We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

SECURE HVAC Sample Clauses

SECURE HVACDEDICATED HVAC FOR LOBBIES, MAILROOMS, AND LOADING DOCKS (NOV 2005) SECTION 4 DESIGN, CONSTRUCTION, AND POST AWARD ACTIVITIES 4.01 SCHEDULE FOR COMPLETION OF SPACE (AUG 2011) X. Xxxxxx-provided design intent drawings (DIDs): The Lessor must submit to DOE, as part of the shell cost, complete DIDs conforming to the requirements of this Lease and other Government-supplied information related to the tenant agency's interior build-out requirements not later than 30 working days following the lease award date, provided that the Government supplies such information and direction as reasonably required for Lessor to timely complete DIDs. The Government (DOE and the tenant agency) shall attend two meetings at the Lessor's request for the purpose of providing information and direction in the development of DIDs. The Lessor should anticipate at least two submissions of DIDs before receiving approval.
AutoNDA by SimpleDocs
SECURE HVACDEDICATED HVAC FOR LOBBIES, MAILROOMS, AND LOADING DOCKS (BUILDING SHELL) (NOV 2005) To prevent widespread dispersion of a contaminant released within lobbies, mailrooms, and loading docks, the associated HVAC systems shall be isolated and the areas maintained by a dedicated exhaust system at a negative pressure relative to the rest of the building, but at a positive pressure relative to the outdoors. Physical isolation of these areas (well-sealed floor to roof-deck walls, sealed wall penetrations) is critical to maintaining the pressure differential and requires special attention to ensure airtight boundaries between these areas and adjacent spaces. A qualified HVAC professional can assist in determining if the recommended isolation is feasible for a given building. A modification to an existing system will likely require a re-evaluation of the existing HVAC system as well as potentially involving architectural and/or structural changes to the building. Any re-engineering of HVAC systems shall be estimated and costs identified to the Contracting Officer before beginning any proposed alterations. In addition, lobbies, mailrooms, and loading docks shall not share a return-air system. The Lessor shall provide lobby, mailroom, and loading dock ventilation systems' outside air intakes and exhausts with low leakage, fast acting, isolation dampers that can be closed to isolate their systems. Dedicated HVAC will be required for mailrooms only when the Government specifically requires a centrallyoperated mailroom. Non-Government building tenants may share the mailroom. Where possible, the mailroom shall be adjacent to the loading dock to prevent the possible contamination of additional areas within the building. Any mailroom or area where mail is received and sorted, shall have posted the telephone numbers of the Lessor/Owner’s building manager/engineer and local emergency personnel for emergency notification. Mailrooms shall also have posted a copy of the general precautions for mail handling.
SECURE HVAC. SECURE RETURN-AIR GRILLES (NOV 2005)
SECURE HVAC. AIRBORNE HAZARDS (NOV 2005)
SECURE HVAC. OUTDOOR AIR INTAKES (NOV 2005) A. Outdoor air intakes shall be relocated. The lowest edge of the outdoor air intakes shall be placed 40 feet, 0 inches above grade and not less than 30 feet, 0 inches from the loading dock. Access shall be locked and secured, if feasible. For increased visibility of suspicious items, moat areas and other ground level areas surrounding outside air intakes shall be completely free of trash, debris or any other matter. B. Outdoor air intakes shall be extended. If relocation is not feasible, as approved by the Government, intake extensions shall be constructed without creating adverse effects on HVAC performance. The higher the extensions, the better, as long as other design constraints (excessive pressure loss, dynamic and static loads on structure) are considered. An extension height of 40 feet, 0 inches is required unless adverse effects on HVAC performance can be demonstrated. The entrance to the intake shall be covered with a sloped metal mesh to reduce the threat of objects being tossed in the intake. A minimum slope of 45 degrees may be required. Extension height shall be increased where existing platforms or building features (e.g., loading docks, retaining walls) might provide access to the outdoor air intakes. C. A security zone around outdoor air intakes shall be established. When outdoor air intakes are publicly accessible and relocation or physical extensions are not viable options or are cost prohibitive, perimeter barriers that prevent public access to outdoor air intake areas shall be required based on the Government’s building security assessment. Iron fencing or similar see-through barriers may be required. The restricted area shall also include an open buffer zone between the public areas and the intake louvers. The Government will have the right to monitor the buffer zone by physical security and/or closed circuit television (CCTV). Security lighting or intrusion detection sensors are required and shall be provided and installed by the Lessor.

