Due Completion Date definition

Due Completion Date means the date of expiry of the time stated in the Scope of Works in Annexure “B” for achieving Practical Completion of the Works, calculated from the Commencement Date and as adjusted by such extensions of time or acceleration as may be allowed in terms of the Contract;
Sample 1Sample 2Sample 3
Due Completion Date means the date of expiry of the Time for Completion stated in the Contract Data or as tendered in the Form of Offer for achieving Practical Completion of the Works (whichever is the lessor), calculated from the date of Site Handover and Instruction to Commence with the Works and as adjusted by such extensions of time or acceleration as may be allowed in terms of the Contract”
Sample 1Sample 2Sample 3
Due Completion Date means the date or dates of the expiry of the time stated in the Contract Data for achieving Practical Completion for the whole or portions of the Works, calculated from the Commencement Date and as adjusted by such extensions of time or acceleration as may be allowed or agreed in terms of Contract.
Sample 1Sample 2Sample 3

Examples of Due Completion Date in a sentence

  • The programme shall be in bar-chart format showing in detail how the Contractor proposes to complete the work covered by this contract by the Due Completion Date.

  • Labour Intensive Construction shall mean the economically efficient employment of as great a portion of labour as is technically feasible to produce a standard of construction as demanded by the Specifications with completion by the Due Completion Date, thus the effective substitution of labour for equipment.

  • The original Due Completion Date is 13 January 2014 + 365 days + (14 public holidays – 1 Sunday which is a non-working day – 4 special non-working days during the year-end break) + 21 days for the year-end break = 12 February 2015.The Due Completion Date after the agreed acceleration is 13 January 2014 + 334 days + 9 public holidays = 22 December 2014 which falls within the year-end break.

  • Due Completion Date The time for achieving Practical Completion is 18 months after the Commencement Date.

  • Clause 1.1.1.14: Due Completion Date The date for achieving Practical Completion is a date four (4) months after the Commencement Date.

  • Thus, provided that where such period is negative, the Due Completion Date shall not be revised.

  • The Due Completion Date for each respective Works Segment shall be calculated from the Starting Date of the respective Works Segment and shall be adjusted by such extensions of time (if any) as may be allowed in terms of Clause 45.

  • Clause 1.1.1.14: Due Completion Date The date for achieving Practical Completion is 02 Months.

  • Clause 1.1.1.14: Due Completion Date The date for achieving Practical Completion is 8 Months.

  • Clause 1.1.1.14: Due Completion Date The date for achieving Practical Completion is04 Months.


More Definitions of Due Completion Date

Due Completion Date means the date specified as such in the relevant Schedule A or proposal.
Sample 1Sample 2Sample 3
Due Completion Date means the date of expiry of the time stated in the Appendix for completing the execution of the Works, calculated from the Commencement Date and as adjusted by such extensions of time as may be allowed in terms of Clause 45.'
Sample 1
Due Completion Date means the date specified as such in clause 2.2 of the Agreement. «Установленная дата завершения услуг» – означает дату, указанную в качестве таковой в ст.
Sample 1

Related to Due Completion Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Practical Completion means the completion of the Project where the building is fit for occupancy and/or purpose.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.