Service or Work Sample Clauses

Service or Work. Contractor agrees to procure the materials, equipment and/or products necessary for the Project and agrees to diligently provide all services, labor, personnel and materials necessary to perform and complete the Project described in Exhibit which is attached hereto and incorporated herein by reference. Contractor shall further be responsible for the timely completion, and acknowledges that a failure to comply with the standards and requirements of Exhibits and within the time limits prescribed by County may result in County’s decision to withhold payment or to terminate this Agreement.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Service or Work. Contract Professional agrees to procure the materials, equipment and/or products necessary for the project and agrees to diligently provide all services, labor, personnel and materials necessary to perform and complete the project described in Exhibit which is attached hereto and incorporated herein by reference. Contract Professional shall coordinate with Weld County to perform the services described on attached Exhibits and . Contract Professional shall faithfully perform the work in accordance with the standards of professional care, skill, training, diligence and judgment provided by highly competent Contract Professionals performing services of a similar nature to those described in this Agreement. Contract Professional shall further be responsible for the timely completion, and acknowledges that a failure to comply with the standards and requirements of Exhibits and within the time limits prescribed by County may result in County’s decision to withhold payment or to terminate this Agreement.
Sample 1Sample 2Sample 3See All (4)
Service or Work. Contractor agrees to procure the materials, equipment and/or products necessary for the Project and agrees to diligently provide all services, labor, personnel and materials necessary to perform and complete the Project described in Exhibit which is attached hereto and incorporated herein by reference. Contractor shall coordinate with, the Weld County Director of Public Works or other designated supervisory personnel, (the “Manager”), to perform the services described on attached Exhibits and . Contractor shall faithfully perform the work in accordance with the standards of professional care, skill, training, diligence and judgment provided by highly competent Contractors performing construction services of a similar nature to those described in this Agreement. Contractor shall further be responsible for the timely completion, and acknowledges that a failure to comply with the standards and requirements of Exhibits and within the time limits prescribed by County may result in County’s decision to withhold payment or to terminate this Agreement. In its sole discretion, the County, by the Director increase the compensation to be paid to the Contractor nor change any other term herein. of the Department of Public Works or his or her designee, may extend the time for the Contractor to complete the service or work, by not more than thirty (30) days. Such extension shall not Comment [WCG12]: Burden on county to renew or not, make sure there is some sort of notification of this so department knows to address in a years time.
Sample 1
Service or Work. Contractor agrees to procure the materials, equipment and/or products necessary for the Project and agrees to diligently provide all services, labor, personnel and materials necessary to perform and complete the Project described in Exhibit which is attached hereto and incorporated herein by reference. Contractor shall coordinate with, the Weld County Director of Public Works or other designated supervisory personnel, (the “Manager”), to perform the services described on attached Exhibits and . Contractor shall faithfully perform the work in accordance with the standards of professional care, skill, training, diligence and judgment provided by highly competent Contractors performing construction services of a similar nature to those described in this Agreement. Contractor shall further be responsible for the timely completion, and acknowledges that a failure to comply with the standards and requirements of Exhibits and
Sample 1
Service or Work. Contractor agrees to diligently provide all services, labor, personnel and materials necessary to perform and complete the Work described in the attached Exhibits. Services shall be provided by the Contractor to any person(s) eligible for services in compliance with Exhibits A, Scope of Services, and Exhibit D, Contractor’s Response to Request for Proposal. Contractor shall further be responsible for the timely completion and acknowledges that a failure
Sample 1

Related to Service or Work

  • OTHER WORK 14.1 Owner may perform other work related to the Project at the site by Owner’s own forces, have other work performed by utility owners or let other direct contracts. If the fact that such other work is to be performed is not noted in the Contract Documents, written notice thereof will be given to Construction Contractor prior to starting any such other work. If Construction Contractor believes that such performance will involve additional expense to Construction Contractor or require additional time, Construction Contractor shall send written notice of that fact to Owner and Design Professional within seven (7) calendar days of being notified of the other work. If Construction Contractor fails to send the above required seven (7) calendar days’ notice, Construction Contractor will be deemed to have waived any rights it otherwise may have had to seek an extension to the Contract Time or adjustment to the Contract Amount. 14.2 Construction Contractor shall afford each utility owner and other contractor who is a party to such a direct contract (or Owner, if Owner is performing the additional work with Owner’s employees) proper and safe access to the site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such work and shall properly connect and coordinate its Work with theirs. Construction Contractor shall do all cutting, fitting and patching of the Work that may be required to make its several parts come together properly and integrate with such other work. Construction Contractor shall be responsible for all damage to the work of others caused by the performance of its Work. Further, Construction Contractor shall not in any way cut or alter the work of others without first receiving the written consent of that other person and Design Professional. 14.3 If any part of Construction Contractor’s Work depends for proper execution or results upon the work of any other contractor or utility owner (or Owner), Construction Contractor shall inspect and promptly report to Design Professional in writing any delays, defects or deficiencies in such work that render it unavailable or unsuitable for such proper execution and results. Such report must be made within seven (7) calendar days of the time Construction Contractor first became aware of the delay, defect or deficiency or by the scheduled commencement of Construction Contractor’s dependent Work, whichever occurs first. Construction Contractor’s failure to report within the allotted time will constitute an acceptance of the other work as fit and proper for integration with Construction Contractor’s Work.

