ENVIRONMENTAL DOCUMENTATION Each environmental service provided by the Engineer shall have a deliverable. Deliverables shall summarize the methods used for the environmental services, and shall summarize the results achieved. The summary of results shall be sufficiently detailed to provide satisfactory basis for thorough review by the State, The Federal Highway Administration (FHWA), and (where applicable) agencies with regulatory oversight. All deliverables shall meet regulatory requirements for legal sufficiency, and shall adhere to the requirements for reports enumerated in the State’s NEPA MOU.
a. Quality Assurance/Quality Control Review For each deliverable, the Engineer shall perform quality assurance quality control (QA/QC) reviews of environmental documents and on other supporting environmental documentation to determine whether documents conform with:
1) Current Environmental Compliance Toolkit guidance published by the State’s Environmental Affairs Division and in effect as of the date of receipt of the documents or documentation to be reviewed;
2) Current state and federal laws, regulations, policies, guidance, agreements, and memoranda of understanding between the State and other state or federal agencies; and
3) FHWA and American Association of State Highway and Transportation Officials (AASHTO) guidelines contained in “Improving the Quality of Environmental Documents, A Report of the Joint AASHTO and American Council of Engineering Companies (ACEC) Committee in Cooperation with the Federal Highway Administration” (May 2006) for: DocuSign Envelope ID: F9E4AA24-4672-4529-8EFA-00D1CA218520
a) Readability, and
b) Use of evidence and data in documents to support conclusions. Upon request by the State, the Engineer shall provide documentation that the QA/QC reviews were performed by qualified staff.
b. Deliverables shall contain all data acquired during the environmental service. All deliverables shall be written to be understood by the public and must be in accordance with the State’s Environmental Toolkit guidance, documentation standards, current guidelines, policies and procedures.
c. Electronic versions of each deliverable must be written in software which is compatible to the State and must be provided in a changeable format for future use by the State. The Engineer shall supplement all hard copy deliverables with electronic copies in searchable Adobe Acrobat™ (.pdf) format, unless another format is specified. Each deliverable shall be a single, searchable .pdf file that mirrors the layout and appearance of the physical deliverable. The Engineer shall deliver the electronic files on CD-R, CD-RW media in Microsoft Windows format, or through the ftp site.
d. When the environmental service is to apply for a permit (e.g., United States Coast Guard (USCG) or United States Army Corps of Engineers (USACE), the permit and all supporting documentation shall be the deliverable.
e. Submission of Deliverables
1) Deliverables shall consist of reports of environmental services performed in addition to a Categorical Exclusion (CE) determination form and supporting documentation including the required form or Environmental Assessment (EA) document, when applicable.
2) All deliverables must comply with all applicable state and federal environmental laws, regulations and procedures and include all items listed in the Environmental Document Review Checklist and the Administrative Completeness Review Checklist.
3) On the cover page of each environmental assessment (EA), finding of no significant impact (XXXXX), environmental impact statement (EIS), and record of decision (ROD) prepared under the authority granted by this MOU, and for any memorandum corresponding to any CE determination it makes, the Engineer shall insert the following language in a way that is conspicuous to the reader or include it in a CE project record: "The environmental review, consultation, and other actions required by applicable DocuSign Envelope ID: F9E4AA24-4672-4529-8EFA-00D1CA218520 Federal environmental laws for this project are being, or have been, carried-out by TxDOT pursuant to 23 U.S.C. 327 and a Memorandum of Understanding dated December 16, 2014, and executed by FHWA and TxDOT."
f. The State shall provide the State’s and other agency comments on draft deliverables to the Engineer. The Engineer shall revise the deliverable:
1) to include any State commitments, findings, agreements, or determinations (e.g., wetlands, endangered species consultation, Section 106, or Section 4(f)), required for the Transportation Activity as specified by the State;
2) to incorporate the results of public involvement and agency coordination;
3) to reflect mitigation measures resulting from comments received or changes in the Transportation Activity; and
4) include with the revised document a comment response form (matrix) in the format provided by the State.
