Variations to the Work Sample Clauses

Variations to the Work. (a) Xxxxx may issue to Owner at any time a Variation to the Work. (b) Owner must not vary the Work except as directed by Xxxxx in writing under a Variation (c) Owner is bound only to execute a Variation which is within the capabilities and expertise of Owner and is within the general scope of the Work under the Order. (d) Owner is entitled to request a Variation where an occurrence has taken place, or an instruction has been received from Hirer which impacts upon the Price or the Schedule for the Work. The Variation request shall include the information prescribed under Clause 6.2(a) below. Within twenty-four (24) hours of Owner request hereunder, Xxxxx shall issue a notice to Owner whether the request is accepted or rejected with full particulars and substantiation of its decision. If no such notice is received within the time stipulated the variation request shall be deemed accepted. If accepted, Xxxxx shall issue to Owner a Variation in accordance with the relevant Variation request. If the Hirer rejects the Variation request, the Variation shall be treated as disputed and the Parties shall resolve such disputed variation under Clause 21.2
Sample 1See All (8)
AutoNDA by SimpleDocs
Variations to the Work. 17.1 The Company has the right to issue instructions to the Contractor at any time to make Variations to the Purchase Order. 17.2 The Contractor must comply with the Company’s instruction without delay. 17.3 Where the Variation requires an adjustment to the total Fee, the Variation will be valued at the appropriate rates and prices included in the Purchase Order or, in the absence of any appropriate rates or prices, at a fair valuation agreed between the parties.
Sample 1Sample 2Sample 3See All (6)
Variations to the Work. 28. NPD has the right to order variations to the Work within the frame of what the parties could reasonably have expected at the time the Contract was signed. 29. When NPD issues a Variation Order, Contractor shall, without undue delay, submit an estimate to NPD. The estimate shall contain a description of the variation to the Work in question, together with any effects on the compensation and the agreed time of delivery and time-limits / milestones or other effects on any conditions agreed in the Contract. NPD may require the submission of such estimate prior to issuing a Variation Order. 30. If Contractor finds that variations to the Work is required, NPD shall be notified in writing, without delay. Variations to the Work shall be approved by NPD by means of a Variation Order before Contractor initiates the variation to the Work. 31. All of Contractor obligations under the Contract shall also apply to variations to the Work, unless otherwise agreed. 32. Unless otherwise agreed between the Parties, the price for variations to the Work shall be determined according to the following provisions: (a) Variations, whether resulting in an increase or decrease of the compensation, shall be charged and compensated for in accordance with Appendix 2. (b) If specific rates are not included in Appendix 2, any appropriate or comparable rates included in the Contract shall be used. (c) In the absence of specific, appropriate or comparable rates a fair valuation shall be made. 33. If a variation to the Work effects the agreed time of delivery or time-limits / milestones, the effects shall be agreed upon between the parties. Variations to the Work caused by circumstances for which Contractor is responsible shall not lead to any adjustments in the compensation or the agreed time of delivery or time-limits / milestones in favour of Contractor. 34. All variations to the Work shall be made by means of a Variation Order issued by NPD. A Variation Order shall be expressly identified as such and be submitted on a prescribed and numbered form. The Variation Order shall at least contain a description of what the variation Work consists of. On receipt of a Variation Order Contractor shall implement it without undue delay, even if the effect of the Variation Order on the compensation, the time of delivery and time-limits / milestones and other provisions of the Contract/Purchase Order have not been agreed. 35. If NPD requires work to be performed, which in the opinion of Contractor ...
Sample 1
Variations to the Work. The Superintendent may direct the Contractor to— (a) increase, decrease or omit any part of the work under the Contract; Lihir Gold Limited Contract No LGL-MO-0107 Provision of Geothermal Coring Services Part III: General Conditions of Contract (b) change the character or quality of any material or work; (c) change the levels, lines, positions or dimensions of any part of the work under the Contract; (d) execute additional work; and/or (e) demolish or remove material or work no longer required by the Principal. The Contractor shall not vary the work under the Contract except as directed by the Superintendent or approved in writing by the Superintendent under Clause 40. The Contractor is bound only to execute a variation that is within the general scope of the Contract. The Contractor shall not be bound to execute a variation directed after Practical Completion unless the variation is in respect of rectification work referred to in Clause 37.
Sample 1

Related to Variations to the Work

  • Modifications to the General Conditions The modifications to the General Conditions are as follows: 1. Paragraph (a) of Section 2.07 is modified to read as follows:

  • Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.

  • Alternate Work Schedules Workweeks and work shifts of different numbers of hours may be established for overtime-eligible employees by the Employer in order to meet business and customer service needs, as long as the alternate work schedules meet federal and state law. When there is a holiday, employees may be required to switch from their alternate work schedules to regular work schedules.

  • MINOR CHANGES IN THE WORK If permitted in the agreement between Owner and Architect, the Architect has authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents.

  • Additional Work If changes in the work seem merited by Consultant or the City, and informal consultations with the other party indicate that a change is warranted, it shall be processed in the following manner: a letter outlining the changes shall be forwarded to the City by Consultant with a statement of estimated changes in fee or time schedule. An amendment to this Agreement shall be prepared by the City and executed by both Parties before performance of such services, or the City will not be required to pay for the changes in the scope of work. Such amendment shall not render ineffective or invalidate unaffected portions of this Agreement.

  • Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time: (a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways; (b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available; (c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas; (d) To add additional buildings and improvements to the Common Areas; (e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and (f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.

  • Alternative Work Schedule An alternate forty (40) hour work schedule (other than five (5) uniform and consecutive eight (8) hour days in a seven (7) day period), or for hospital personnel an eighty (80) hour workweek in a fourteen (14) day period and other mutually agreed upon schedules that comply with applicable federal and state law. Employee work schedules normally include two (2) consecutive days off.

  • Alternative Work Schedules Employees may request alternative work schedules such as a nine (9) day - 80 hour two week schedule or a four (4) day - 40 hour week schedule. Management will respond to an employee's request within 15 calendar days. Any changes from existing work schedules will be based on the needs of the service as determined by Management. Employees covered by the Fair Labor Standards Act will not be placed on alternate work schedules that mandate the payment of overtime under the Act.

  • Alternate Work Schedule An alternate work schedule is any work schedule where an employee is regularly scheduled to work five (5) days per week, but the employee’s regularly scheduled two (2) days off are NOT Saturday and Sunday.

  • ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!