Majeure Event definition

Majeure Event means an event or circumstance beyond the Parties’ reasonable control that prevents either Party from complying from any of its obligations under the Contract; FOIA means the Freedom of Information Act 2000;

Majeure Event has the meaning specified in clause 15.1;

Majeure Event means any event due to any cause beyond the reasonable control of the Service Provider or, as applicable, any Administrative Support Provider, such as unavailability of communications systems or pricing information, sabotage, fire, flood, explosion, acts of God, civil commotion, strikes or industrial action of any kind, riots, insurrection, war or acts of government, or suspension or disruption of any relevant stock exchange or securities clearance system or market. The Service Provider will use reasonable efforts to minimize the adverse effects to the Client of any Force Majeure Event.

Examples of Majeure Event in a sentence

• Notwithstanding anything to the contrary contained in this Agreement, refusal of or inability to obtain any such permits and approvals by the Contractor or any of its Sub- contractors or their sub-contractors shall not constitute a Force Majeure Event, and shall not in any manner excuse the Contractor from the performance and discharge it of its obligations and liabilities under this Agreement, and the Contractor’s liabilities hereunder shall remain unaffected by such failure, refusal or inability.

• If the period of nonperformance exceeds thirty (30) days from the receipt of notice of the Force Majeure Event, the party whose ability to perform has not been so affected may, by giving written notice, terminate this Contract.

• The Party unable to perform shall advise the other Party of its efforts to remedy its inability to perform and to mitigate the consequences of the Force Majeure Event, and shall advise the other Party of when it believes it will be able to resume performance of its obligations under this Agreement.

• In no event shall the number of days by which a Milestone Completion Target is extended exceed the number of days remaining, as of the date the Force Majeure Event or TxDOT-Caused Delay began, until the Milestone Completion Target.

• In the event TxDOT issues a Change Order to DB Contractor to extend the Substantial Completion Deadline due to a Force Majeure Event or a TxDOT- Caused Delay and such Force Majeure Event or TxDOT-Caused Delay causes delay to the critical path for Milestone Completion of one or more Milestones, the Milestone Completion Target for the affected Milestone may be extended by one day for each day of delay to the critical path for Milestone Completion of the applicable Milestone.

More Definitions of Majeure Event

Majeure Event means an event beyond the reasonable control of the Vendor including act of God, fire, flood or other physical disaster, disruption to transport infrastructure, supply or production facilities, but does not include industrial action.

Majeure Event has the meaning given to it in clause 14. Goods: the goods (or any part of them) set out in the Order. Goods Specification: any specification for the Goods, including any relevant plans or drawings, that is agreed in writing by the Customer and Motion Impossible. Intellectual Property Rights: patents, utility models, rights to inventions, copyright and neighbouring and related rights, moral rights, trademarks and service marks, business names and domain names, rights in get-up and trade dress, goodwill and the right to sue for passing off or unfair competition, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world. Order: the Customer's order for the supply of Goods howsoever received.

Majeure Event means an event beyond a Party's control.

Majeure Event means an event outside the control of a party.

Majeure Event is defined in Section 13.a.

Majeure Event means a circumstance beyond a party’s reasonable control, which circumstances include, but are not limited to, the following: act of God (e.g., flood, earthquake, wind); fire; war; act of a public enemy or terrorist; act of sabotage; strike or other labor dispute; riot; misadventure of the sea; inability to secure materials and/or transportation; or a restriction imposed by legislation, an order or a rule or regulation of a governmental entity.

Majeure Event means an event beyond the reasonable control of a party including the cutting or disconnection of Uecomm’s fibre optic cable; Governmental Agency means any government or any governmental, semi-governmental, administrative, fiscal or judicial body, department, commission, authority, tribunal, government minister, officer, agent or entity including the Australian Communications and Media Authority; GST means the goods and services tax prescribed under the GST Act or any replacement or similar tax;