THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT Sample Clauses

THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. The Construction Manager accepts the relationship of trust and confidence established between itself and the Owner by this Agreement. The Construction Manager covenants with the Owner to demonstrate high performance in the industry to its best skill and judgment and to cooperate with the Architect/Engineer in furthering the interests of the Owner. The Construction Manager agrees to exceptional business administration and superintendence and use of the best efforts industry wide to complete the project in the best and soundest way and in the most expeditious and economical manner consistent with the interest of the Owner.
Sample 1Sample 2Sample 3See All (24)
AutoNDA by SimpleDocs
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. 2.1 Construction Manager agrees to furnish its best skill and judgment and to cooperate with the applicable architect/engineer(s) (the “Architect/Engineer(s)”) in furthering the interests of Owner. Construction Manager agrees to furnish efficient business administration for the Project and to manage, supervise, and complete the Project in an expeditious and economical manner consistent with the interests of Owner.
Sample 1Sample 2Sample 3See All (17)
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. The Construction Manager accepts the relationship of trust and confidence established between him and the Owner by this Agreement. He covenants with the Owner to furnish his best skill and judgment and to cooperate with the Architect-Engineer in furthering the interests of the Owner. He agrees to furnish efficient business administration and superintendence and use his best efforts to complete the project in the best and soundest way and in the most expeditious and economical manner consistent with the interest of the Owner and the Construction Manager warrants that he has read those sections of the current Florida Building Code pertaining to Construction Management and agrees to perform to its standards and rules.
Sample 1Sample 2Sample 3See All (10)
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. The Construction Manager accepts the relationship of trust and confidence established between the Construction Manager and the Owner by this Agreement. The Construction Manager covenants with the Owner to furnish the Construction Manager’s best skill and judgment and to cooperate with the Architect-Engineer in furthering the interests of the Owner. The Construction Manager shall perform the Project in a good and workmanlike manner with sufficient manpower to meet the time and quality requirements set forth in this Agreement and the Contract Documents. The Construction Manager agrees to furnish efficient business administration and superintendence and use the Construction Manager’s best efforts to complete the project in the best and soundest way and in the most expeditious and economical manner consistent with the interest of the Owner. The Owner’s engagement of the Construction Manager is based upon the Construction Manager’s representations to the Owner that it (i) is financially solvent and has sufficient working capital to perform its obligations under this Agreement; (ii) is experienced in providing construction management services for projects of similar size and complexity to the Project; (iii) is authorized and licensed to perform the type of labor and services for which it is being engaged in the State and locality in which the Project is located; (iv) is qualified, willing and able to perform construction management services for the Project; and (v) has the expertise and ability to provide construction management services which will meet the Owner’s objectives and requirements and which will comply with the requirements of all governmental, public and quasi-public authorities and agencies having or asserting jurisdiction over the Project.
Sample 1Sample 2Sample 3See All (6)
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. The CM/GC accepts the relationship of trust and confidence established with the Owner by this Agreement. The CM/GC covenants with the Owner to furnish its best skill and judgment and to cooperate with the Landscape Architect in furthering the interests of the Owner. The CM/GC agrees to furnish efficient business administration and superintendence and to use its best efforts to perform the Work in the best and soundest way and in the most expeditious and economical manner consistent with the interests of the Owner.
Sample 1Sample 2See All (4)
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. 1.1 The Construction Manager accepts the relationship of trust and confidence established by this Agreement and covenants with the Owner to cooperate with the professionals providing architectural and/or engineering services on the projects (“Architect” or “Architect/Engineer”) and exercise the Construction Manager’s skill and judgement in furthering the interests of the Owner to furnish efficient construction administration, management services, and supervision; to furnish at all times an adequate supply of workers and materials; and to perform the Work in an expeditious and economical manner consistent with the Owner’s interests. The Owner agrees to furnish or approve, in a timely manner, information required by the Construction Manager and to make payments to the Construction Manager in accordance with the requirements of the Contract Documents. The term “
Sample 1Sample 2
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT. 1.1 The Provider agrees to provide building inspection and/or quality control services for each specific designated project as set forth when activated in writing by the Owner's Contracts Administrator.
Sample 1
AutoNDA by SimpleDocs

Related to THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT

  • EXTENT OF AGREEMENT 17.1 This Agreement represents the entire and integrated Agreement between the OWNER and the CONSULTANT and supersedes all prior negotiations, representations, or agreements, either written or oral. This Agreement shall not be superseded by provisions of contracts for design or construction and may be amended only by a written instrument signed by both the OWNER and the CONSULTANT.

