Source Code 5.1 Nothing in this XXXX shall give to the User or any other person any right to access or use the Source Code or constitute any licence of the Source Code.
Contract Deliverables The Contractor shall provide information technology staff augmentation services, including comprehensive management of staff, as set forth in this Contract. The term “staff” refers to the temporary staff provided by the Contractor to render information technology services identified by Customers, but that staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks. Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. The Department’s intent is for Contractor’s information technology staff to provide services closely related to those described in the Job Family Descriptions document. Detailed scopes of work, specific requirements of the work to be performed, and any requirements of staff shall be provided by the Customer in a Request for Quote. The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified information technology staff to perform the services requested by the Customer. The Contractor shall provide Customers with staff who must have sufficient skill and experience to perform the services assigned to them. All of the information technology staff augmentation services to be furnished by the Contractor under the Contract shall meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. The Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of staff. The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s information technology staff. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance and approvals of whatever nature that are legally required to perform the information technology staff augmentation services.
SERVICE DELIVERABLES You will receive service on the Covered Product as described below: Carry-In: Unless otherwise provided in this Agreement, the Covered Product must be shipped or delivered and retrieved by You at Our authorized service center during normal business hours. In-Home/On-Site: Service will be performed in Your home or on-site as indicated on the Declarations Page of this Agreement, or on Your sales receipt or invoice provided You have fulfilled the following requirements: (1) provide Our authorized technician with accessibility to the Covered Product; (2) provide a non-threatening and safe environment for Our authorized technician; and (3) an adult over the age of 18 must be present for the period of time Our authorized technician is scheduled to provide service and while Our authorized technician is on Your property servicing the Covered Product. In-Home Service will be provided by Our authorized service provider during regular business hours, local time, Monday through Friday, except holidays. Our authorized service center may opt to remove the Covered Product to perform service in-shop. The Covered Product will be returned upon completion. Additional time and mileage charges for in-home repairs outside of twenty-five (25) contiguous land miles or the normal service radius of Our authorized service center are not covered by this Agreement, and are Your responsibility.
Source Code Escrow On the date hereof, Company shall deliver to an independent third party escrow agent, selected and designated by AMEX and approved by Company (such approval not to be unreasonably withheld) ("Escrow Agent"), for deposit in accordance with an escrow agreement among the Escrow Agent and the parties hereto and substantially in the form attached as Exhibit E ("Escrow Agreement"), a current and complete copy of the source code (the "Source Code") for the Domain Name and any other materials required to operate the Source Code (the "Escrow Materials"). Within [ ** ] of the installation of any new update to the Service (or any other substantial modification to the Source Code, the Domain Name or the Service) or within [ ** ] of the last deposit hereunder, whichever is sooner, Company shall deliver to the Escrow Agent, for deposit in accordance with such Escrow Agreement, any and all changes to the Escrow Materials which correspond to changes, if any, made to the corresponding Escrow Material or shall notify Escrow Agent that no changes were made during the preceding period. All materials deposited hereunder shall be considered "Escrow Materials" as the term is used herein. In the event of (i) the Company's insolvency (as defined in Section 16(e)) or (ii) the Company's material breach of the terms of this Agreement specifically because of its gross negligence or willful misconduct and such breach is not fully remedied within thirty (30) days of AMEX's notice to Company, then notwithstanding any other rights and remedies to which AMEX may be entitled, AMEX shall immediately have the right to obtain a copy of the Escrow Materials from the Escrow Agent upon written notice as provided in the Escrow Agreement for use in continued provision of the Service. AMEX shall have the right, at any time upon at least ten (10) days' written notice to Company and Escrow Agent, to select and designate a new escrow agent to replace the Escrow Agent hereunder. Upon such notice, Escrow Agent shall completely, safely and securely transfer the Escrow Materials to the new escrow agent (which will then become the "Escrow Agent" hereunder) and confirm such transfer in writing to AMEX and Company. ** INDICATES CONFIDENTIAL TREATMENT REQUESTED.
SOURCE CODE ESCROW FOR LICENSED PRODUCT If Source Code or Source Code escrow is offered by either Contractor or Product manufacturer or developer to any other commercial customers, Contractor shall either: (i) provide Licensee with the Source Code for the Product; or (ii) place the Source Code in a third party escrow arrangement with a designated escrow agent who shall be named and identified to the State, and who shall be directed to release the deposited Source Code in accordance with a standard escrow agreement acceptable to the State; or (iii) will certify to the State that the Product manufacturer/developer has named the State, acting by and through the Authorized User, and the Licensee, as a named beneficiary of an established escrow arrangement with its designated escrow agent who shall be named and identified to the State and Licensee, and who shall be directed to release the deposited Source Code in accordance with the terms of escrow. Source Code, as well as any corrections or enhancements to such source code, shall be updated for each new release of the Product in the same manner as provided above and such updating of escrow shall be certified to the State in writing. Contractor shall identify the escrow agent upon commencement of the Contract term and shall certify annually that the escrow remains in effect in compliance with the terms of this clause. The State may release the Source Code to Licensees under this Contract who have licensed Product or obtained services, who may use such copy of the Source Code to maintain the Product.
Software Updates XXXXX agrees to keep current with software licensed from Skyward and will install new versions on a timeline approved by XXXXX governance. This timeline will be communicated by NWRDC to the Districts.
Antivirus software All workstations, laptops and other systems that process and/or store PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY must have installed and actively use comprehensive anti-virus software solution with automatic updates scheduled at least daily.
Service Delivery Grantee shall: 1. Adhere to the Priority Populations for Treatment Programs as stated in the SUD UM Guidelines. 2. Maintain Daily Capacity Management Report in CMBHS as required in the SUD UM Guidelines. 3. Maintain a Waiting List to track all eligible individuals who have been screened but cannot be admitted to SUD treatment immediately. i. Grantee that has an individual identified as a federal and state priority population on the waiting list shall confirm this in the Daily Capacity Management Report. ii. Grantee shall arrange for appropriate services in another treatment facility or provide access to interim services as indicated within 48 hours when efforts to refer to other appropriate services are exhausted. iii. Grantee shall offer directly or through referral interim services to wait-listed individuals. iv. Establish a wait list that includes priority populations and interim services while awaiting admission to treatment services. v. Develop a mechanism to maintain contact with individuals awaiting admission. 4. If unable to provide admissions to individuals within Priority Populations for Treatment Programs according to SUD UM Guidelines: i. Implement written procedures that address maintaining weekly contact with individuals waiting for admissions as well as what referrals are made when a client cannot be admitted for services immediately. ii. When Grantee cannot admit a client, who is at risk for dangerous for withdrawal, Grantee shall ensure that an emergency medical care provider is notified. iii. Coordinate with an alternate provider for immediate admission. iv. Notify Substance Use Disorder (Xxxxxxxxx_Xxx_Xxxxxxxx@xxxx.xxxxx.xx.xx) so that assistance can be provided that ensures immediate admission to other appropriate services and proper coordination when appropriate. v. Provide pre-admission service coordination to reduce barriers to treatment, enhance motivation, stabilize life situations, and facilitate engagement in treatment. vi. Adhere to Informed Consent Document for Opioid Use Disorder applicable to the individual as stated in the SUD UM Guidelines. vii. When an individual is placed on the Wait List, Grantee shall document interim services as referrals that provides applicable testing, counseling, and treatment for Human Immunodeficiency Virus (HIV), tuberculosis (TB) and sexually transmitted infections (STIs).
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and