Seven Day Operations (except for clause Sample Clauses

Seven Day Operations (except for clause. 16.03) (a) The standard daily hours, inclusive of meal and rest periods, shall be as follows: 1. eight hours for Chief Engineers/ Senior Chief Engineers and all Deck and Catering personnel; 2. seven and one-half hours for all other employees, except as otherwise provided in this Agreement. (b) The shift schedule shall be on the basis of two days on and one day off. (c) The shift schedules are inclusive of a built-in allowance for designated paid holidays. (d) Regular employees covered under clause 16.01(a)1. shall, on January 1 of each year, be credited with 17 days of paid time off for working an eight hour day. (e) Regular employees receiving temporary appointments to eight hour positions or from eight hour positions covered by this clause shall have their 17 day entitlement recalculated on a monthly basis. (f) Employees appointed to positions covered by clause 16.01(a)1. shall have 17 days of paid time off credited on the basis of 1.42 days for each month remaining in the calendar year. These employees shall receive 1.42 days provided they work ten days in those positions in the first month. Overtime shall apply if they work less than ten days. The reverse is the case for employees leaving positions covered by clause 16.01(a)1.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Seven Day Operations (except for clause. 16.03) (a) The standard daily hours, inclusive of meal and rest periods, shall be as follows: 1. eight (8) hours for all Deck, Catering and Chief Engineer personnel; 2. seven and one-half (7.5) hours for all other employees, except as otherwise provided in this Agreement. (b) The shift schedule shall be on the basis of two (2) days on and one (1) day off. (c) The shift schedules are inclusive of a built-in allowance for designated paid holidays. (d) Regular employees covered under clause 16.01(a)1. shall, on January 1 of each year, be credited with seventeen (17) days of paid time off for working an eight hour day. (e) Regular employees receiving temporary appointments to eight (8) hour positions or from eight (8) hour positions covered by this clause shall have their seventeen (17) day entitlement recalculated on a monthly basis. (f) Employees appointed to positions covered by clause 16.01(a)1. shall have seventeen (17) days of paid time off credited on the basis of 1.42 days for each month remaining in the calendar year. These employees shall receive 1.42 days provided they work ten (10) days in those positions in the first month. Overtime shall apply if they work less than ten (10) days. The reverse is the case for employees leaving positions covered by clause 16.01(a)1. (g) The options outlined under clause 18.14 and clause 18.15 will apply to clause 16.01(d) and clause 16.01(f).
Sample 1Sample 2

Related to Seven Day Operations (except for clause

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Limitations on Assignment Except as specifically provided in Section 22.02 hereof, this Agreement may not be assigned or otherwise transferred by any of the Parties without the express prior written consent of the ISO Board which consent shall not be unreasonably withheld or delayed. Any person to which an assignment or transfer is made shall be required to demonstrate, to the reasonable satisfaction of the ISO Board, that it is capable of fulfilling the requirements of this Agreement, and such assignee shall pay all costs and expenses, including reasonable attorney fees, in connection with such assignment. Unless otherwise expressly provided in a written instrument approved by the ISO Board in connection with the consummation of such assignment or transfer, any such assignment or other transfer by a Party of any of its rights and obligations under this Agreement shall not release, or in any way modify, the assigning or transferring party’s liability for the performance of its obligations hereunder.

  • Representations Relating to Documents and Legal Compliance Borrower represents and warrants to Silicon as follows: All statements made and all unpaid balances appearing in all invoices, instruments and other documents evidencing the Receivables are and shall be true and correct and all such invoices, instruments and other documents and all of Borrower's books and records are and shall be genuine and in all respects what they purport to be, and all signatories and endorsers have the capacity to contract. All sales and other transactions underlying or giving rise to each Receivable shall fully comply with all applicable laws and governmental rules and regulations. All signatures and endorsements on all documents, instruments, and agreements relating to all Receivables are and shall be genuine, and all such documents, instruments and agreements are and shall be legally enforceable in accordance with their terms.

  • Standard of Care; Reliance on Records and Instructions; Indemnification BISYS shall use its best efforts to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Trust for any action taken or omitted by BISYS in the absence of bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties. The Trust agrees to indemnify and hold harmless BISYS, its employees, agents, directors, officers and nominees from and against any and all claims, demands, actions and suits, whether groundless or otherwise, and from and against any and all judgments, liabilities, losses, damages, costs, charges, counsel fees and other expenses of every nature and character arising out of or in any way relating to BISYS' actions taken or nonactions with respect to the performance of services under this Agreement or based, if applicable, upon reasonable reliance on information, records, instructions or requests given or made to BISYS by the Trust, the investment adviser and on any records provided by any fund accountant or custodian thereof; provided that this indemnification shall not apply to actions or omissions of BISYS in cases of its own bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties; and further provided that prior to confessing any claim against it which may be the subject of this indemnification, BISYS shall give the Trust written notice of and reasonable opportunity to defend against said claim in its own name or in the name of BISYS.

