TASK ORDER SCOPE OF SERVICES Sample Clauses

TASK ORDER SCOPE OF SERVICES. 4.1 Consultant agrees that the entire Scope of Services for this Task Order includes SECTION 5. SCOPE OF SERVICES of the Master Agreement, and the Scope of Services as set out in Exhibit “Scope of Service”, attached and incorporated herein by this reference. This Task Order Scope of Services will govern over any contrary language in the Scope of Services of the Master Agreement. 4.2 Upon receiving a written notice to proceed from State, Consultant shall complete the Services required under this Task Order and in accordance with the terms of the Master Agreement.
Sample 1
AutoNDA by SimpleDocs
TASK ORDER SCOPE OF SERVICES. The Consultant shall meet with Northern Water at the outset of work to review the planning-level design previously completed by Consultant, receive Northern Water comments on the design, discuss design and construction alternatives, and review other miscellaneous design requirements.
Sample 1
TASK ORDER SCOPE OF SERVICES. 4.1 LPA and Consultant understand that the Services provided by Consultant must be completed in accordance with all federal-aid reimbursement requirements and conditions. Consultant shall provide Environmental Services for project LCLC-3265(11), 68th, Firth Rd to Stagecoach, in Lancaster County, Nebraska. The Scope of Services (“Services”) is outlined in Exhibit “A”, attached and incorporated herein by this reference. The Fee Proposal is outlined in Exhibit “B”, attached and incorporated herein by this reference. 4.2 Exhibits “A” and “B” are the result of the following process: 4.2.1 Consultant was provided with a document describing the detailed proposed Scope of Services for this project 4.2.2 Consultant made necessary and appropriate proposed additions, deletions, and revisions to the detailed Scope of Services document 4.2.3 Consultant participated in a review of the proposed Scope of Services, and the proposed revisions, and negotiated the final detailed Scope of Services and Fee Proposal document, as shown in Exhibit “A” and Exhibit “B”, attached and incorporated herein by this reference. 4.3 LPA, or State on LPA’s behalf, reserves the unconditional right to add to, subtract from, or alter the Scope of Services at any time and such action on its part will in no event be deemed a breach of this Agreement. The addition, subtraction, or alteration will become effective seven (7) days after mailing written notice of such addition, subtraction, or alteration. 4.4 Any change in the Services will follow the process specified in the Out-of-Scope Services section in Exhibit “C”, attached and incorporated herein by this reference. 4.5 Upon receiving a written notice to proceed from LPA, or State on LPA’s behalf, Consultant shall complete the Services required under this Task Order and in accordance with the terms of the Master Agreement.
Sample 1
TASK ORDER SCOPE OF SERVICES. 4.1 LPA and Consultant understand that the Services provided by Consultant must be completed in accordance with all federal-aid reimbursement requirements and conditions. Consultant shall provide Environmental Services for project LCLC-3340(8), Xxxxxxxx Ave, 84th St to 000xx Xx, xx Xxxxxxxxx Xxxxxx, Xxxxxxxx. The Scope of Services ("Services") is outlined in Exhibit "A", attached and incorporated herein by this reference. 4.2 Exhibits "A" and "B" are the result of the following process: 4.2.1 Consultant was provided with a document describing the detailed proposed Scope of Services for this project
Sample 1
TASK ORDER SCOPE OF SERVICES. See EXHIBIT A for Scope of Services.
Sample 1
TASK ORDER SCOPE OF SERVICES. 4.1 Consultant agrees that the entire Scope of Services for this Task Order includes SECTION 5. SCOPE OF SERVICES of the Master Agreement, and the Scope of Services as set out in Exhibit “Scope of Service”, attached and incorporated herein by this reference. This Task Order Scope of Services will govern over any contrary language in the Scope of Services of the Master Agreement. 4.2 Upon receiving a written notice to proceed from State, Consultant shall complete the Services required under this Task Order and in accordance with the terms of the Master Agreement. State reserves the unconditional right to add to, subtract from, or alter the Services at any time, and such action by State will in no event be deemed a breach of this Task Order. The addition, subtraction, or alteration will become effective seven (7) days after mailing written notice of such addition, subtraction, or alteration. 4.3 Any change in the Services will follow the process specified in the Out-of-Scope Services section in Exhibit “<fees & payments>”, attached and incorporated herein by this reference.
Sample 1

