Final Project Schedule definition

Final Project Schedule has the meaning set forth in Exhibit G.
Sample 1Sample 2Sample 3
Final Project Schedule means the final schedule for completion of the Utility Relocation Project that incorporates and integrates final schedules for all Work required to complete the Final Scope, as further set forth in § 5.3.
Sample 1
Final Project Schedule means the high level project schedule provided as part of Project Blueprint in accordance with section 4.1(b), provided that same may be revised, as mutually agreed by the Parties, from time to time as the Presto Systems Project proceeds;
Sample 1

Examples of Final Project Schedule in a sentence

  • Before PWRF gives its construction contractor its Notice to Proceed with construction, the Parties shall develop a process under which any proposed material changes shall be reviewed by the City Design Review Board, including a timeline for such review designed to minimize potential delays in completing the Project consistent with the Final Project Schedule.

  • Developer shall use commercially reasonable efforts to cause the General Contractor to comply with the Final Development Plan, Final Development Budget and Final Project Schedule.

  • The Final Project Schedule shall only be modified upon the written approval of District.

  • The Final Project Schedule shall incorporate float for inclement weather and resulting muddy site conditions due to rain (separate from any event of Force Majeure) and shall also include any potential acceleration paths.

  • The work on the Project shall be completed on or before the Commercial Operation Date in accordance with the Final Project Schedule set forth below and as may be amended from time to time during the Term.

  • The Final Project Schedule shall indicate the beginning and completion dates of all phases of construction and shall use the “critical path method” for the planning and scheduling of all work required.

  • Any modified schedule approved by District shall replace the existing Final Project Schedule set forth below.

  • Exhibit G – Attachment C – 37 A monthly Project schedule update shall be provided to accurately indicate the actual progress of the work against the baseline Final Project Schedule for the prior month, and the remaining planned completion of the work.

  • Owner hereby appoints Developer as its independent contractor to perform the Project, and delegates to Developer the right and obligation to supervise, manage and carry out the Project, on behalf and for the account of Owner, upon the terms and conditions set forth in this Agreement and in accordance with the Final Development Plan, Final Development Budget and Final Project Schedule (as each such term is defined below) and all items related thereto.

  • Subject to the other provisions of this Agreement, Developer, on behalf of Owner, shall manage and coordinate the development of the Project in accordance with the Final Development Plan, Final Development Budget and Final Project Schedule (as each such term is defined below) in a good and workmanlike manner and in accordance with the standards of professional care applicable to such services.

Related to Final Project Schedule

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Contract Schedule means a schedule to this Contract;

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Approved Project Budget means the most recent statement, approved by the FTA, of the costs of the Project, the maximum amount of Federal assistance for which the TJPA is currently eligible, the specific tasks (including specified contingencies) covered, and the estimated cost of each task.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.

  • Project Budget means the budget and project description included in the grant application. The Project Budget must succinctly describe all major elements of project work, the estimated cost of each and clearly allocate requested grant funding and match contributions to each.

  • Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • BASE budget means the minimum general fund budget of a district, which includes 80% of the basic

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Original Project Cost means the capital expenditure incurred by the Generating Company or the Transmission Licensee, as the case may be, within the original scope of the project up to the cut-off date as admitted by the Commission;

  • Project Scope means the description or activity of work to be accomplished on the Project.

  • Project area budget means a multiyear projection of annual or cumulative

  • Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalized Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Specification Schedule means the Schedule containing details of the Specification.

  • Product Schedule means a product schedule documenting the specific terms and conditions applying to a Product as may be amended, updated or replaced from time to time (and includes any Electronic Platform Schedules);

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Expansion Project has the meaning set forth in Section IV.3.a of this Agreement.

  • Project Work means the work required to complete the Project.

  • The Contract Price/Project Cost means the price payable to the Vendor under the Contract for the full and proper performance of its contractual obligations.

  • Punchlist means a list of items of Work to be completed or corrected by Contractor after Substantial Completion. Punchlists indicate items to be finished, remaining Work to be performed, or Work that does not meet quality or quantity requirements as required in the Contract Documents.

  • Construction project means the same as that term is defined in Section 38-1a-102.