g. All photographs shall be 3.5” x 5” color presentation printed on matte finish photographic paper or 3.5” x 5” color presentation printed on matte white, premium or photo quality laser or inkjet paper. All photographs shall be well focused and clearly depict details relevant to an evaluation of the project area. Provision of photographs shall be one original print of each image or electronic presentations of comparable quality. Comparable quality electronic photograph presentations shall be at least 1200 x 1600 pixel resolution. Photographs shall be attached to separately labeled pages that clearly identify project name, project identification (ID) number, address or Universal Transverse Mercator (UTM) of resource, description of the picture and direction of the photographic view. In addition to the hard-copy prints, an electronic version of each will be submitted with the same identification information as the hard-copy.
Preparation of Environmental Reports At the request of the Administrative Agent from time to time if the Administrative Agent reasonably suspects the presence of any Hazardous Materials on any property of the Borrower or its Subsidiaries, provide to the Administrative Agent within sixty (60) days after such request, at the expense of the Borrower, an environmental site assessment report for any Specified Real Estate described in such request, prepared by a nationally recognized environmental consulting firm (or other environmental consulting firm reasonably acceptable to the Administrative Agent), indicating the presence or absence of Hazardous Materials and the estimated cost of any compliance, removal or remedial action in connection with any Hazardous Materials on such properties; without limiting the generality of the foregoing, if the Administrative Agent determines at any time that a material risk exists that any such report will not be provided within the time referred to above, the Administrative Agent may retain an environmental consulting firm to prepare such report at the expense of the Borrower, and such Loan Party hereby grants and agrees to cause any Subsidiary that owns any property described in such request to grant at the time of such request to the Administrative Agent, such firm and any agents or representatives thereof an irrevocable non-exclusive license, subject to the rights of tenants, to enter onto their respective properties to undertake such an assessment.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Environmental Monitoring (a) Borrower shall give prompt written notice to Lender of (i) any proceeding or inquiry by any party (including any Governmental Authority) with respect to the presence of any Hazardous Substance on, under, from or about the Property, (ii) all claims made or threatened by any third party (including any Governmental Authority) against Borrower or the Property or any party occupying the Property relating to any loss or injury resulting from any Hazardous Substance, and (iii) Borrower’s discovery of any occurrence or condition on any real property adjoining or in the vicinity of the Property that could cause the Property to be subject to any investigation or cleanup pursuant to any Environmental Law. Upon becoming aware of the presence of mold or fungus at the Property, Borrower shall (i) undertake an investigation to identify the source(s) of such mold or fungus and, to the extent required by applicable law, shall develop and implement an appropriate remediation plan to eliminate the presence of any Toxic Mold, (ii) perform or cause to be performed all acts reasonably necessary for the remediation of any Toxic Mold (including taking any action necessary to clean and disinfect any portions of the Property affected by Toxic Mold, including providing any necessary moisture control systems at the Property), and (iii) provide evidence reasonably satisfactory to Lender of the foregoing. Borrower shall permit Lender to join and participate in, as a party if it so elects, any legal or administrative proceedings or other actions initiated with respect to the Property in connection with any Environmental Law or Hazardous Substance, and Borrower shall pay all reasonable attorneys’ fees and disbursements incurred by Lender in connection therewith.
(b) If Lender, on its good faith judgment, determines that reasonable cause exists for the performance of an environmental inspection or audit of the Property, at any time and from time to time upon Lender’s request, Borrower shall provide such inspection or audit of the Property prepared by a licensed hydrogeologist, licensed environmental engineer or qualified environmental consulting firm approved by Lender assessing the presence or absence of Hazardous Substances on, in or near the Property, and if Lender in its good faith judgment determines that reasonable cause exists for the performance of such environmental inspection or audit, then the cost and expense of such audit or inspection shall be paid by Borrower. Such inspections and audit may include soil borings and ground water monitoring. If Borrower fails to provide any such inspection or audit within thirty (30) days after such request, Lender may order same, and Borrower hereby grants to Lender and its employees and agents access to the Property and a license to undertake such inspection or audit.