  • NO CESSATION OF WORK 6.01 Neither the Union nor any employee shall take part in or call or encourage any strike, sit-down, slow-down, or any suspension of work against the Company which shall in any way affect the operations of the Company; nor shall the Company engage in any lockout at its Plants or Mines in the Sudbury District.

  • PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.

  • Performance of Work a. Contractor shall perform all Work in a good and workmanlike manner. Contractor shall maintain sufficient staff and crews to perform all Work in an expeditious manner consistent with the interests of the Park District. Contractor shall promptly notify the Park District immediately in writing: (i) of any information required from the Park District and necessary for Contractor to complete its Work in a timely manner; and (ii) of any Work requested by the Park District or required for the project that is not included in the scope of Work reflected in the Contract Documents. Contractor shall be solely responsible for means and methods selected in performing the Work. Contractor shall supervise all Work so that it is performed in a safe and expeditious manner. Contractor shall be solely responsible for the Work of its employees and its subcontractors’ and suppliers’ employees. Contractor shall keep all documents and information related to the project confidential and, except as required by law, shall not disclose such documents or information to any person or other party except the employees of Contractor and its subcontractors who need such documents or information to perform the Work and complete the project. b. Contractor shall confine all equipment, the storage of materials and the operations of its workers, to limits indicated by law, ordinances, permits, or directions of the Park District and shall not unreasonably encumber the project site with such materials. The project site shall not be utilized for the storage of vehicles, materials, equipment, or fixtures not intended for the Work to be performed. c. Contractor shall notify all utility companies, public and private, as necessary in advance of commencing performance of the Work. The responsibility for moving water lines, gas lines, wire lines, service connections, water and gas meter boxes, water and gas valve boxes, light standards, cable ways, signals and all other utility appurtenances which are within the limits of the proposed construction will be assumed by the Contractor, at no additional compensation. The Contractor shall verify the location of all utilities prior to the start of construction and shall be responsible for the preservation of existing utility installation and the cost of providing precautionary supports, braces, or other equipment to insure against damage to said utility installation. The cost to repair and replace any new or existing utilities damaged will be paid for by the Contractor. d. If Contractor uncovers or discovers any concealed condition differing materially from conditions depicted in the Contract Documents or differing from conditions reasonably anticipated or inherent in the Work, Contractor shall immediately stop the Work and notify the Park District of the condition in writing. The Park District shall then issue written directions. Contractor shall not proceed with the Work until the Park District has issued written directions. The contract time and Contract Sum shall be equitably adjusted if necessitated by such directions of the Park District.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Performance of Work by City If the Contractor fails to perform the Work in accordance with the schedule referred to in section 2 above, the City may, in its discretion, in order to bring the project closer to the schedule, perform or cause to be performed some or all of the Work, and doing so shall not waive any of the City’s rights and remedies. Before doing so, the City shall give the Contractor notice of its intention. The Contractor shall reimburse the City for additional costs incurred by the City in exercising its right to perform or cause to be performed some or all of the Work pursuant to this section.

  • Coordination of Work Licensee shall be responsible for coordination of its Equipment installation work to avoid any interference with existing utilities, substructures, facilities and/or SFMTA transit operations. Licensee shall be the City's point of contact for all Equipment installation and except in case of emergency, all communications concerning Equipment installation shall be through Licensee's field representatives.

  • OF WORK The normal hours of work for an employee are not a guarantee of work per day or per week, or a guarantee of days of work per week. The normal hours of work shall be seven and one-half (7%) hours per day, and seventy-five (75) hours in any period. The normal daily tour shall consist of seven and one-half hours, exclusive of a one-half hour unpaid meal period. Employees shall be entitled to a fifteen (15) minute paid break during each half of the normal daily tour, at a time designated by the Employer. Employees required for reporting purposes shall remain at work for a period of up to fifteen (15) minutes which shall be unpaid. Should the reporting time extend beyond fifteen ( I 5) minutes however, the entire period shall be considered for the purposes of payment. Requests for change in posted work schedules must be submitted in writing and by the employee willing to exchange days off or shifts and are subject to the discretion of the Administrator or her designate. In any event, it is understood that such a change initiated by the employee and approved by the Employer shall not result in overtime compensation or payment or any other claims on the Employer by an employee under the terms of this t Where there is a change to Daylight Savings from Standard Time or vice-versa, an employee who is scheduled and works a full shift shall be paid for a seven and one-half (7.5) hour tour rather than the actual hours worked. The Employer will endeavour to accommodate requests by employees for specific days off and also requests for changes in posted time schedules once the schedule has been posted. Shift schedules shall be posted two (2) weeks in advance and shall cover a minimum of a four (4) week period. The following shall apply to full-time employees: During each pay period, two (2) consecutive days off will be scheduled. Schedules may provide for more than (5) consecutive days of work, but not more than seven (7) consecutive days of work without days off, as long as four (4) days off are scheduled in each fourteen (14) day period. Except as outlined below, meal time of one-half hour shall be scheduled away from the floor during the employee's shift whether day, evening or night. Where there is only one registered employee on duty, it is recognized that this is not possible. Should an employee be recalled to duty during meal time, additional time shall be provided later in the shift.

  • ARTICLE HOURS OF WORK The following provision designating regular hours on a daily tour and regular daily tours over the nursing schedule determined by the Hospital shall not be construed to be a guarantee of the hours of work to be performed on each tour or during each tour schedule. Subject to Article below:

  • Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!