incurred in connection with this Agreement. ARIS shall provide access to such records upon Customer's reasonable request. ARIS will make periodic status or progress reports to Customer at such times and in such form as is mutually agreed in the applicable Work Order.
Sample 1
AutoNDA by SimpleDocs
Records and Progress Reports. At mutually agreeable times during the Development Program, the Project Managers of both Parties will meet, at least by telephone, to compare the status of the development. Each Party will maintain and distribute, approximately bi-monthly during the course of the Development Program, a written progress report in a form reasonably mutually acceptable, which shall include any matter anticipated to delay completion of any Milestone and the reason for, and anticipated extent of, such delay.
Sample 1Sample 2
Records and Progress Reports. Document and maintain accurate records. Document all client contact and provide said documentation to COUNTY within 3 business days of request. Progress report shall include but not limited to, attendance including absences, successful completion, concerns for safety, progress in the integration of change, and other pertinent information to assess client’s behavioral change.
Sample 1Sample 2
Records and Progress Reports. ARIS shall keep full and accurate records of all of its labor hours and reimbursable expenses incurred in connection with this Agreement. ARIS shall provide access to such records upon Customer's reasonable request. Such records will be available for audit ninety (90) days after the event and remain available for four (4) years after the termination date and for four (4) years after completion of all work authorized hereunder. ARIS will make periodic progress reports to Customer at such times and in such form as is mutually agreed in the applicable Work Order.
Sample 1
Records and Progress Reports. The Sublessee shall maintain copies of all requisition forms and Project Contracts, including but not limited to subcontracts, purchase orders and procurement documents, and provide copies to the State and the Assistance Board upon request. All such documents and records relating to the Project shall be retained by the Sublessee during the term of this Sublease and shall be provided to the State upon request. The Trustee is required under the Indenture to provide to the Sublessee at its request an accounting of all receipts and disbursements from the Sublessee’s Project Account. The Sublessee shall provide monthly progress reports to the Assistance Board, which progress reports shall provide at a minimum, photos of the Project, a current line item budget, a current Project budget compared to the State approved Project budget, and an updated Project schedule compared to the State approved Project schedule. MATCHING MONEYS Sublessee’s Obligation to Pay Matching Moneys. Certain information regarding the Sublessee’s obligation to pay Matching Moneys with respect to its Project is set forth in Exhibit D hereto.
Sample 1
Records and Progress Reports 
Sample 1

Related to Records and Progress Reports

  • Progress Reports The Recipient shall submit to the OPWC, at the OPWC's request, summary reports detailing the progress of the Project pursuant to this Agreement and any additional reports containing such information as the OPWC may reasonably require.

  • Access to Records and Properties (a) From the date hereof until the Closing Date or earlier termination of this Agreement, Seller will, and will cause the Companies and their Subsidiaries to:

  • RECORDS AND STATEMENTS The records of the Trustee pertaining to the Plan must be open to the inspection of the Plan Administrator, the Advisory Committee and the Employer at all reasonable times and may be audited from time to time by any person or persons as the Employer, Plan Administrator or Advisory Committee may specify in writing. The Trustee must furnish the Plan Administrator or Advisory Committee with whatever information relating to the Trust Fund the Plan Administrator or Advisory Committee considers necessary.

  • Books and Records Reports (a) The Trustees shall keep a certified copy or duplicate original of this Trust Agreement on file at the office of the Trust and the office of the Administrator available for inspection at all reasonable times during its usual business hours by any Holder. The Trustees shall keep proper books of record and account for all the transactions under this Trust Agreement at the office of the Trust and the office of the Administrator, and such books and records shall be open to inspection by any Holder at all reasonable times during usual business hours. The Trustees shall retain all books and records in compliance with Section 31 of the Investment Company Act and the rules and regulations thereunder.

  • Records Reports To maintain records and to prepare and file reports required by law to be filed by the Trustee or required by agreement with the Company;

  • Records, Audits and Reports At the expense of the Company, the Managers shall maintain records and accounts of all operations and expenditures of the Company.

  • Books Records and Reports 6 19. The Contractor shall establish and maintain accounts and other books and records 7 pertaining to administration of the terms and conditions of this Settlement Contract, including: 8 the Contractor's financial transactions, water supply data, and Project land and right-of-way 9 agreements; the water users' land-use (crop census), land ownership, land-leasing and water use 10 data; and other matters that the Contracting Officer may require. Reports thereon shall be 11 furnished to the Contracting Officer in such form and on such date or dates as the Contracting 12 Officer may require. Subject to applicable Federal laws and regulations, each party to this 13 Settlement Contract shall have the right during office hours to examine and make copies of each 14 other’s books and official records relating to matters covered by this Settlement Contract.

  • Inspection of Records and Reports Every Trustee shall have the right at any reasonable time to inspect all books, records, and documents of every kind and the physical properties of the Trust. This inspection by a Trustee may be made in person or by an agent or attorney and the right of inspection includes the right to copy and make extracts of documents. No Shareholder shall have any right to inspect any account, book or document of the Trust that is not publicly available, except as conferred by the Trustees. The books and records of the Trust may be kept at such place or places as the Board of Trustees may from time to time determine, except as otherwise required by law.

  • Books and Records; Audits Licensee shall prepare and maintain, in such manner as will allow its accountants to audit same in accordance with generally accepted accounting principles, complete and accurate books of account and records (specifically including without limitation the originals or copies of documents supporting entries in the books of account) in which accurate entries will be made covering all transactions, including advertising expenditures, arising out of or relating to this Agreement. Licensee shall keep separate general ledger accounts for such matters that do not include matters or sales related to this Agreement. Licensor and its duly authorized representatives shall have the right, for the duration of this Agreement and for one (1) year thereafter, during regular business hours and upon seven (7) business days advance notice (unless a shorter period is appropriate in the circumstances), to audit said books of account and records and examine all other documents and material in the possession or under the control of Licensee with respect to the subject matter and the terms of this Agreement, including, without limitation, invoices, credits and shipping documents, and to make copies of any and all of the above. All such books of account, records, documents and materials shall be kept available by Licensee for at least two (2) years after the end of the Annual Period to which they relate. If, as a result of any audit of Licensee's books and records, it is shown that Licensee's payments were less than the amount which should have been paid by an amount equal to *% or more of the payments actually made with respect to sales occurring during the period in question, Licensee shall reimburse Licensor for the cost of such audit and shall make all payments required to be made (along with accrued interest at the rate of *%)) to eliminate any discrepancy revealed by said audit within ten (10) days after Licensor's demand therefore.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!