Related to TASK ORDER SCOPE OF SERVICES

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • Scope of Services The specific scope of work for each job shall be determined in advance and in writing between TIPS Member, Member’s design professionals and Vendor. It is permitted for the TIPS Member to provide a general scope description, but the awarded vendor should provide a written scope of work, and if applicable, according to the TIPS Member’s design Professional as part of the proposal. Once the scope of the job is agreed to, the TIPS Member will issue a PO and/or an Agreement or Contract with the Job Order Contract Proposal referenced or as an attachment along with bond and any other special provisions agreed by the TIPS Member. If special terms and conditions other than those covered within this solicitation and awarded Agreements are required, they will be attached to the PO and/or an Agreement or Contract and shall take precedence over those in this base TIPS Vendor Agreement.

  • SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.

  • 000 SCOPE OF WORK 5. 100 The scope of this Agreement covers all work of a maintenance, repair and renovation nature, assigned by the Owner to the Company and performed by the employees of the Company covered by this Agreement, within the limits of the Owner's plant site.

  • General Scope of Services Contractor promises and agrees to furnish all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply professional services, as more particularly described in Exhibit B (Statement of Work and Misc. Documents) attached hereto and incorporated herein by reference (collectively “Services”). All Services shall be subject to, and performed in accordance with, this Contract, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.

  • Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.

  • Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.

  • General Scope of Work The Scope of Work and projected level of effort required for these SERVICES is described in Exhibit “A” attached hereto and by this reference made a part of this AGREEMENT. The General Scope of Work was developed utilizing performance based contracting methodologies.

  • Scope of Work For the 2022/2023 Grant Period, the Provider will maintain a victim services program that will be available to provide direct services to victims of crime who are identified by the Provider or are presented to the Provider, as specified in the Provider’s 2022/2023 Grant Application as approved by the OAG and incorporated herein by reference.

  • Supply of Services 7.1 Supplier shall provide the Services to Purchaser in accordance with the Order in all material respects using reasonable care and skill. 7.2 Supplier shall use reasonable endeavours to meet any performance dates for the Services specified in the Order but any dates shall be estimates only and time shall not be of the essence for the performance of the Services. 7.3 Supplier shall have the right to make any changes to the Services which are necessary to comply with any applicable law or safety requirements or which do not materially affect the nature or quality of the Services. 7.4 Purchaser shall: (a) ensure that the terms of Order are complete and (if submitted by Purchaser) the service specification are complete and accurate; (b) co-operate with Supplier in all matters relating to the Services; (c) provide Supplier, its employees, agents, consultants and subcontractors with access to Purchaser’s premises, machinery and other facilities as reasonably required by Supplier to provide the Services; and (d) provide Supplier with such information and materials as Supplier may reasonably require to supply the Services, and ensure that such information is accurate in all material respects. 7.5 If Supplier’s performance of any of its obligations in respect of the Services is prevented or delayed by an any act or omission by Purchaser or failure by Purchaser to performs its obligations (“Purchaser Default”) Supplier shall without limiting its other rights or remedies have the right to suspend performance of the Services until Purchaser remedied Purchaser Default and relieves Supplier from its obligations to the extent the Customer Default prevents or delays Supplier’s performance. Purchaser shall indemnify Supplier against all liabilities costs, losses and expenses which Supplier may incur by reason of Purchaser Default. 7.6 Where the Services consist of any experimental or developmental work, the results supplied or recommendations made under the Services are given in good faith within the limitations of the data available, but no warranty, expressed or implied, is given as to the ability of Supplier to achieve a specific outcome, nor the accuracy of results obtained. 7.7 Any claims by Purchaser which is based on defect in the Services shall be notified to Supplier within twenty-one (21) days of the services being performed and promptly after discovery of defect or failure. The sole and exclusive remedy of Purchaser for such defect hereunder shall be the re-performance or re- fund, at Supplier’s option, of any defective or non-conforming Services.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!