Use by Others Forest Service shall have the right to use any road constructed by Purchaser under this contract for any and all purposes in connection with the protection and administration of the National Forest. Other parties, in connection with the logging of tributary National Forest timber, may use roads constructed by Purchaser hereunder when Contracting Officer determines that such use will not materially interfere with Purchaser’s Operations. Third party use shall be contin- gent upon Contracting Officer determining, and third party agreeing to pay, a fair share of maintenance cost com- mensurate with such commercial use.
(a) Contracting Officer makes appropriate arrange- ments to relieve Purchaser of related maintenance costs commensurate with such other uses and
(b) Such other uses will not materially interfere with Purchaser’s Operations. Where Purchaser reconstructs a road having estab- lished use, Purchaser’s use during reconstruction and thereafter shall be such as to reasonably accommodate such established use. Contracting Officer shall ensure that other users do not materially interfere with Purchaser’s right to use such reconstructed road.
NON-USE OF NAMES Neither Party shall use the name of the other Party, nor any adaptation thereof, in any advertising, promotional or sales literature without prior written consent obtained from such other Party in each case (which consent shall not be unreasonably withheld or delayed).
TERMINATION BY MPS - BREACH BY CONTRACTOR If Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or violates any of its provisions, MPS shall thereupon have the right to terminate it by giving five (5) days written notice before the effective date of termination of the Contract, specifying the alleged violations, and effective date of termination. The Contract shall not be terminated if, upon receipt of the notice, Contractor promptly cures the alleged violation with five (5) days. In the event of termination, MPS will only be liable for services rendered through the date of termination and not for the uncompleted portion, or for any materials or services purchased or paid for by Contractor for use in completing the Contract.
Where by reason of the provisions of paragraph 1 an individual is a resident of both Contracting States, then his status shall be determined as follows:
a) he shall be deemed to be a resident only of the State in which he has a permanent home available to him; if he has a permanent home available to him in both States, he shall be deemed to be a resident only of the State with which his personal and economic relations are closer (centre of vital interests);
b) if the State in which he has his centre of vital interests cannot be determined, or if he has not a permanent home available to him in either State, he shall be deemed to be a resident only of the State in which he has an habitual abode;
c) if he has an habitual abode in both States or in neither of them, he shall be deemed to be a resident only of the State of which he is a national;
d) if he is a national of both States or of neither of them, the competent authorities of the Contracting States shall settle the question by mutual agreement.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Limitation of Use The parties agree that this Agreement shall not be proffered by either party in another jurisdiction as evidence of any concession or as a waiver of any position taken by the other party in that jurisdiction or for any other purpose.
Formation and Purpose Promptly following the Effective Date, the Parties shall confer and then create the JSC and the IPC, and, optionally, create one or more of the other Committees listed in the chart below. Each Committee shall have the purpose indicated in the chart. To the extent that after conferring both Parties agree to not create a Committee (other than the JSC and the IPC), the creation of such Committee shall be deferred until one Party informs the other Party of its then desire to create the so-deferred Committee, at which point the Parties will thereafter promptly create the so-deferred Committee. Joint Steering Committee (“JSC”) Establish projects for the Bacteriophage Program and establish the priorities, as well as approve budgets for such projects. Approve all subcommittee projects and plans (except for decisions of the IPC). The JSC shall establish budgets not less than on a quarterly basis. Chemistry, Manufacturing and Controls Committee (“CMCC”) Establish project plans and review and approve activities and budgets for chemistry, manufacturing, and controls under the Bacteriophage Program. Regulatory Committee (“RC”) Review and approve all research and development plans and projects, including clinical projects, associated with any necessary regulatory approvals, all associated publications, and all regulatory filings and correspondence relating to gaining regulatory approval for new Ampliphi Products under the Bacteriophage Program; and review and approve itemized budgets with respect to the foregoing. Commercialization Committee (“CC”) Establish project plans and review and approve activities and budgets for Commercialization activities under the Bacteriophage Program. Portions herein identified by [*****] have been omitted pursuant to a request for confidential treatment under Rule 24b-2 of the Securities Exchange Act of 1934, as amended. A complete copy of this document has been filed separately with the Securities and Exchange Commission. Intellectual Property Committee (“IPC”) Evaluate all intellectual property issues in connection with the Bacteriophage Program; review and approve itemized budgets with respect to the foregoing.
Limitations on Use No part of the moneys delivered to the Recipient pursuant to Section II hereof is being or will be used to refinance, retire, redeem, or otherwise pay debt service on all or any part of any part of any governmental obligations regardless of whether the interest on such obligations is or was excluded from gross income for federal income tax purposes unless prior approval by the Director is given.
Limitations on Use of Information The Fund agrees not to use the information received for marketing or any other similar purpose without the prior written consent of the Intermediary.
Acceptance by Recipient This Agreement must be signed by the Chief Executive Officer of the Recipient and returned to, and received by, the OPWC within forty-five (45) days of the date written on the first page of this Agreement. Failure of the Recipient to return a fully executed copy of this Agreement to the OPWC within the forty-five (45) day limit will result in this Agreement being declared null and void. However, upon the Recipient presenting the Director with a written explanation of the need to extend this forty-five (45) day limit, the Director, in his sole discretion, may extend the forty-five (45) day limit.