  • Terms and Conditions Applicable to Assignment and Subletting (a) Regardless of Lessor's consent, any assignment or subletting shall not: (i) be effective without the express written assumption by such assignee or sublessee of the obligations of Lessee under this Lease, (ii) release Lessee of any obligations hereunder, or (iii) alter the primary liability of Lessee for the payment of Base Rent and other sums due Lessor hereunder or for the performance of any other obligations to be performed by Lessee under this Lease. (b) Lessor may accept any rent or performance of Lessee's obligations from any person other than Lessee pending approval or disapproval of an assignment. Neither a delay in the approval or disapproval of such assignment nor the acceptance of any rent or performance shall constitute a waiver or estoppel of Lessor's right to exercise its remedies for the Default or Breach by Lessee of any of the terms, covenants or conditions of this Lease. (c) The consent of Lessor to any assignment or subletting shall not constitute a consent to any subsequent assignment or subletting by Lessee or to any subsequent or successive assignment or subletting by the sublessee. However, Lessor may consent to subsequent sublettings and assignments of the sublease or any amendments or modifications thereto without notifying Lessee or anyone else liable on the Lease or sublease and without obtaining their consent, and such action shall not relieve such persons from liability under this Lease or sublease. (d) In the event of any Default or Breach of Lessee's obligations under this Lease, Lessor may proceed directly against Lessee, any Guarantors or any one else responsible for the performance of the Lessee's obligations under this Lease, including the sublessee, without first exhausting Lessor's remedies against any other person or entity responsible therefor to Lessor, or any security held by Lessor or Lessee. (e) Each request for consent to an assignment or subletting shall be in writing, accompanied by information relevant to Lessor's determination as to the financial and operational responsibility and appropriateness of the proposed assignee or sublessee, including but not limited to the intended use and/or required modification of the Premises, if any, together with a non-refundable deposit of $1,000 or ten percent (10%) of the current monthly Base Rent, whichever is greater, as reasonable consideration for Lessor's considering and processing the request for consent. Lessee agrees to provide Lessor with such other or additional information and/or documentation as may be reasonably requested by Lessor. (f) Any assignee of, or sublessee under, this Lease shall, by reason of accepting such assignment or entering into such sublease, be deemed, for the benefit of Lessor, to have assumed and agreed to conform and comply with each and every term, covenant, condition and obligation herein to be observed or performed by Lessee during the term of said assignment or sublease, other than such obligations as are contrary to or inconsistent with provisions of an assignment or sublease to which Lessor has specifically consented in writing. (g) The occurrence of a transaction described in Paragraph 12.1

  • GENERAL WORKING CONDITIONS Section 18-1. Employment begins and ends at each project site. Section 18-2. The selection of craft foremen and/or general foremen and the number of foremen required shall be entirely the responsibility of the Employer, it being understood that in the selection of such foremen and/or general foremen the Employer will give primary consideration to the qualified individuals available in the local area. After giving such consideration, the Employer may select such individuals from other areas. All foremen shall take orders from the designated Employer representatives. Craft foremen shall be designated working foremen at the request of the Employer. Section 18-3. There shall be no limit on production by employees nor restrictions on the full use of tools or equipment. Employees using tools shall perform any of the work of the trade and shall work under the direction of the craft foremen. There shall be no restrictions on efficient use of manpower other than as may be required by safety regulations. Section 18-4. Employees shall be at their place of work at the starting time and shall remain at their place of work performing their assigned functions under the supervision of the Employer until quitting time. The parties reaffirm their policy of a fair day’s work for a fair day’s wage. Section 18-5. All equipment assigned to a project shall be under the control of the Employer. The Employer shall have the right to determine how many pieces of equipment an individual employee shall operate. In an emergency, foremen shall operate any equipment assigned by the Employer, and there shall be no restriction on foremen in the use of the tools of his or her craft in such emergency. The foremen shall be from the craft normally operating the equipment. In accordance with currently recognized craft jurisdiction, the Employer shall determine the assignment of employees to start, stop, and maintain small portable construction equipment. Such work may be assigned to craft employees within a reasonable distance of their primary duties or an employee may be assigned full time to start, stop and maintain the Employer’s small, portable equipment on the job site. There shall be no over xxxxxxx of this type of equipment. The number of employees assigned to rigging and scaffolding operations shall be at the sole discretion of the Employer. The ratio of journeyperson to welders shall be determined solely by the Employer. Section 18-6. The Employer may utilize the most efficient methods or techniques of construction, tools or other labor saving devices to accomplish the work. Practices not a part of the terms and conditions of this Agreement, stand by crews and feather bedding practices will not be recognized. Section 18-7. It is recognized that specialized or unusual equipment may be installed and/ or serviced by individuals who have special training, skill, or qualifications and are not covered by this Agreement. Testing, inspection, or service performed on plant equipment under warranty may be performed by the vendor’s personnel. Section 18-8. Neither the Union nor its local unions shall coerce or in any way interfere with the Owner’s personnel, operation or facilities at the plant site. The Owner’s right to contract directly with other companies for work at the plant site shall not be limited, and the Union shall cooperate and not interfere with the Employer’s operations. Section 18-9. It is agreed that overtime is undesirable and not in the best interest of the industry or the employees; therefore, except in unusual circumstances, overtime will not be worked. Where unusual circumstances do exist, however, the Employer will have the right to assign specific employees and/or crews to perform such overtime work as is necessary to accomplish the job. Section 18-10. There will be no rest periods, organized coffee breaks or other non-working time established during working hours. Section 18-11. Individual seniority shall not be recognized or applied to employees working on projects under this Agreement. Section 18-12. The Employer shall establish such reasonable project rules as the Employer deems appropriate. These rules will be reviewed at the pre-job conference and posted at the project site by the Employer, and may be amended thereafter as necessary.