  • Legal Construction If one or more of the provisions contained in this Agreement shall for any reason be held invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability shall not affect any other provisions and this Agreement shall be construed as if it did not contain the invalid, illegal, or unenforceable provision.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • Advice on Construction Progress To each Application for Payment forwarded to the Owner, the Design Professional shall attach its Advice on Construction Progress, in the format provided in the CM/GC Forms Packet, and provide a copy to the CM/GC.

  • Construction and Scope of Agreement The language of all parts of this Agreement shall in all cases be construed as a whole, according to its fair meaning, and not strictly for or against any party. This Agreement is the only, sole, entire, and complete agreement of the parties relating in any way to the subject matter hereof. No statements, promises, or representations have been made by any party to any other, or relied upon, and no consideration has been offered or promised, other than as may be expressly provided herein. This Assumption of Risk, Release of Claims, Indemnification, and Hold Harmless and Agreement supersedes any earlier written or oral understandings or agreements between the parties. Participant acknowledges that he/she has read this Assumption of Risk, Release of Claims, Indemnification and Hold Harmless Agreement, understands its meaning and effect, and agrees to be bound by it. Date:

  • Commencement and Completion of Construction The Company shall begin Construction Activities no later than January 1, 2014 (“Commencement Date”) and secure a final Certificate of Compliance by June 30, 2015 (hereinafter, “Completion Date”).

  • Interpretation and Construction 2.1 This Agreement includes this Agreement and all Exhibits appended hereto, each of which is hereby incorporated by reference in this Agreement and made a part hereof. All references to Sections and Exhibits shall be deemed to be references to Sections of, and Exhibits to, this Agreement unless the context shall otherwise require. The headings and numbering of Sections and Exhibits used in this Agreement are for convenience only and will not be construed to define or limit any of the terms in this Agreement or affect the meaning and interpretation of this Agreement. Unless the context shall otherwise require, any reference to any statute, regulation, rule, Tariff, technical reference, technical publication, or any publication of Telecommunications industry administrative or technical standards, shall be deemed to be a reference to the most recent version or edition (including any amendments, supplements, addenda, or successor) of that statute, regulation, rule, Tariff, technical reference, technical publication, or any publication of Telecommunications industry administrative or technical standards that is in effect. Provided however, that nothing in this Section 2.1 shall be deemed or considered to limit or amend the provisions of Section 2.2. In the event a change in a law, rule, regulation or interpretation thereof would materially change this Agreement, the terms of Section 2.2 shall prevail over the terms of this Section 2.1. In the case of any material change, any reference in this Agreement to such law, rule, regulation or interpretation thereof will be to such law, rule, regulation or interpretation thereof in effect immediately prior to such change until the processes set forth in Section 2.2 are implemented. The existing configuration of either Party's network may not be in compliance with the latest release of technical references, technical publications, or publications of Telecommunications industry administrative or technical standards.

  • Quality and Extent of Services The Board considered the terms of the Agreements, including the scope of advisory services provided under the Agreements. The Board noted that, under the Agreements, DIMA and RREEF provide portfolio management services to the Fund and that, pursuant to a separate administrative services agreement, DIMA provides administrative services to the Fund. The Board considered the experience and skills of senior management and investment personnel and the resources made available to such personnel. The Board also considered the risks to XXXX in sponsoring or managing the Fund, including financial, operational and reputational risks, the potential economic impact to XXXX from such risks and XXXX’s approach to addressing such risks. Throughout the course of the year, the Board also received information regarding XXXX’s oversight of fund sub-advisors, including RREEF. The Board reviewed the Fund’s performance over short-term and long-term periods and compared those returns to various agreed-upon performance measures, including market index(es) and a peer universe compiled using information supplied by Morningstar Direct (“Morningstar”), an independent fund data service. The Board also noted that it has put into place a process of identifying “Funds in Review” (e.g., funds performing poorly relative to a peer universe), and receives additional reporting from XXXX regarding such funds and, where appropriate, XXXX’s plans to address underperformance. The Board believes this process is an effective manner of identifying and addressing underperforming funds. Based on the information provided, the Board noted that, for the one-, three- and five-year periods ended December 31, 2020, the Fund’s performance (Class A shares) was in the 3rd quartile, 2nd quartile and 2nd quartile, respectively, of the applicable Morningstar universe (the 1st quartile being the best performers and the 4th quartile being the worst performers). The Board also observed that the Fund has outperformed its benchmark in the one-, three- and five-year periods ended December 31, 2020.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!