(c) If any environmental site assessment report prepared in connection with such inspection or audit recommends that an operations and maintenance plan be implemented for any Hazardous Substance, whether such Hazardous Substance existed prior to the ownership of the Property by Borrower, or presently exists or is reasonably suspected of existing, Borrower shall cause such operations and maintenance plan to be prepared and implemented at its expense upon request of Lender, to the extent required by applicable law, and with respect to any Toxic Mold, Borrower shall, to the extent required by applicable law, take all action necessary to clean and disinfect any portions of the Improvements affected by Toxic Mold in or about the Improvements, including providing any necessary moisture control systems at the Property. If any investigation, site monitoring, containment, cleanup, removal, restoration or other work of any kind is reasonably necessary under an applicable Environmental Law (“Remedial Work”), Borrower shall commence all such Remedial Work within thirty (30) days after written demand by Lender and thereafter diligently prosecute to completion all such Remedial Work within such period of time as may be required under applicable law. All Remedial Work shall be performed by licensed contractors approved in advance by Lender and under the supervision of a consulting engineer approved by Lender which approval shall not be unreasonably withheld or delayed. All costs of such Remedial Work shall be paid by Borrower, including Lender’s reasonable attorneys’ fees and disbursements incurred in connection with the monitoring or review of such Remedial Work. If Borrower does not timely commence and diligently prosecute to completion the Remedial Work, Lender may (but shall not be obligated to) cause such Remedial Work to be performed at Borrower’s expense. Notwithstanding the foregoing, Borrower shall not be required to commence such Remedial Work within the above specified time period: (x) if prevented from doing so by any Governmental Authority, (y) if commencing such Remedial Work within such time period would result in Borrower or such Remedial Work violating any Environmental Law, or (z) if Borrower, at its expense and after prior written notice to Lender, is contesting by appropriate legal, administrative or other proceedings, conducted in good faith and with due diligence, the need to perform Remedial Work. Borrower shall have the right to contest the need to perform such Remedial Work, provided that, (1) Borrower is permitted by the applicable Environmental Laws to delay performance of the Remedial Work pending such proceedings, (2) neither the Property nor any part thereof or interest therein will be sold, forfeited or lost if Borrower fails to promptly perform the Remedial Work being contested, and if Borrower fails to prevail in contest, Borrower would thereafter have the opportunity to perform such Remedial Work, (3) Lender would not, by virtue of such permitted contest, be exposed to any risk of any civil liability for which Borrower has not furnished additional security as provided in clause (4) below, or to any risk of criminal liability, and neither the Property nor any interest therein would be subject to the imposition of any Lien for which Borrower has not furnished additional security as provided in clause (4) below, as a result of the failure to perform such Remedial Work and (4) Borrower shall have furnished to Lender additional security in respect of the Remedial Work being contested and the loss or damage that may result from Borrower’s failure to prevail in such contest in such amount as may be reasonably requested by Lender but in no event less than the cost of such Remedial Work as estimated by Lender and Borrower or Lender’s Consultant and any loss or damage that may result from Borrower’s failure to prevail in such contest.
(d) Borrower shall not install or permit to be installed on the Property any underground storage tank.
Project Documentation All documentation provided to the City other than Project drawings shall be furnished on a Microsoft compatible compact disc.
Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Environmental Report Lender shall have received an Environmental Report (not more than six months old) with respect to the Property that discloses no material environmental contingencies with respect to the Property.
Environmental Site Assessment Perform in accordance with the City Design Manual and other City requirements as designated in writing by the Director.
Environmental Reports Lender shall have received an environmental report in respect of the Property, in each case reasonably satisfactory to Lender.
Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.