Related to SECURE HVAC

  • Capacity Interconnection Rights Pursuant to and subject to the applicable terms of the Tariff, the Interconnection Customer shall have Capacity Interconnection Rights at the Point(s) of Interconnection specified in this Interconnection Service Agreement in the amount of 33.6

  • Equipment and Tools 40.01 The Employer will make available all necessary tools and equipment it requires for the performance of work assignments at no cost to the employees. Such tools and equipment will remain the property of the Employer and the employees will be required to take reasonable care of this property and may be required to sign out certain equipment and tools.

  • Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).

  • Contractor’s Equipment The Contractor shall be responsible for all Contractor’s Equipment. The Contractor’s Equipment shall be deemed to be exclusively intended for the execution of the Works.

  • Security Management The Contractor shall comply with the requirements of the DOD 5200.1-M and the DD Form 254. Security of the Contractor’s electronic media shall be in accordance with the above documents. Effective Program Security shall require the Contractor to address Information Security and Operations Security enabled by the Security Classification Guides. The Contractor’s facility must be able to handle and store material up to the Classification Level as referenced in Attachment J-01, DD Form 254.

  • One-Way Interconnection Trunks 2.3.1 Where the Parties use One-Way Interconnection Trunks for the delivery of traffic from Onvoy to Frontier, Onvoy, at Onvoy’s own expense, shall: 2.3.1.1 provide its own facilities for delivery of the traffic to the technically feasible Point(s) of Interconnection on Frontier’s network in a LATA; and/or 2.3.1.2 obtain transport for delivery of the traffic to the technically feasible Point(s) of Interconnection on Frontier’s network in a LATA (a) from a third party, or, (b) if Frontier offers such transport pursuant to a Frontier access Tariff, from Frontier. 2.3.2 For each Tandem or End Office One-Way Interconnection Trunk group for delivery of traffic from Onvoy to Frontier with a utilization level of less than sixty percent (60%) for final trunk groups and eighty-five percent (85%) for high usage trunk groups, unless the Parties agree otherwise, Onvoy will promptly submit ASRs to disconnect a sufficient number of Interconnection Trunks to attain a utilization level of approximately sixty percent (60%) for all final trunk groups and eighty-five percent (85%) for all high usage trunk groups. In the event Onvoy fails to submit an ASR to disconnect One-Way Interconnection Trunks as required by this Section, Frontier may disconnect the excess Interconnection Trunks or bill (and Onvoy shall pay) for the excess Interconnection Trunks at the rates set forth in the Pricing Attachment. 2.3.3 Where the Parties use One-Way Interconnection Trunks for the delivery of traffic from Frontier to Onvoy, Frontier, at Frontier’s own expense, shall provide its own facilities for delivery of the traffic to the technically feasible Point(s) of Interconnection on Frontier’s network in a LATA.

  • NYISO and Connecting Transmission Owner Obligations Connecting Transmission Owner and NYISO shall cause the New York State Transmission System and the Connecting Transmission Owner’s Attachment Facilities to be operated, maintained and controlled in a safe and reliable manner in accordance with this Agreement and the NYISO Tariffs. Connecting Transmission Owner and NYISO may provide operating instructions to Developer consistent with this Agreement, NYISO procedures and Connecting Transmission Owner’s operating protocols and procedures as they may change from time to time. Connecting Transmission Owner and NYISO will consider changes to their respective operating protocols and procedures proposed by Developer.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Infrastructure Vulnerability Scanning Supplier will scan its internal environments (e.g., servers, network devices, etc.) related to Deliverables monthly and external environments related to Deliverables weekly. Supplier will have a defined process to address any findings but will ensure that any high-risk vulnerabilities are addressed within 30 days.

  • Installation, Maintenance, Testing and Repair Unless otherwise agreed in writing by the Parties, to the extent required by Applicable Law, Interconnection provided by a Party shall be equal in quality to that provided by such Party to itself, any subsidiary, affiliates or third party. If either Party is unable to fulfill its obligations under this Section 14.2, it shall notify the other Party of its inability to do so and will negotiate alternative intervals in good faith. The Parties agree that to the extent required by Applicable Law, the standards to be used by a Party for isolating and clearing any disconnections and/or other outages or troubles shall be at parity with standards used by such Party with respect to itself, any subsidiary, affiliate or third party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!