  • Vendor’s Resellers as Related to This Agreement Vendor’s Named Resellers (“Resellers”) under this Agreement shall comply with all terms and conditions of this agreement and all addenda or incorporated documents. All actions related to sales by Authorized Vendor’s Resellers under this Agreement are the responsibility of the awarded Vendor. If Resellers fail to report sales to TIPS under your Agreement, the awarded Vendor is responsible for their contractual failures and shall be billed for the fees. The awarded Vendor may then recover the fees from their named reseller. If there is a dispute between the awarded Vendor and TIPS Member, TIPS or its representatives may, at TIPS sole discretion, assist in conflict resolution if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded Vendor’s TIPS project files, documentation and correspondence related to the requesting TIPS Member’s order. If there are confidentiality requirements by either party, TIPS shall comply to the extent permitted by law. The TIPS Solicitation which resulted in this Vendor Agreement, whether a Request for Proposals, the Request for Competitive Sealed Proposals or Request for Qualifications solicitation, or other, the Vendor’s response to same and all associated documents and forms made part of the solicitation process, including any addenda, are hereby incorporated by reference into this Agreement as if copied verbatim. THE SECTON HEADERS OR TITLES WITHIN THIS DOCUMENT ARE MERELY GUIDES FOR CONVENIENCE AND ARE NOT FOR CLASSIFICATION OR LIMITING OF THE RESPONSIBILITES OF THE PARTIES TO THIS DOCUMENT. Texas governmental entities are prohibited from doing business with companies that fail to certify to this condition as required by Texas Government Code Sec. 2270. By executing this agreement, you certify that you are authorized to bind the undersigned Vendor and that your company (1) does not boycott Israel; and (2) will not boycott Israel during the term of the Agreement. You certify that your company is not listed on and does not and will not do business with companies that are on the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf You certify that if the certified statements above become untrue at any time during the life of this Agreement that the Vendor will notify TIPS within three (3) business day of the change by a letter on Vendor’s letterhead from and signed by an authorized representative of the Vendor stating the non-compliance decision and the TIPS Agreement number and description at: Attention: General Counsel ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx, XX,00000 And by an email sent to xxxx@xxxx-xxx.xxx The undersigned Vendor agrees to maintain the below minimum insurance requirements for TIPS Contract Holders: When the Vendor or its subcontractors are liable for any damages or claims, the Vendor’s policy, when the Vendor is responsible for the claim, must be primary over any other valid and collectible insurance carried by the Member. Any immunity available to TIPS or TIPS Members shall not be used as a defense by the contractor's insurance policy. The coverages and limits are to be considered minimum requirements and in no way limit the liability of the Vendor(s). Insurance shall be written by a carrier with an A-; VII or better rating in accordance with current A.M. Best Key Rating Guide. Only deductibles applicable to property damage are acceptable, unless proof of retention funds to cover said deductibles is provided. "Claims made" policies will not be accepted. Vendor’s required minimum coverage shall not be suspended, voided, cancelled, non-renewed or reduced in coverage or in limits unless replaced by a policy that provides the minimum required coverage except after thirty (30) days prior written notice by certified mail, return receipt requested has been given to TIPS or the TIPS Member if a project or pending delivery of an order is ongoing. Upon request, certified copies of all insurance policies shall be furnished to the TIPS or the TIPS Member. • Orders: All Vendor orders received from TIPS Members must be emailed to TIPS at tipspo@tips- xxx.xxx. Should a TIPS Member send an order directly to the Vendor, it is the Vendor’s responsibility to forward a copy of the order to TIPS at the email above within 3 business days and confirm its receipt with TIPS. • Vendor Encouraging Members to bypass TIPS agreement: Encouraging TIPS Members to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program. • Order Confirmation: All TIPS Member Agreement orders are approved daily by TIPS and sent to the Vendor. The Vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!