Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.
Time for Commencement and Completion The term (Initial Term) of this Agreement will begin on the Effective Date and expire on ______________________, 20___. University will have the option to renew this Agreement for _______ (___) additional ______ (____) year terms (each a Renewal Term). The Initial Term and each Renewal Term are collectively referred to as the Term.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Date for Completion 4.1 Completion must take place in Canberra on the Date for Completion or as otherwise determined by the Contract and if not specified or determined, within a reasonable time.
Term Extension It is understood and agreed that the State may extend the Term an additional period of time, not to exceed one hundred-eighty (180) days beyond the expiration date of this Grant Contract, under the same terms and conditions. In no event, however, shall the maximum Term, including all extensions or renewals, exceed a total of sixty (60) months.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
Time for Compliance Consultant shall not commence work under this Agreement until it has provided evidence satisfactory to the City that it has secured all insurance required under this section. In addition, Consultant shall not allow any subconsultant to commence work on any subcontract until it has provided evidence satisfactory to the City that the subconsultant has secured all insurance required under this section. Failure to provide and maintain all required insurance shall be grounds for the City to terminate this Agreement for cause.
Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension. When such extension is made, Forest Service shall make an appraisal using standard Forest Service methods and appraisal data in effect 45 days prior to the original Termination Date. Bid Premium Rates shall be added to such appraised rates to establish Flat Rates or Tentative Rates for the extension period. In event rates so established would develop Current Contract Value immediately prior to such an extension that is less than Current Contract Value at that time, Flat Rates and Tentative Rates in effect immediately prior to extension shall be retained for the extension period. In consideration for granting an extension, Purchaser shall pay the Government for Purchaser’s failure to cut and remove timber meeting Utilization Standards prior to Contract Term Extension, an amount that shall be the total of the costs to the Government resulting from the delay in harvest of Included Timber. Such costs will be determined by Forest Service and shall include, but not be limited to, the following:
Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.
